Curb Height Measurement Form

Curb Height Measurement Form and Measurement Services Agreement

Project and Parties

Project Name:

Date of Measurement:   Inspector Name:

Inspector License / Cert. No.:   Equipment Used:

WHEREAS

WHEREAS, Client Name: requires accurate curb height measurements at the Project Address for design, compliance, or construction verification purposes; and

WHEREAS, Contractor Name: represents it is qualified to perform said measurements in accordance with industry practice and applicable tolerances; and

NOW, THEREFORE, the parties agree as follows with respect to measurement services and the collection, documentation, and certification of curb heights at the Project Address.

Scope of Work

Measurement Data and Observations

Measurement Methodology:

Payment Terms

Contract Amount: $

Late Payment Fee:

Invoices are payable within days of invoice date unless otherwise agreed in writing.

Term and Termination

Effective Date:   Anticipated Completion Date:

Either party may terminate this Agreement for material breach if the breaching party fails to cure within days after written notice. Termination shall not relieve Client of obligation to pay for services rendered and documented through the effective date of termination.

Confidentiality

Contractor shall maintain as confidential all non-public information received from Client pertaining to this Project and shall not disclose measurement data, survey control, or as-built drawings to third parties without prior written consent of Client, except as required by law or for performance of the work. This obligation survives termination for a period of three (3) years.

Certifications, Tolerances, and Liability

Contractor certifies that measurements recorded on this form were taken using the stated equipment and methodology and to the tolerances set forth in this form. Measurements reflect conditions observed at the time of inspection and are subject to change due to subsequent site activity or environmental factors.

Client acknowledges that Contractor's sole obligation is to perform measurements with reasonable professional care. Contractor's total liability for errors in measurement shall be limited to the amount paid for the measurement services under this Agreement, except to the extent governed otherwise by applicable law.

Governing Law and Entire Agreement

This Agreement shall be governed by and construed in accordance with the laws of the jurisdiction where the Project is located, without regard to conflict of law principles. Venue for any dispute relating to this Agreement shall be exclusive to the courts located in that jurisdiction.

This document, together with any attachments or referenced drawings, constitutes the entire agreement between Client and Contractor with respect to the subject matter and supersedes all prior oral or written agreements. Any amendment must be in writing and signed by authorized representatives of both parties.

Limitations and Notices

Measurements do not verify compliance with building code or accessibility requirements unless specifically retained to do so. Client is responsible for independent verification if required for regulatory submissions. Contractor is not responsible for latent site conditions or third-party work affecting curb geometry after measurement.

Sign Now