Business Communication Wall Letters

Business Communication Wall Letters Agreement

Parties and Contract Identification

Recitals

WHEREAS, Client desires to procure the design, fabrication, delivery and installation of business communication wall letters, dimensional signage, and associated mounting systems (collectively, the "Work") for the location identified below; and

WHEREAS, Contractor represents that it possesses the skill, experience and resources necessary to manufacture and install the Work in accordance with industry standards, applicable codes, and the specifications set forth in this Agreement; and

WHEREAS, the parties wish to set forth their respective rights and obligations with respect to the design, fabrication, delivery and installation of the Work.

Project and Location

Installation Address:

Client Contact:    Phone:

Contractor Contact:    Phone:

Scope of Work

Contractor shall perform the Work in accordance with the specifications described below. The description shall include materials, finishes, mounting systems, electrical work (if applicable), permit procurement responsibilities, and any required testing or certification.

Payment Terms

Total Contract Price: $. Payment shall be made in accordance with the schedule below.

Late Payment: If any undisputed invoice is not paid within days after the due date, interest shall accrue at % per month (or the maximum permitted by law, whichever is less). The foregoing shall be in addition to all other remedies available to Contractor.

Term and Termination

Term Commencement Date: . Estimated Completion Date: .

Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure such breach within days after written notice. Upon termination for cause, Client shall pay Contractor for all Work performed and materials procured to the effective date of termination, subject to applicable offsets for damages.

Warranty and Acceptance

Contractor warrants that the Work will be free from defects in materials and workmanship for a period of following final acceptance. Warranty remedies shall be repair or replacement at Contractor's option. This warranty excludes damage caused by vandalism, misuse, acts of God, or modifications by persons other than Contractor.

Confidentiality

Each party agrees that it will not disclose Confidential Information of the other party to any third party without prior written consent. "Confidential Information" includes designs, pricing, installation methods, technical drawings, contact lists and other non-public business information disclosed in connection with this Agreement. Confidential obligations do not apply to information that: (a) is or becomes publicly available other than through breach of this Agreement; (b) is already lawfully in the receiving party's possession; or (c) is rightfully received from a third party without restriction. The obligations of confidentiality shall survive termination or expiration of this Agreement for a period of years.

Liability and Insurance

Contractor shall maintain commercial general liability and workers' compensation insurance in customary amounts and shall provide certificates of insurance upon request. Except for willful misconduct, each party's liability to the other for direct damages shall be limited to the greater of (i) the amount paid under this Agreement or (ii) $. Neither party shall be liable for consequential, incidental, or punitive damages.

Governing Law; Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the State of , without regard to its conflict of laws principles. The parties shall attempt in good faith to resolve disputes promptly through negotiation between executive-level representatives. If negotiation fails, the parties may pursue any remedy available at law or in equity in the courts of the state identified above.

Entire Agreement; Amendments

This Agreement, including all attachments and change orders executed by the parties, constitutes the entire agreement between Client and Contractor concerning the Work and supersedes all prior proposals and understandings, whether written or oral. Any amendment or modification must be in writing and signed by authorized representatives of both parties.

Miscellaneous Provisions

Assignment: Neither party may assign this Agreement without the prior written consent of the other, except that Contractor may assign to an affiliate or as security. Severability: If any provision is found unenforceable, the remainder shall remain in effect. Notices: All notices shall be in writing and delivered to the addresses set forth above.

Sign Now