Electrical Cabling Agreement

ELECTRICAL CABLING AGREEMENT

This Electrical Cabling Agreement (the "Agreement") is made and entered into as of Month: Day: Year: by and between Client Name: and Contractor Name: .

RECITALS

WHEREAS, Client requires professional installation, testing, and certification of electrical low-voltage cabling systems (including but not limited to fiber optic, category copper cabling, terminations and labeling) at the Client premises for data, voice, and related services; and

WHEREAS, Contractor represents that it is duly licensed, experienced and qualified to perform the cabling work in accordance with industry standards, applicable codes, and manufacturer recommendations; and

WHEREAS, the parties desire to set forth in writing the scope, payment terms, schedule, and other terms and conditions governing the cabling work to be performed.

PARTIES AND CONTACT INFORMATION

SCOPE OF WORK

Contractor shall furnish all labor, materials, equipment, testing, labeling, and certifications necessary to complete the electrical and low-voltage cabling work described below in a workmanlike manner and in compliance with applicable codes and industry standards. Contractor shall obtain any required permits, coordinate inspections with authorities having jurisdiction, and ensure that all installations meet manufacturer specifications.

PAYMENT TERMS

Contract Price (total): $. Client shall pay Contractor in accordance with the schedule below. All invoices are due within days of invoice receipt unless otherwise agreed in writing.

Retainage: of each progress payment may be withheld by Client until final acceptance. Final payment shall be due upon substantial completion and acceptance following final inspection and delivery of test documentation.

Late Fee: Overdue amounts shall bear interest at or the maximum permitted by law, whichever is less. Client shall be responsible for reasonable collection costs and attorney fees incurred by Contractor to collect delinquent amounts.

CHANGES / CHANGE ORDERS

Any changes to the Scope of Work shall be documented in a written change order signed by both parties, specifying adjustments to price, schedule, and any other affected terms. Contractor is not required to proceed with change order work until pricing and schedule are agreed in writing.

TERM AND TERMINATION

Term: The work shall commence on Start Date: Month Day Year and shall be substantially completed by Completion Date: Month Day Year , subject to adjustments for approved change orders and excusable delays.

Termination: Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure the breach within days after written notice. Client may terminate for convenience upon written notice; in such event Contractor shall be paid for work performed, materials procured, and reasonable demobilization costs.

WARRANTY

Contractor warrants that all cabling and associated workmanship furnished under this Agreement shall be free from defects for a period of months from the date of final acceptance. This warranty is limited to repair or replacement of defective components or workmanship at Contractor's option and does not cover damage due to abuse, alterations, or events outside Contractor's control.

CONFIDENTIALITY

Each party agrees to hold in confidence and not disclose to any third party any non-public technical, business, or financial information provided by the other party in connection with this Agreement. Confidential information shall not include information that is or becomes publicly available through no fault of the receiving party, or which is independently developed without use of the disclosing party's confidential information. The obligations of confidentiality shall survive termination for a period of years.

INSURANCE, INDEMNITY AND SAFETY

Contractor shall maintain commercial general liability and, where applicable, workers' compensation insurance in amounts customary for this trade and shall provide certificates of insurance upon request. Contractor shall indemnify and hold Client harmless from and against claims, liabilities, losses and expenses arising from Contractor's negligence or willful misconduct in performing the Work. Contractor shall comply with all safety laws, codes and site rules while on Client premises.

GOVERNING LAW

This Agreement shall be governed by and construed in accordance with the laws of the State of without regard to its conflict of law principles. Any dispute arising under this Agreement shall be resolved by the courts located in that State, unless the parties agree in writing to arbitration.

ENTIRE AGREEMENT

This Agreement, including any attachments and signed change orders, constitutes the entire agreement between the parties concerning the subject matter hereof, and supersedes all prior negotiations, representations, or agreements, whether written or oral. Any amendment to this Agreement must be in writing and signed by both parties.

MISCELLANEOUS

If any provision of this Agreement is found to be invalid or unenforceable, the remainder of the Agreement shall remain in full force and effect. Neither party may assign this Agreement without the prior written consent of the other, except that Contractor may assign to a successor entity in the event of merger or sale of substantially all assets related to the Work.

Sign Now