Establishing secure connection…Loading editor…Preparing document…

EPC Contract Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

EPC CONTRACT AGREEMENT

This Engineering, Procurement and Construction Agreement (the "Agreement") is made as of between Owner: , organized under the laws of , with principal place of business at (the "Owner"), and Contractor: , organized under the laws of , with principal place of business at (the "Contractor").

RECITALS

WHEREAS, Owner intends to develop and have constructed the project described as (the "Project"); and

WHEREAS, Contractor represents that it possesses the necessary experience, personnel and financial resources to perform engineering, procurement and construction services required for the Project in accordance with the Contract Documents; and

WHEREAS, Owner desires to engage Contractor, and Contractor agrees to perform the Work subject to the terms and conditions set forth in this Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein, the Parties agree as follows:

1. DEFINITIONS

1.1 "Contract Documents" means this Agreement, the Schedules, the Specifications, Drawings and any amendments and Change Orders executed in accordance with this Agreement.

1.2 "Work" means all engineering, procurement, construction, testing, commissioning and related services required to deliver the Project to the performance criteria set out in the Contract Documents.

2. SCOPE OF WORK

2.1 Contractor shall undertake and complete the Work described in the Contract Documents in a professional and workmanlike manner in accordance with prevailing industry standards, applicable codes and all permits and approvals required by law.

3. CONTRACT PRICE AND PAYMENT

3.1 The Contract Price for full performance of the Work shall be payable in accordance with the payment schedule set forth below.

4. TIME FOR COMPLETION

4.1 Contractor shall achieve Substantial Completion of the Work by subject to extensions permitted under this Agreement.

5. PERFORMANCE SECURITY

5.1 Contractor shall, within the time specified in the Contract Documents, furnish to Owner a performance security in the form and amount set forth below to secure Contractor's performance of its obligations.

6. TESTING, COMMISSIONING AND HANDOVER

6.1 Contractor shall perform all tests, inspections and commissioning activities required to demonstrate that the Work meets the performance and acceptance criteria set forth in the Contract Documents. Final handover shall occur upon successful completion of punch list items and issuance of final completion certificate by Owner.

7. DEFECTS LIABILITY AND WARRANTIES

7.1 Contractor warrants that the Work shall be free from defects in design, materials and workmanship for a period of years from the date of Final Completion. Contractor shall remedy, at its own cost, any defects arising within the warranty period.

8. CHANGES AND VARIATIONS

8.1 No change to the Work shall be binding unless evidenced by a written Change Order signed by authorized representatives of Owner and Contractor. Change Orders shall set out any adjustments to the Contract Price and/or Time for Completion and the basis for such adjustments.

9. LIQUIDATED DAMAGES

9.1 If Contractor fails to achieve Substantial Completion by the date specified, Owner shall be entitled to liquidated damages at the rate of per day, subject to any applicable notice and cure provisions.

10. INDEMNITY AND LIMITATION OF LIABILITY

10.1 Contractor shall indemnify, defend and hold harmless Owner, its affiliates and their respective officers, directors and employees from and against all losses, liabilities, damages and claims arising out of or resulting from Contractor's negligent acts or willful misconduct in the performance of the Work, except to the extent caused by Owner's negligence or willful misconduct.

10.2 Neither party's liability for indirect, incidental or consequential damages shall exceed the extent permitted by applicable law; provided, however, that this limitation shall not apply to liability arising from gross negligence, willful misconduct or Contractor's obligations under Section 10.1.

11. INSURANCE

11.1 Contractor shall procure and maintain, at its own expense, insurance coverages customary for EPC contracts of comparable scope and value, including commercial general liability, employer's liability, professional liability (as applicable), and all-risk contractors' all-risk insurance covering the Work.

12. FORCE MAJEURE

12.1 Neither party shall be liable for delay or failure to perform where such delay or failure is caused by an event beyond the reasonable control of the affected party, including acts of God, war, strike, government action, epidemic or other events of force majeure. The affected party shall promptly notify the other party of the occurrence and expected duration of such event and shall use reasonable efforts to mitigate its effects.

13. SUSPENSION AND TERMINATION

13.1 Owner may suspend the Work by written notice to Contractor. If suspension persists beyond a reasonable period, Contractor may seek an equitable adjustment to time and price. Either party may terminate this Agreement for material breach if the breaching party fails to cure within the cure period specified in the Contract Documents.

14. DISPUTE RESOLUTION

14.1 Parties shall first seek to resolve disputes through good faith negotiations between senior representatives. If unresolved within thirty (30) days, disputes shall be finally resolved by binding arbitration administered in accordance with the arbitration rules agreed by the parties and conducted by a tribunal of competent arbitrators. The arbitrator's award shall be final and binding and may be entered in any court of competent jurisdiction for enforcement.

15. NOTICES

15.1 All notices, requests, consents and other communications required or permitted under this Agreement shall be in writing and shall be delivered to the addresses set forth below (or to such other address as either party designates by notice):

16. GOVERNING LAW

16.1 This Agreement shall be governed by and construed in accordance with the laws of , without regard to conflict of laws principles.

17. ENTIRE AGREEMENT

17.1 This Agreement, together with the Contract Documents, constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes all prior negotiations, representations and agreements, whether written or oral.

18. AMENDMENTS AND WAIVER

18.1 No amendment or waiver of any provision of this Agreement shall be effective unless made in writing and signed by authorized representatives of both Parties. No failure or delay by either Party in exercising any right shall operate as a waiver of that right.

19. SEVERABILITY

19.1 If any provision of this Agreement is held to be invalid or unenforceable, such provision shall be severed and the remaining provisions shall remain in full force and effect.

20. COUNTERPARTS

20.1 This Agreement may be executed in two or more counterparts, each of which shall be deemed an original and all of which together shall constitute one and the same instrument.

21. MISCELLANEOUS

21.1 The headings in this Agreement are for convenience only and shall not affect interpretation. The Parties shall cooperate in good faith to implement the provisions of this Agreement.

Owner:

By:

Date:

Contractor:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What an EPC Contract Agreement Covers

An EPC Contract Agreement (Engineering, Procurement, and Construction) is a single, integrated contract used on large infrastructure and industrial projects that assigns design, procurement, construction, and commissioning responsibilities to one contractor. The EPC contractor accepts technical delivery obligations, schedules, performance guarantees, and a turnkey handover at completion. The agreement typically allocates risks such as cost overruns, schedule delays, warranty obligations, and testing requirements, and includes payment terms, change order procedures, performance securities, and dispute resolution provisions tailored to capital-intensive projects.

Why a Clear EPC Agreement Matters

A well-drafted EPC Contract Agreement centralizes responsibility, reduces interface risk between multiple vendors, and sets clear standards for performance, testing, and acceptance. It clarifies allocation of cost and schedule risk, identifies remedies for failures, and establishes mechanisms for change orders, liquidated damages, and final handover obligations.

Why a Clear EPC Agreement Matters

Who Typically Prepares and Signs EPC Agreements

Final signatures usually include authorized corporate officers or representatives with authority to bind each contracting party.

  • Project owners and sponsors who define scope, performance criteria, and payment milestones.
  • EPC contractors and subcontractors responsible for design, procurement, construction, and commissioning obligations.
  • Legal, procurement, and finance teams that negotiate risk allocation, securities, insurance, and payment terms.

Who Signs and Why

Owner Representative

A corporate officer or delegated signatory who confirms funding, scope acceptance, and commercial onboarding; signs to commit the owner to payment and acceptance clauses.

EPC Contractor

An authorized executive or project manager who accepts responsibility for design, procurement, construction, testing, commissioning, warranties, and performance guarantees under the contract.

Core Sections to Include in an EPC Contract Agreement

A professional EPC agreement contains specific sections that allocate risk, set technical standards, define payment flow, and create acceptance tests to govern project delivery and closure.

Scope of Work

Precise description of deliverables, drawings, technical specifications, milestones, and interfaces with third-party systems to avoid ambiguity during execution.

Price and Payment

Contract price, payment schedule, retention, conditions for payment, and procedures for invoice approval and disputed amounts.

Schedule and Milestones

Key dates, critical path obligations, liquidated damages for delays, acceleration rights, and extensions for excusable delays.

Performance Guarantees

Testing, commissioning criteria, acceptance tests, warranty period, remedy obligations, and remedies for failed performance metrics.

Change Management

Change order procedures, pricing protocols for extras and omissions, time impacts, and approval authority for scope variations.

Risk Allocation

Insurance, indemnities, force majeure, performance bonds, dispute resolution, termination rights, and limitations of liability.

Essential Data Fields to Capture

Party Names: Full legal entity names
Contract Price: Contracted sum and currency
Effective Date: MM/DD/YYYY format
Scope Reference: Attachment and exhibit IDs
Signatory Info: Name, title, authority
Performance Bonds: Bond amounts and expiry

Step-by-Step: Completing an EPC Contract Agreement

Follow a defined sequence to avoid missing approvals, technical attachments, or commercial terms that affect cost or schedule.

  • 01
    Assemble team: Bring legal, technical, procurement, and finance stakeholders together.
  • 02
    Confirm scope: Lock technical specs and deliverable list before pricing.
  • 03
    Negotiate terms: Agree on liquidated damages, warranties, and bonds.
  • 04
    Execute signature: Authorized signatories sign, date, and circulate executed copies.

How to Configure an Online EPC Signature Workflow

Set up routing, authentication, and visibility rules so each party receives required fields in the correct order.

Field Configuration
Signer Order Sequential or parallel signing
Authentication Email, SMS code, or MFA
Conditional Fields Show fields based on prior answers
Document Version Lock after first signature

Digital Signing and Integration Considerations

Ensure the provider supports your retention policy, audit exports, and any industry compliance such as HIPAA or 21 CFR Part 11 when applicable.

  • File Formats: PDF, DOCX supported
  • Integrations: CRM and ERP connectors
  • Authentication: SMS, email, or KBA

Typical Electronic Signing Flow for an EPC Agreement

A clear eSigning flow reduces execution time and creates an auditable record of intent, attribution, and consent.

  • Upload document: Prepare final PDF with exhibits attached.
  • Place fields: Insert signature, date, and initial blocks.
  • Add signers: Enter signer names and contact emails.
  • Send for signature: Track completion and collect certificate.

Key Timing and Deadline Considerations

EPC agreements are deadline-sensitive; calendar acceptance, payment milestones, and warranty notice periods carefully.

Bid and Award Deadline:

Bid submission and award dates set commercial start.

Mobilization Date:

Date when contractor must begin on-site activities.

Milestone Payments:

Due dates linked to progress milestones and inspections.

Final Acceptance:

Date of commissioning acceptance and release of retention.

Warranty Start:

Warranty begins on formal acceptance or handover.

Project Milestones from Contract to Handover

Track major phases in a milestone sequence to manage deliverables, inspections, and payment triggers.

01

Contract Award

Formal execution and issuance of mobilization notice to contractor.

02

Mobilization

Site setup, procurement kickoff, and initial mobilization activities begin.

03

Construction

Main works, inspections, and quality assurance procedures occur on schedule.

04

Commissioning

Performance testing, acceptance, and final handover to owner.

Practical Tips to Reduce Execution Risk

Use contractual clarity, consistent exhibits, and reliable execution workflows to reduce disputes and administrative friction.

Lock technical exhibits
Reference exhibit revision numbers and freeze drawings before signing to prevent later scope disputes and remove ambiguity about deliverables and acceptance criteria.
Define acceptance tests
Include commissioning protocols and objective pass/fail criteria; tie milestone payments and release of retention to successful completion of those tests.
Use performance securities
Require performance bonds and parent guarantees when appropriate, and specify procedures for calling bonds in case of material breach.
Maintain audit trail
Preserve execution records—timestamps, IP, signer authentication, and version history—to support enforceability and dispute resolution.

Real-World EPC Contract Scenarios

Examples highlight how integrated EPC agreements reduce handover friction and clarify liability across large projects.

Onshore Plant Delivery

Owner selects single EPC contractor to deliver turnkey plant

  • Single point of responsibility reduces interface risk
  • Final acceptance tied to performance tests and warranty obligations to ensure operational readiness.

Utility Substation Project

Contractor provides design, equipment procurement, and construction in one agreement

  • Change orders are priced per unit rates
  • Project closeout requires commissioning certificates and third-party inspection sign-off.

Common Penalties and Contract Risks

Liquidated Damages: Monetary deductions for delays
Performance Failure: Remedies include repair or re-performance
Bond Forfeiture: Loss of performance bond funds
Lien Claims: Subcontractor liens can affect title
Tax Withholding: Misclassified payments trigger penalties
Dispute Costs: Arbitration or litigation expense

Frequent Mistakes When Preparing EPC Agreements

  • Vague scope language that leaves key deliverables undefined and creates basis for scope claims and disputes.
  • Missing or inconsistent exhibit references that result in different parties relying on conflicting technical documents.
  • Unclear change-order procedures that allow contractors to assert wide interpretations of extras and time impacts.
  • Improper signatory authority where the signer lacks corporate authorization, risking contract unenforceability or later repudiation.

eSignature Vendor Comparison for EPC Contract Execution

Compare common eSignature capabilities and pricing models for digital execution of EPC agreements; signNow appears first by design as the platform column.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day trial Trial available Trial available Trial available Trial available
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes (BAA) Yes (BAA) Yes (BAA) Varies by plan Varies by plan
Envelope Cap No cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Frequently Asked Questions About the EPC Contract Agreement

Practical answers to common execution, enforceability, and digital signing questions for EPC contracts.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.