Establishing secure connection…Loading editor…Preparing document…

Business PCOs Template

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

BUSINESS PCOs TEMPLATE

Recitals

WHEREAS, Client Name: and Contractor Name: entered into a written Agreement dated (the "Agreement") under which Contractor performs certain services for Client.

WHEREAS, Contractor proposes a change to the Scope of Work described in the Agreement and submits this Proposed Change Order (PCO) for Client's review; and

WHEREAS, the Parties desire to document the proposed change, associated cost and schedule impacts, and the terms pursuant to which the change will be implemented if approved.

PCO Details

Date Submitted:

Requested By:

Change Type:

Scope of Work

The Contractor shall perform the following additional or revised work if this PCO is approved:

Cost Impact

Affect on Contract Price:

Affect on Retainage (if any):

Schedule Impact

Estimated impact to the Contract Schedule: Additional Days: ; Revised Completion Date:

Payment Terms

Payment for approved work under this PCO shall be governed by the following terms:

Payments are due within days of invoice. Overdue amounts shall bear interest at % per month or the maximum rate permitted by law, whichever is less. A late fee minimum of applies to each delinquent payment.

Term and Termination

This PCO, if approved, becomes an amendment to the Agreement effective as of the Effective Date set forth below and remains in effect until the completion of the revised work or earlier termination in accordance with this Section.

Effective Date:

Anticipated Completion Date:

Notice Period to Terminate: days written notice

Either Party may terminate performance of the work described herein if the other Party materially breaches the Agreement or this PCO and fails to cure such breach within the notice period set forth above.

Confidentiality

Each Party shall maintain in confidence and shall not disclose to any third party Confidential Information of the other Party disclosed in connection with this PCO, except as required by law or as necessary to perform the work. Confidential Information does not include information that is or becomes generally known through no fault of the receiving Party, was rightfully in the receiving Party’s possession prior to disclosure, or is rightfully received from a third party without restriction.

Confidential information required to be disclosed pursuant to law shall be disclosed only after prompt written notice to the disclosing Party and, where appropriate and available, after seeking protective relief.

Governing Law

This PCO shall be governed by and construed in accordance with the laws of the State of without regard to its conflicts of law principles.

Entire Agreement

Upon approval by the Parties, this PCO and the Agreement, as amended, constitute the entire agreement between the Parties with respect to the subject matter hereof and supersede all prior negotiations, proposals or understandings, whether written or oral, concerning the subject matter. No amendment to this PCO shall be effective unless in writing and signed by authorized representatives of both Parties.

Approvals / Responses

Client Approval:

Contractor Acceptance:

Client:

By:

Date:

Contractor:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Business PCOs Template Is

A Business PCOs Template is a standardized form used to propose, document, and track proposed change orders (PCOs) to an existing commercial agreement or project scope. It captures the change description, estimated cost impact, schedule impact, authorization routing, and supporting attachments so parties share the same written record. The template reduces ambiguity by documenting scope, dates, and signatures and supports electronic workflows and audit trails for compliance and later reference.

Why a Clear PCO Template Matters

Using a consistent Business PCOs Template reduces disputes, speeds approvals, and preserves a defensible record of scope and cost changes. It helps finance and project teams evaluate impacts quickly and creates an auditable trail that supports contract enforcement and payment reconciliation.

Why a Clear PCO Template Matters

Who Typically Completes a PCO

Project managers, contract administrators, and procurement teams most often create and issue PCOs when scope changes arise during execution.

  • Construction managers and site superintendents who document scope changes and attach drawings, cost estimates, and schedule revisions for contractor approvals.
  • Procurement and purchasing teams who capture price changes, vendor proposals, and PO amendments to align purchasing and payment.
  • Legal and contract admins who ensure authorization limits are respected and that the PCO aligns with the master contract and lien waiver requirements.

Legal, finance, and client stakeholders review and approve PCOs according to the project’s approval matrix before changes take effect.

Step-by-Step: Issue and Approve a PCO

Follow a consistent sequence to create, circulate, approve, and record a PCO so changes are enforceable and auditable.

  • 01
    Draft PCO: Prepare the change description, cost estimate, and schedule impact; attach supporting documents.
  • 02
    Internal Review: Route to finance and project stakeholders for budget and constructability review.
  • 03
    External Approval: Send to the client or counterparty for acceptance using documented routing and authentication.
  • 04
    Record and Close: File the executed PCO with contract records and update project cost and schedule logs.

Configure an Online PCO Workflow

Key workflow settings ensure the PCO moves through the correct reviewers and captures an audit trail for each action.

Field Configuration
Routing Order Define signer sequence for internal and external approvals
Authentication Use email + optional SMS code for signer verification
Attachments Allow PDF, DOCX, and image uploads; enforce required attachments
Notifications Set reminders and escalations for overdue approvals

Where to Send and How to File an Executed PCO

An executed PCO should be delivered to internal records, the counterparty, and any project document repositories used for contract management.

  • Primary Recipient: Send signed PCO to the contract administrator and the client contact listed on the master contract
  • Finance: Route executed copy to accounts payable for payment or invoice adjustments
  • Project File: Store the executed PCO in the official project folder or document management system
  • Third Parties: Share with subcontractors or suppliers only if fees or scope directly affect them

Digital Signing and Distribution Options

Choose a signing platform that supports templates, role-based routing, and a reliable audit trail.

  • File Formats: PDF, DOCX, and Excel supported for templates and attachments
  • Integrations: Connectors for Salesforce, NetSuite, Google Workspace, and Box reduce manual entry
  • Authentication: Email, SMS code, and advanced signer verification available

eSignature Pricing and Feature Snapshot

Typical small-to-midmarket plans vary by price model and features. The table compares starting price, trial options, bulk send, audit trail, HIPAA compliance, and envelope caps across vendors.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No envelope cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Security and Compliance Data to Preserve

Encryption: TLS 1.2/1.3 in transit; AES-256 at rest
Audit Trail: Timestamped logs with IP and action history
Certifications: SOC 2 Type II; ISO 27001
HIPAA: Compliant (BAA required)
21 CFR Part 11: Supported for regulated records
Data Privacy: GDPR and CCPA compliance frameworks available

Key Risks and Consequences of Incorrect PCOs

Payment Delays: Withholding or delayed compensation
Contract Disputes: Increased litigation or arbitration risk
Schedule Impact: Unapproved schedule changes causing claims
Cost Overruns: Untracked expenses inflating project budget
Lien Risk: Subcontractor liens for unpaid work
Compliance Exposure: Regulatory or audit penalties for missing records

Common Preparation Mistakes to Avoid

  • Vague change descriptions that omit drawings, clause references, or measurable acceptance criteria, causing disagreement about scope.
  • Missing or inconsistent project identifiers that prevent the PCO from being linked to purchase orders or invoices during reconciliation.
  • Failing to state whether cost figures are estimates or firm amounts, which delays approvals and creates payment disputes.
  • Skipping required approver roles or exceeding approval limits, which can render the PCO non-binding until proper authorization is obtained.

Core Components Every Business PCOs Template Should Include

A robust PCO template contains fields that clarify scope, quantify impacts, and document authorization to ensure each change is actionable and auditable.

Change Summary

Concise narrative describing the work to be added, deleted, or modified; reference plan sheets and contract clauses to eliminate ambiguity.

Cost Breakdown

Line-item estimate of labor, materials, overhead, and contingency; identify whether amounts are provisional or fixed for payment processing.

Schedule Effect

Explicit statement of days added or reduced and updated milestone dates; indicate critical path impact and rationale for any float adjustments.

Supporting Documents

Attach quotes, submittals, revised drawings, or vendor proposals that substantiate the cost and schedule claims for review.

Approval Matrix

List required signers, order of approvals, and any monetary thresholds that trigger additional executive or client sign-off.

Signature Block

Space for signer name, title, date, and electronic signature with an audit trail showing authentication method and timestamp.

Practical Examples of PCO Use

Real-world examples show how standardized templates reduce turnaround time and preserve auditability across contract changes.

Martin Properties

A small development firm needed faster approvals for minor scope changes

  • They adopted a templated PCO with required attachments
  • "I can process and execute all of these documents online with 100% compliance and built-in security," said Tim Martin, Founder, describing faster execution and clearer records.

Xerox / NetSuite

A large enterprise integrated change orders into its ERP to automate cost posting

  • Integration reduced manual rekeying and errors
  • Kodi-Marie Evans, Director of NetSuite Operations, noted that the integration provided flexibility to capture signatures and update financial systems without duplicate entry.

Frequently Asked Questions about Business PCOs

Answers to common questions about e-signing, authority, notarization, revisions, and recordkeeping for PCOs.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.