Can this form be signed electronically?

Yes. Electronic signatures are enforceable under the federal ESIGN Act (15 U.S.C. ch. 96, 2000) and most state UETA laws, provided intent, consent, attribution, and retention requirements are met.

When is notarization required?

Most construction contracts do not require notarization. Certain jurisdictions or specific instruments (deeds, some affidavits) may require a notary; check state notary and lien statutes for confirmation.

Who must sign the form?

An authorized representative of each legal entity should sign; use the entity’s exact legal name and indicate the signer’s title to avoid disputes about authority and enforceability.

What supporting documents are needed?

Attach scope exhibits, drawings, insurance certificates, performance/payment bonds, and any licensing proof. Missing exhibits frequently cause scope disputes and payment delays.

How do I correct a signed error?

If parties agree, execute a written amendment signed by authorized representatives. For minor typographical errors, a bilateral amendment or signed addendum is standard practice to preserve the original effective date.

How long should I keep the executed form?

Retain executed forms for the contract term plus at least three years; tax and healthcare rules can require longer retention (IRC §6501(a); HIPAA 45 CFR §164.530(j)). State law may extend these periods.

Electronic Signature
Templates
Miscellaneous
Construction Builder Form

Construction Builder Form

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

CONSTRUCTION BUILDER FORM

This Construction Builder Form (the Agreement) is made between the parties identified below pursuant to the terms set forth herein.

Parties

Contractor (Builder) Contractor Address Client Client Address

Recitals

WHEREAS, Contractor is duly licensed and engaged in the business of construction, renovation, and related services and represents that Contractor has the skill, experience, and ability to perform the construction work described herein; and

WHEREAS, Client desires to retain Contractor to perform construction services at the project location identified below, and Contractor agrees to perform such services under the terms and conditions set forth in this Agreement; and

WHEREAS, the parties intend for this Agreement to set forth the entire understanding of the parties with respect to the scope, schedule, payment, insurance, and legal obligations relating to the Project.

Project Identification

Project Address:

Project Title/Reference:

Scope of Work

Contractor shall furnish all labor, materials, tools, equipment, supervision, and services necessary to perform the work described below in a good and workmanlike manner in accordance with industry standards and applicable codes:

Project Schedule

Commencement Date:

Substantial Completion Date:

Payment Terms

Contract Sum (Total Price): $

Payment Schedule / Milestones

Deposit Amount: $ payable upon execution of this Agreement.

Late Payment Fee: applied to overdue balances after 30 days.

Change Orders

All alterations, additions, or deletions to the Scope of Work shall be executed only by written Change Order signed by both parties, which shall state the change in work, any adjustment to the Contract Sum, and any adjustment to the Contract Time.

Permits, Licenses, and Approvals

Responsibility for securing permits and approvals: Contractor Client

Permit Authority / Number (if known)

Insurance and Licensing

Contractor License No.:

Insurance Requirements

Warranties

Contractor warrants that work performed under this Agreement shall be free from defects in workmanship for a period of from substantial completion, subject to normal wear and tear, misuse, or alteration by others.

Confidentiality

Each party shall treat as confidential all proprietary or non-public information disclosed by the other party in connection with the Project. Confidential information shall not include information that is or becomes publicly available through no fault of the receiving party, or information lawfully obtained from a third party. This obligation shall survive termination of this Agreement for a period of two years.

Indemnification

Contractor shall indemnify, defend, and hold harmless Client from and against claims, liabilities, losses, and expenses (including reasonable attorneys' fees) arising out of Contractor’s negligent performance of the Work, provided such claims are not due to Client's negligence or willful misconduct.

Term and Termination

Agreement Start Date:

Agreement End Date (if applicable):

Either party may terminate this Agreement for material breach by the other party if such breach is not cured within days after written notice. Termination shall not relieve the Client of obligation to pay for work performed to termination date.

Governing Law

This Agreement shall be governed by and construed in accordance with the laws of the state identified below without regard to its conflict of laws principles.

Governing State

Entire Agreement

This Agreement, including all exhibits and any written Change Orders signed by both parties, contains the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements, whether written or oral, relating to the subject matter hereof. No amendment or modification shall be binding unless in writing and signed by both parties.

Miscellaneous Provisions

Notices under this Agreement shall be in writing and delivered to the addresses set forth in this form. If any provision of this Agreement is held invalid, the remaining provisions shall remain in full force and effect.

Contractor:

By:

Date:

Client:

By:

Date:

What the Construction Builder Form Is

Construction Builder Form is a standardized contract used by general contractors, subcontractors, and owners to document scope, schedule, payment terms, permits, insurance, change orders, and lien rights for a construction project. It establishes parties' responsibilities, milestone payments, retainage, and dispute-resolution provisions, and typically incorporates exhibits such as plans and schedules. In the United States such forms must align with state construction lien statutes and applicable consumer- and employment-related rules. When executed electronically, the form should meet ESIGN/UETA requirements for intent, consent, attribution, and retention to ensure enforceability.

Why a Clear Builder Form Matters

A complete Construction Builder Form reduces ambiguity, speeds payments, documents change orders, and preserves lien rights. Clear terms protect parties from disputes, streamline approvals, and create an auditable record that supports compliance with state lien statutes and contractor licensing requirements.

Who Completes and Relies on This Form

Typical users who complete or receive a Construction Builder Form include general contractors, specialty subcontractors, property owners, project managers, and construction administrators.

General contractors — prepare and manage project contracts, schedules, and payments.
Subcontractors — submit scope attachments, lien waivers, and billing details for payment.
Project owners — review scope, approve change orders, and control funding and retainage.

Use the form to communicate obligations clearly, create an auditable record for payments and lien rights, and provide a single source of truth for project milestones and approvals.

Primary Signer Roles

General Contractor

The general contractor typically prepares the form, coordinates subcontractor attachments, and signs on behalf of the contracting entity. Ensure the signer is an authorized officer or agent and the legal entity name matches tax and licensing records.

Owner / Developer

Owners approve scope, releases, and retainage and usually sign to authorize funding and change orders. The signing representative should be authorized and the party designation match ownership documents to avoid enforceability issues.

Security and Compliance Features to Expect

Encryption: TLS 1.2/1.3 in transit; AES-256 at rest

Certifications: SOC 2 Type II and ISO 27001 certified

HIPAA: BAA available for covered entities

Audit Trail: Detailed timestamp, IP, and action history

Authentication: Multi-factor, SMS codes, KBA options

Access Controls: Role-based permissions with SSO support

Key Risks and Potential Consequences

Payment Delay: Claims, stop notices, or mechanic's liens

Improper Waiver: Improper waiver may waive lien rights

Wrong Parties: Invalid signature; unenforceable agreement

Missing Permits: Fines, remediation, work stoppage

Tax Exposure: Backup withholding if TIN missing

Statute Noncompliance: Lose statutory lien protections

Common Preparation Errors to Avoid

Leaving the contract price, retainage, or payment schedule ambiguous leads to disputes and late payments; include exact percentages, milestone triggers, and clear invoice procedures.
Failing to attach plans, specifications, or scopes creates scope gaps that cause change-order conflicts and additional costs during construction.
Using initials in place of full authorized signatures or listing a non-legal business name can render the contract unenforceable and complicate lien filings.
Not including notice procedures and designated contacts for change orders and disputes delays responses and frequently escalates to formal claims.

Step-by-Step: Completing the Builder Form

Use this sequence to prepare, review, and execute the Construction Builder Form so it is complete and enforceable before work begins.

01

Prepare document: Assemble scope, drawings, schedule, and insurance certificates.
02

Enter parties: Use exact legal entity names and authorized signers.
03

Define payments: Specify price, milestones, retainage, and invoice terms.
04

Execute and record: Sign, obtain notarization if required, and distribute copies.

How Execution and Routing Typically Work

Typical delivery and signing flows for a Construction Builder Form vary by project size and whether signing is electronic or in person.

Authoring: Draft in authoring system and attach exhibits.
Internal review: Legal and project teams check terms and insurance.
Signer routing: Send in sequence to contractor, subcontractor, then owner.
Completion: Collect signatures, save executed copy, retain audit trail.

Core Sections to Include in a Professional Form

A robust Construction Builder Form contains discrete sections that together define obligations, remedies, and administrative procedures for the project.

Scope of Work

Precisely describe tasks, deliverables, referenced drawings, and any excluded items; attach the specifications and drawings as enforceable exhibits to avoid ambiguity and disputes.

Payment Terms

Set the contract price, progress payment schedule, retainage percentage, criteria for invoice acceptance, and remedies for late payment to limit disputes and accelerate cash flow.

Schedule & Milestones

Include start and completion dates, milestone definitions, critical-path dependencies, and liquidated damages or incentives tied to timely performance and acceptance.

Change Orders

Define written approval process, pricing methodology for changes, time impact assessments, and authorization thresholds for field directives versus formal change orders.

Insurance & Bonds

Specify minimum insurance types and limits, required performance and payment bonds, additional insured endorsements, and certificate requirements prior to mobilization.

Lien Waivers & Remedies

Address conditional and unconditional lien waivers, procedures for releases upon payment, and dispute-resolution paths including mediation, arbitration, or litigation venue.

Configuring an Electronic Workflow

Set up your digital workflow to match signatory order, authentication level, and integration needs before sending the form for signature.

Field	Configuration
E-signature method	Email link, SMS code, or advanced auth
Field types	Signature, initials, date, conditional fields
Signer order	Sequential or parallel routing options
Integrations	Connect to Procore, NetSuite, Salesforce, Google Workspace

Technical Formats and Integrations

Ensure your platform supports common file formats and the integrations you need for project administration.

File formats: PDF, DOCX, and Excel supported
Project integrations: Procore, NetSuite, Salesforce integrations
Storage options: Box, Google Drive, Egnyte supported

eSignature Pricing and Feature Comparison

Compare starter pricing and core feature availability among common eSignature providers; signNow is listed first per comparison convention.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day trial	Varies	Varies	Varies	Varies
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No cap	100 envelopes/user/year	Varies	Varies	Varies

Real-World Examples from Customers

Construction and property management teams use digital signing to speed execution and keep projects moving without in-person signatures.

Optica Ventures LLC — COO

Optica consolidated contractor documents into a single digital workflow to reduce back-and-forth.

The interface simplified customer signing.
After implementation they reported faster turnaround and fewer missing attachments, enabling consistent execution of builder agreements across multiple simultaneous projects while maintaining compliance controls.

Martin Properties — Founder

Martin Properties moved all forms online to handle remote closings and subcontractor signoffs.

Mobile signing was essential.
This allowed the team to execute contracts and change orders from mobile devices, reduce in-person coordination, and maintain an auditable record for payments, lien waivers, and insurance certificates.

Typical Deadlines and Timing Considerations

Key dates affect notice rights, payments, and lien filings; confirm state-specific deadlines and incorporate them into the contract schedule.

Effective Date:

The MM/DD/YYYY date when obligations begin and milestones are measured.

Notice to Proceed:

Formal authorization to start work; often triggers schedule and insurance obligations.

Progress Payment Due:

Invoice due dates tied to completion milestones or monthly cycles.

Lien Claim Deadline:

Deadline varies by state; often measured from last furnished labor or materials.

Final Acceptance:

Date for closeout, retainage release, and final lien waiver exchange.

FAQs and Troubleshooting

Answers to common questions about execution, e-signing, notarization, and recordkeeping for a Construction Builder Form.

Need help? Contact support

Can this form be signed electronically?
Yes. Electronic signatures are enforceable under the federal ESIGN Act (15 U.S.C. ch. 96, 2000) and most state UETA laws, provided intent, consent, attribution, and retention requirements are met.
When is notarization required?
Most construction contracts do not require notarization. Certain jurisdictions or specific instruments (deeds, some affidavits) may require a notary; check state notary and lien statutes for confirmation.
Who must sign the form?
An authorized representative of each legal entity should sign; use the entity’s exact legal name and indicate the signer’s title to avoid disputes about authority and enforceability.
What supporting documents are needed?
Attach scope exhibits, drawings, insurance certificates, performance/payment bonds, and any licensing proof. Missing exhibits frequently cause scope disputes and payment delays.
How do I correct a signed error?
If parties agree, execute a written amendment signed by authorized representatives. For minor typographical errors, a bilateral amendment or signed addendum is standard practice to preserve the original effective date.
How long should I keep the executed form?
Retain executed forms for the contract term plus at least three years; tax and healthcare rules can require longer retention (IRC §6501(a); HIPAA 45 CFR §164.530(j)). State law may extend these periods.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now