Brick Floor Price Quote

BRICK FLOOR PRICE QUOTE AND SERVICE AGREEMENT

Quote Number:     Date:

Parties

Contractor Name:

Client Name:

Recitals

WHEREAS, Contractor is engaged in the business of supplying materials and performing installation services for brick flooring, including substrate preparation, bonding, grouting, sealing, and finishing; and

WHEREAS, Client desires to obtain the services of Contractor for the installation of a brick floor at the Project Location described above, and Contractor has provided a price quote for the work described herein; and

WHEREAS, the parties intend that this Price Quote, upon Client acceptance, shall govern the scope, price, schedule, and terms of the work to be performed.

Scope of Work

Work includes: preparation of substrate, removal of existing flooring where specified, installation of brick pavers, jointing/grouting, application of approved sealer, and final cleanup. Any modifications to the Scope of Work must be agreed in writing by both parties and may affect price and schedule.

Itemized Pricing

Quantity:    Unit Price: $    Line Total: $

Quantity:    Unit Price: $    Line Total: $

Quantity:    Unit Price: $    Line Total: $

Subtotal: $    Sales Tax (%):    Sales Tax Amount: $

Total Price (including tax): $

Payment Terms

This Quote requires a deposit equal to % of the Total Price: $ Due upon acceptance.

Remaining balance is due upon completion and acceptance of the work, unless otherwise specified in the Payment Schedule. Late payments shall bear interest at % per month (or the maximum permitted by law), computed from the due date until paid.

Term and Termination

Work Commencement Date: Estimated Completion Date:

Either party may terminate this Agreement for convenience upon days' prior written notice to the other. Contractor may suspend work or terminate immediately for nonpayment or material breach by Client. If terminated, Client shall pay for all work performed and materials purchased up to the effective date of termination, plus reasonable demobilization costs.

Confidentiality

Each party shall treat as confidential the terms of this Quote, pricing, technical information, and any proprietary business information disclosed by the other party in connection with the Project. Confidential information shall not be disclosed to third parties except to employees, subcontractors, lenders or insurers on a need-to-know basis, or as required by law. Confidential obligations do not apply to information that is publicly known through no fault of the receiving party or independently developed by the receiving party.

Governing Law; Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the State of without regard to its conflicts of law rules. The parties shall attempt in good faith to resolve disputes through negotiation; if unresolved, disputes shall be resolved by the courts of the governing state unless the parties agree to binding arbitration in writing.

Representations; Warranties; Entire Agreement

Contractor represents that it is duly licensed (where required) and qualified to perform the Work and that materials supplied shall be as specified and free from material defects. Unless otherwise stated in writing, Contractor provides workmanship warranty of from date of completion. EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS AGREEMENT, CONTRACTOR MAKES NO OTHER WARRANTIES, EXPRESS OR IMPLIED.

This Quote and any documents incorporated by reference constitute the entire agreement between the parties with respect to the subject matter hereof and supersede all prior offers, proposals, negotiations and other communications, whether written or oral. Any modification to this Agreement must be in writing and signed by both parties.

Acceptance

This Quote is valid for days from the Quote Date shown above. Acceptance of this Quote by Client, as evidenced by signature below, constitutes a binding agreement under the terms set forth herein.

Sign Now