Entry Door Installation Contract

ENTRY DOOR INSTALLATION CONTRACT

Parties

Contractor Name:

Client Name:

Recitals

WHEREAS, Contractor is a licensed installer of entry doors and related hardware and performs installation, modification, and finishing services for residential and commercial properties; and

WHEREAS, Client desires to engage Contractor to furnish labor, materials, and services necessary to remove the existing entry door and install a new entry door at the job location set forth below in accordance with the terms and conditions of this Agreement; and

WHEREAS, the parties intend that Contractor be paid for such services and that responsibilities for permits, access, and completion be allocated as provided herein.

Job Location

Scope of Work

Contractor shall furnish all labor, materials, equipment, and supervision necessary to complete installation of the entry door as described below and in any attachments incorporated by reference. The Scope of Work includes removal and disposal of the existing door, preparation of the opening, installation of the new door, installation of specified hardware, sealing and finishing as required, and a final inspection by both parties.

Materials, Permits, and Warranties

Contractor will supply the materials specified in the Scope of Work. Materials provided by Contractor are warranted to be free from defects in workmanship for the warranty period set forth below, subject to manufacturer's warranty for products. Contractor's warranty expressly excludes defects caused by improper site conditions, vandalism, acts of third parties, misuse, normal wear and tear, or modifications not performed by Contractor.

Contractor obtains permits:    Client obtains permits:

Payment Terms

The total contract price for the Scope of Work is: $

Final payment is due upon substantial completion and acceptance by Client, subject to any agreed retainage. Payments not received within days of the invoice due date will incur a late fee of on the unpaid balance, to be charged monthly until paid in full.

Change Orders

Any changes or additions to the Scope of Work shall be made only by written change order signed by both parties. Change orders shall state the change in work, price adjustment, and any schedule impact. Contractor shall not be required to perform changed work without an executed change order.

Term and Termination

Work under this Agreement shall commence on or about and Contractor shall achieve substantial completion by , subject to adjustments for change orders, delays beyond Contractor's control, or force majeure events.

Either party may terminate this Agreement for material breach if the breaching party fails to cure such breach within days after receiving written notice. In the event of termination, Contractor shall be paid for work performed, materials purchased, and reasonable demobilization costs to date of termination.

Confidentiality

Each party shall maintain the confidentiality of the other party's non-public information obtained in connection with this Agreement. Confidential information does not include information that (a) is or becomes generally known to the public other than by a breach of this Agreement, (b) was already known to the receiving party, or (c) is lawfully obtained from a third party not under an obligation of confidentiality. The obligations of this Section survive termination of this Agreement for a period of two (2) years.

Insurance, Indemnity, and Risk Allocation

Contractor shall maintain commercial general liability insurance and workers' compensation as required by law. Contractor shall indemnify and hold harmless Client from claims, losses, or liabilities arising from Contractor's performance of work, except to the extent caused by Client's negligence or willful misconduct. Client shall maintain adequate property insurance for the premises. Contractor's required insurance limits:

Acceptance, Cleanup, and Completion

Upon substantial completion, Contractor will notify Client and perform a joint inspection. Client shall have three (3) business days to provide written notice of any nonconforming work. Contractor shall correct nonconforming work within a reasonable time. Contractor will remove construction debris from the job site daily and leave the site in broom-clean condition upon completion.

Lien Waiver and Remedies

Upon receipt of payment, Contractor shall provide unconditional lien waivers for the portion of work paid. Failure to pay amounts due constitutes a material breach entitling Contractor to suspend work, recover payment for work performed, and pursue all available legal remedies including mechanic's liens and collection of costs and attorneys' fees as provided by law.

Governing Law and Dispute Resolution

This Agreement shall be governed by the laws of the state of without regard to conflict of law principles. The parties shall first attempt to resolve disputes through good faith negotiation. If unresolved, disputes shall be resolved by binding arbitration administered in the county where the job is located, and judgment on the award may be entered in any court of competent jurisdiction.

Force Majeure

Neither party shall be liable for delays or failures in performance due to causes beyond its reasonable control, including acts of God, strikes, shortages, governmental orders, utilities outages, or severe weather. Time for performance shall be extended for the duration of such force majeure event.

Entire Agreement

This Agreement, together with any attachments, exhibits, and executed change orders, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, representations, and agreements, whether written or oral. No amendment shall be effective unless in writing and signed by both parties.

Acknowledgment

By signing below, the parties acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Entry Door Installation Contract.

Sign Now