Establishing secure connection…Loading editor…Preparing document…

Design Step Template

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

DESIGN STEP TEMPLATE

Parties and Effective Date

Client Name:     Designer Name:

Project Title:     Effective Date:

Recitals

WHEREAS, Client Name: seeks professional design services for the Project Title identified above; and

WHEREAS, Designer Name: represents that it has the experience, personnel and resources to perform the design services described in this Design Step Template; and

NOW, THEREFORE, in consideration of the mutual covenants herein contained, the parties agree as follows.

Scope of Work

Payment Terms

Client shall pay Designer for the services described in the Scope of Work in accordance with the schedule below. All amounts are payable in lawful currency. Unless otherwise specified, invoices are due upon receipt and become past due if not paid within the stated payment period.

Milestone-based — payments tied to completion of defined milestones.

Upon delivery and Client acceptance of deliverables.

Monthly installments — specify due date below.

Payments not received within 30 days of invoice date shall incur interest at the lesser of 1.5% per month (18% per annum) or the maximum rate permitted by law, and Client shall be responsible for any collection costs, including reasonable attorneys' fees.

Change Orders

Any material change to the Scope of Work shall be documented in a written change order signed by both parties, describing additional work, revised schedule and any additional compensation. Designer is not required to proceed with changes until a signed change order is in effect.

Term and Termination

This Design Step shall commence on Start Date: and shall continue until End Date: , unless earlier terminated in accordance with this Agreement.

Either party may terminate this step for material breach by the other party if the breach remains uncured for a period of Notice Period: days after written notice. Upon termination, Client shall pay Designer for work performed and expenses incurred through the effective date of termination as documented in invoices.

Confidentiality

Each party may disclose Confidential Information to the other. "Confidential Information" means information disclosed in any form that is identified as confidential or that a reasonable person would understand to be confidential. Recipient shall use the same degree of care to protect Confidential Information as it uses to protect its own confidential information, but in no event less than reasonable care. Confidential Information does not include information that is or becomes publicly available through no breach of this Agreement, is independently developed, or is lawfully obtained from a third party.

The obligations of confidentiality shall survive termination of this Design Step for a period of 3 years except with respect to trade secrets, for which protection shall continue for so long as the information qualifies as a trade secret under applicable law.

Acknowledgement: Client and Designer each acknowledge they will comply with the confidentiality obligations set forth above.

Intellectual Property and Licenses

Unless otherwise agreed in writing, Designer retains ownership of underlying concepts, processes, techniques and tools. Upon full payment of fees for this Step, Designer grants Client a non-exclusive, worldwide, perpetual license to use the final deliverables for the intended Project purpose. Designer may retain copies for its records and portfolio, subject to confidentiality obligations.

Warranties, Limitations of Liability

Designer warrants that the services will be performed in a professional manner consistent with prevailing industry standards. EXCEPT AS EXPRESSLY SET FORTH HEREIN, SERVICES ARE PROVIDED "AS IS" AND DESIGNER DISCLAIMS ALL OTHER WARRANTIES, EXPRESS OR IMPLIED. IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR INDIRECT, CONSEQUENTIAL, SPECIAL OR PUNITIVE DAMAGES. THE AGGREGATE LIABILITY OF EITHER PARTY UNDER THIS STEP SHALL NOT EXCEED THE FEES PAID BY CLIENT FOR THE SPECIFIC STEP GIVING RISE TO THE CLAIM.

Governing Law; Dispute Resolution

This Design Step shall be governed by and construed in accordance with the laws of State: without regard to its conflict of laws principles. Parties agree to negotiate in good faith to resolve disputes; if unresolved, disputes shall be submitted to the exclusive jurisdiction of the courts located in the specified state.

Entire Agreement

This Design Step Template, together with all executed change orders and attachments, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous agreements, proposals, negotiations and communications, whether written or oral. Any amendment must be in writing and signed by both parties.

Notices

Notices under this Design Step shall be in writing and delivered to the addresses below (or to such other address as a party may specify in writing) and shall be deemed given upon receipt.

Client Name:

By:

Date:

Designer Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Design Step Template Is and When It Applies

A Design Step Template is a structured document that records the sequence, responsibilities, deliverables, and acceptance criteria for discrete phases of a design or development workflow. It standardizes how teams capture who does what, when key deliverables are due, and how outputs are approved. Used for handoffs, client reviews, and internal approvals, the template supports clear expectations and creates an auditable record that can be executed electronically when parties indicate intent to sign under the ESIGN Act (15 U.S.C. ch. 96) or applicable state UETA rules.

Why a Consistent Design Step Template Matters

A consistent template reduces ambiguity, speeds approvals, and lowers rework by recording scope, milestones, signatory authority, and acceptance criteria. When signed electronically with preserved audit data it also creates admissible proof of agreement under ESIGN/UETA, improving project governance and dispute prevention.

Why a Consistent Design Step Template Matters

Who Typically Prepares and Signs This Template

The Design Step Template is commonly prepared by project leads and used by cross-functional teams to coordinate deliverables and approvals.

  • Project managers and program leads who coordinate tasks across teams and suppliers.
  • Designers and developers who submit deliverables and confirm completion against acceptance criteria.
  • Client representatives or product owners who review, request changes, and sign approvals.

Use by these roles ensures responsibilities and signatory authority are captured before work proceeds and payments or milestones are released.

Core Elements to Include for a Professional Template

A robust Design Step Template bundles several structural elements so each phase is actionable, measurable, and auditable.

Scope Summary

Concise statement of what the step delivers, including functional boundaries and exclusions so stakeholders share the same expectations and avoid scope creep.

Deliverables

Specific artifacts to be produced (files, prototypes, specs) with formats and naming conventions identified to prevent ambiguity at handoff.

Acceptance Criteria

Measurable pass/fail conditions or checklist items the reviewer uses to confirm whether the deliverable meets requirements and can be approved.

Responsibilities

Named parties with clear roles (author, reviewer, approver) and contact details so accountability is unambiguous during execution.

Schedule

Target dates and allowable review windows mapped to milestones so delays and dependencies are visible to project stakeholders.

Change Control

A short process for amendments, versioning, and re-approval to manage scope changes without losing auditability.

Step-by-Step: Completing a Design Step Template

Follow these sequential actions to prepare, review, and execute a design step with clarity and traceability.

  • 01
    Draft: Populate scope, deliverables, and dates.
  • 02
    Assign: Name responsible parties and reviewers.
  • 03
    Review: Circulate for comments and update acceptance criteria.
  • 04
    Approve: Obtain signatures and record the audit trail.

How Electronic Completion and Routing Typically Flow

Electronic execution follows a repeatable workflow that preserves signer intent and creates an audit record for each action.

  • Upload: Sender uploads the template file to the signing platform.
  • Place Fields: Add signature, date, and checkbox fields where required.
  • Invite Signers: Enter signer emails or generate a secure signing link.
  • Store: Signed copies and audit trail are saved for retention.

Configuring a Digital Workflow for This Template

Key settings reduce friction and ensure each signed template is secure, auditable, and routed correctly.

Field Configuration
Authentication Email link | SMS code optional for higher assurance
Routing Sequential or parallel signer order as required
Notifications Email reminders on assignment and expiration
Retention Archive signed PDF and audit log per policy

Technical Considerations for Digital Completion

Confirm file format, integrations, and authentication before sending the template for signatures.

  • Integrations: Salesforce, NetSuite, Microsoft 365 supported
  • File Formats: PDF, DOCX, and HTML accepted
  • Authentication: Email, SMS, or advanced ID checks

Align platform settings with your security and retention policies; enable audit logging and export formats to preserve evidence.

Common Timing Points to Track in the Template

Include explicit dates for each milestone and calculate review windows to avoid schedule drift and disputes.

Draft Completion Date:

When the deliverable is first submitted for review.

Internal Review Window:

Number of business days allocated for internal checks.

Client Review Deadline:

Final date client must respond or approve.

Revision Turnaround:

Time allowed for required fixes and second submission.

Final Approval Date:

Date when formal acceptance is recorded.

Key Project Milestones in Sequence

Map these numbered milestones in the template so stakeholders see dependencies and approval gates at a glance.

01

1. Initial Draft

Creation and internal QC of the deliverable.

02

2. Internal Sign-off

Team lead approves readiness for client review.

03

3. Client Review

Client inspects deliverable against acceptance criteria.

04

4. Final Approval

Authorized representative signs and closes the step.

Frequent Preparation Errors to Avoid

  • Unclear acceptance criteria leading to repeated revisions and missed milestones.
  • Missing or inconsistent party names that delay sign-off and create payment disputes.
  • Incorrect dates or ambiguous time windows that cause scheduling conflicts.
  • Failure to identify an authorized signer, risking invalid or unenforceable approvals.

Consequences of Incomplete or Incorrect Templates

Contract Delay: Extended project timelines
Payment Hold: Milestone payments may be deferred
Dispute Exposure: Greater risk of claims or arbitration
Administrative Costs: Higher review and rework expense
Signature Invalidity: Noncompliant signing can affect enforceability
Regulatory Risk: Industry rules may impose retention obligations

Supporting Documents, Exports, and Version Controls to Use

Pair templates with a small set of companion documents and export settings to maintain continuity and evidentiary value.

Supporting Docs

Attach specifications, mockups, or acceptance checklists as numbered exhibits to avoid ambiguity about deliverable scope.

Export Formats

Save final signed records as PDF/A with embedded audit trail for long-term preservation and reproducibility.

Versioning

Track edits with sequential version numbers and a brief summary of changes for auditability.

Audit Trail

Keep timestamped logs showing signer actions, IP, and authentication method for evidentiary support.

Real-World Examples of Templates in Use

These short examples show how organizations applied templates to accelerate approvals and preserve compliance.

Optica Ventures LLC

Company standardized step templates to reduce handoff confusion.

  • COO oversight streamlined approvals.
  • "The interface is simple and easy-to-use for our team; more importantly, it is just as easy for our customers."

Martin Properties

A small real estate firm formalized deliverables and signatory roles.

  • Templates captured inspection and disclosure dates.
  • "I can process and execute all of these documents online with 100% compliance and built-in security. Whether on mobile or working offline, I can get forms back to their necessary parties efficiently."

Typical Signatory Roles and Authority

Project Manager

Project managers prepare the template, coordinate reviewers, and act as the primary contact for questions; they ensure dates, deliverables, and responsibilities are accurate and that approvals are collected in the required order.

Client Representative

The client representative reviews deliverables against acceptance criteria and, if authorized, signs approvals that trigger milestone payments or project transitions; ensure their signing authority is documented in contract terms.

Security and Compliance Features to Preserve Legal Weight

Encryption: TLS 1.2/1.3 in transit
Data at Rest: AES-256 encrypted storage
Certifications: SOC 2 Type II and ISO 27001
HIPAA Support: BAA available where required
Audit Trails: Timestamped action logs retained
Accessibility: WCAG 2.0 Level AA compliance

Select eSignature Vendor Pricing and Capability Snapshot

Compare core pricing and common capability differences for eSignature platforms relevant when choosing how to execute templates electronically.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies Varies Varies Varies
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year Varies Varies Varies

Frequently Asked Questions about Using the Design Step Template

Answers to common issues encountered when preparing, signing, or storing a Design Step Template.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.