Can this agreement be signed electronically?

Yes. Electronic signatures are legally binding under the federal ESIGN Act (15 U.S.C. ch. 96) and state UETA laws when intent, consent, attribution, and retention are present. Exceptions may apply for documents requiring notarization, court filings, or where a lender requires an acknowledged signature.

Who should sign on behalf of a business?

An authorized company officer or agent with legal authority must sign. For LLCs or corporations, use the named signatory listed in formation documents or a board resolution. Mismatched signer names or unsigned power of attorney may impair enforceability.

Are notarization or witnesses necessary?

Most Custom Countertops Agreements do not require notarization or witnesses to be enforceable. However, specific lender conditions, local construction finance rules, or state statutes related to lien waivers or deeds may require notarization or witnesses; always verify with jurisdictional counsel.

How do I amend the agreement?

Amendments should be in writing, reference the original agreement, describe changes precisely, and be signed and dated by all parties. For electronic amendments, ensure e-signature consent is maintained and preserve the audit trail showing who approved each change and when.

Can I cancel or revoke after signing?

Revocation depends on contract terms and state law. If the agreement includes a cancellation clause, follow its process and any defined fees. Absent an express right to cancel, revocation may be limited; consult counsel and preserve written notice of cancellation actions.

What if materials or installation are defective?

Follow the contract's warranty and claim procedures: notify the fabricator in writing, document defects with photos and dates, and allow reasonable cure time. If unresolved, pursue contractual remedies such as repair, replacement, or limited refund, and consider dispute resolution clauses.

Electronic Signature
Templates
Miscellaneous
Custom Countertops Agreement

Custom Countertops Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

CUSTOM COUNTERTOPS AGREEMENT

This Custom Countertops Agreement ("Agreement") is made and entered into on by and between:

Client Name:

Client Address

Contractor Name:

Contractor Address

WHEREAS

WHEREAS, Client desires the design, fabrication and installation of custom countertops for the Client property in accordance with the specifications set forth in this Agreement; and

WHEREAS, Contractor represents that it has the skill, experience and proper licensing to fabricate, finish and install countertops and related work, and agrees to perform such work under the terms and conditions herein; and

WHEREAS, the parties desire to set forth their entire agreement with respect to the fabrication, delivery and installation of the custom countertops.

SCOPE OF WORK

Contractor shall perform all labor, supervision, materials, tools, equipment, transportation and services necessary to complete the countertops installation described below. Specific work to be provided:

Scope of Work — Describe services, locations, and limits of work Materials and Specifications Project Measurements / Notes

Template and on-site measurements required: Yes Sealer / finish included: Yes

PAYMENT TERMS

Client agrees to pay Contractor the total contract price set forth below in exchange for satisfactory performance of the Scope of Work. All payments shall be in United States dollars.

Total Contract Price Deposit

Deposit due on or before:

Balance

Balance due on or before:

Payment Method

Late payments shall incur a late fee of % per month, compounded monthly, or a late fee of $ , whichever is greater. Client shall also be responsible for reasonable collection and legal costs incurred by Contractor.

Change Orders

TERM AND TERMINATION

This Agreement commences on the start date below and shall continue until completion of the Scope of Work unless earlier terminated in accordance with this Agreement.

Start Date: Estimated Completion Date:

Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure the breach within days after written notice. Termination shall not relieve Client of the obligation to pay for Work performed up to the date of termination.

CONFIDENTIALITY

Each party shall maintain in confidence any non-public business, technical or financial information disclosed by the other party in connection with this Agreement and shall not disclose such information to third parties except as required by law or as necessary to perform its obligations hereunder. Confidential information does not include information that is publicly known or becomes publicly known through no fault of the receiving party.

WARRANTY; INSURANCE; INDEMNITY

Contractor warrants that work performed shall be free from defects in workmanship for a period of months from substantial completion, subject to normal wear and tear and misuse. Manufacturer warranties for materials apply where provided; Contractor does not extend manufacturer warranties.

Contractor shall maintain insurance sufficient to cover its obligations and shall indemnify and hold Client harmless from claims arising from Contractor's negligent acts in performing the Work, except to the extent caused by Client's negligence.

Proof of insurance provided upon request: Yes

GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be governed by and construed in accordance with the laws of the State of without regard to its conflicts of law principles. The parties shall attempt in good faith to resolve disputes through negotiation. If unresolved, disputes may be submitted to binding arbitration or to the courts of the governing state as elected by the initiating party.

ENTIRE AGREEMENT

This Agreement, including any attachments or signed change orders, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, representations and agreements, whether written or oral. Any modification must be in writing and signed by both parties.

ACCEPTANCE AND FINAL TERMS

By signing below, each party acknowledges that it has read, understands, and agrees to be bound by the terms and conditions of this Agreement, including payment and termination provisions.

Client:

By:

Date:

Contractor:

By:

Date:

What the Custom Countertops Agreement Covers

The Custom Countertops Agreement is a written contract that defines the scope, materials, measurements, timeline, and payment terms for fabrication and installation of custom countertops. It allocates responsibility for templates, site preparation, change orders, and permits, and establishes acceptance criteria and warranty obligations. The agreement can include exhibits such as material specifications, installation schedules, and permit copies. When executed properly it creates enforceable rights and remedies between homeowner or commercial owner and fabricator/installer, and may be integrated with lien waiver and payment application procedures used in construction projects.

Why a Written Agreement Matters for Countertops

Use a Custom Countertops Agreement to set clear expectations for materials, measurements, lead times, payments, and warranties. A complete agreement reduces disputes, supports payment claims and lien procedures, and establishes a record suitable for electronic execution under the ESIGN Act and state law.

Who Typically Uses a Custom Countertops Agreement

Typical parties who use a Custom Countertops Agreement include homeowners, contractors, fabricators, and property managers engaged in remodels or new construction.

Homeowners and property owners managing renovations or upgrades, needing clear scope and warranty terms.
Countertop fabricators and installers documenting material specifications, measurement tolerances, and installation responsibilities.
General contractors and property managers coordinating schedules, payments, and lien waiver requirements across trades.

The agreement also benefits lenders, general contractors, and architects when it clarifies payment flow, change orders, and acceptance criteria for installed countertops.

Core Sections to Include in the Agreement

Core sections of a professional Custom Countertops Agreement define scope, materials, measurements, payment, delivery schedule, and warranty with clear acceptance criteria and change order procedures.

Scope of Work

Describe the exact fabricating and installation tasks, finished edges, sink cutouts, seams, and on-site responsibilities. Include who supplies materials and who performs site prep and final cleaning.

Materials & Specs

Specify stone or surface type, color, grade, slab selection process, edging profile, sealer type, and acceptable tolerances. Attach manufacturer specifications and cut sample approvals documentation.

Measurements

Record field template dates, measured dimensions, and tolerances. Note who verifies measurements and the deadline for approving templates before fabrication begins to avoid rework and extra charges.

Payment Terms

State deposit amount, progress payments, final payment due on completion, accepted payment methods, and conditions for withholding payment due to defects or incomplete work remedies.

Schedule & Delivery

Provide estimated fabrication lead times, site availability windows, delivery and install dates, allowable weather or permit-related delays, and procedures for schedule changes and delay charges.

Warranty & Remedies

Define warranty duration, coverage of workmanship and materials, procedures for claiming defects, correction timelines, and remedies including repair, replacement, or limited refund and any exclusions.

Step-by-Step: From Draft to Signed Agreement

Follow these steps to prepare, approve, and execute a Custom Countertops Agreement to minimize delays and disputes during fabrication and installation.

01

Prepare Contract: Draft scope, materials, payment schedule, and warranty terms.
02

Confirm Measurements: Take templates and verify dimensions on-site before fabrication.
03

Approve Sample: Approve slab, edge, and sealer samples in writing.
04

Finalize & Sign: Collect signatures, dates, and any notarizations or lien waivers required.

How Electronic Execution Works for This Agreement

Digital signing flow for a Custom Countertops Agreement reduces turnaround and preserves an audit trail suitable for dispute resolution.

Upload Document: Attach contract, specs, and templates for signature.
Place Fields: Add signature, date, and measurement confirmation fields.
Send to Signer: Email or link with authentication options.
Complete Audit: System records timestamp, IP, and action history.

Recommended Online Workflow Configuration

Configure an online workflow to collect measurements, place conditional fields, route approvals, and capture audit trails for every executed Custom Countertops Agreement.

Field	Configuration
Authentication	Email link with optional SMS verification.
Templates	Reusable contract templates with prefilled fields.
Conditional Fields	Show measurement fields only after template approval.
Notifications	Automated email reminders for outstanding approvals.
Integrations	Connect to CRM and project management tools.

Platform Capabilities to Look For

Use a platform that supports PDF, DOCX, and image templates, provides audit trails, and integrates with your project systems for streamlined execution.

File Formats: PDF, DOCX, JPG support.
Integrations: Salesforce, NetSuite, Procore supported.
Authentication: Email, SMS, or advanced MFA.

eSignature Pricing and Feature Comparison

Comparison of common eSignature providers for executing Custom Countertops Agreements; signNow is shown first with verified plan details and limits for context.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies	Varies	Varies	Varies
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No cap	100 envelopes/user/year	Varies	Varies	Varies

Typical Project Deadlines and Lead Times

Typical deadlines and lead times for fabrication, delivery, and warranty claims are listed below to set expectations.

Template Approval Deadline:

Approve templates within three to seven business days of measurement to avoid delays

Fabrication Lead Time:

Allow seven to twenty-one business days depending on material and shop backlog

Installation Window:

Schedule installation within the agreed two-day window and confirm site readiness

Final Payment Due:

Pay final balance upon satisfactory installation and signed acceptance form

Warranty Claim Period:

Follow warranty claim procedures within stated warranty period to preserve remedies

Short-Form Risks and Penalties

Measurement Errors: May trigger re-cut fees

Delayed Access: Can cause schedule and cost overruns

Nonpayment: Leads to mechanic's lien risk

Improper Materials: Void warranty or require replacement

Unauthorized Changes: Can result in cost and time claims

Missing Permits: May halt installation and incur fines

Common Preparation Mistakes to Avoid

Unclear scope or vague material descriptions frequently cause disputes over finish quality, seam placement, acceptable color variance, and responsibility for site preparation, which leads to change orders and acceptance delays.
Missing or late template approvals commonly force shops to re-cut countertops, increasing labor costs, causing installation rescheduling, and creating material waste and additional charges.
Incomplete payment terms or lack of lien waiver procedures expose contractors to nonpayment risk and complicate recovery through mechanic's lien or collections.
Poor documentation of site conditions and access instructions often leads to additional onsite time, travel fees, and disputes about responsibility for installation delays.

Frequently Asked Questions About Execution and Enforcement

Common questions about executing, amending, signing, and enforcing a Custom Countertops Agreement are answered below with practical guidance and legal context.

Need help? Contact support

Can this agreement be signed electronically?
Yes. Electronic signatures are legally binding under the federal ESIGN Act (15 U.S.C. ch. 96) and state UETA laws when intent, consent, attribution, and retention are present. Exceptions may apply for documents requiring notarization, court filings, or where a lender requires an acknowledged signature.
Who should sign on behalf of a business?
An authorized company officer or agent with legal authority must sign. For LLCs or corporations, use the named signatory listed in formation documents or a board resolution. Mismatched signer names or unsigned power of attorney may impair enforceability.
Are notarization or witnesses necessary?
Most Custom Countertops Agreements do not require notarization or witnesses to be enforceable. However, specific lender conditions, local construction finance rules, or state statutes related to lien waivers or deeds may require notarization or witnesses; always verify with jurisdictional counsel.
How do I amend the agreement?
Amendments should be in writing, reference the original agreement, describe changes precisely, and be signed and dated by all parties. For electronic amendments, ensure e-signature consent is maintained and preserve the audit trail showing who approved each change and when.
Can I cancel or revoke after signing?
Revocation depends on contract terms and state law. If the agreement includes a cancellation clause, follow its process and any defined fees. Absent an express right to cancel, revocation may be limited; consult counsel and preserve written notice of cancellation actions.
What if materials or installation are defective?
Follow the contract's warranty and claim procedures: notify the fabricator in writing, document defects with photos and dates, and allow reasonable cure time. If unresolved, pursue contractual remedies such as repair, replacement, or limited refund, and consider dispute resolution clauses.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now