Home Improvement Half Bath Template

HOME IMPROVEMENT HALF BATH AGREEMENT

Parties and Recitals

This Agreement is made effective as of the date of last signature below by and between:

Client Name:

Client Address:

Contractor Name:

Contractor Address:

Project Address:

WHEREAS, Client desires to engage Contractor to perform remodeling and installation work to create or renovate a half bathroom at the Project Address; and

WHEREAS, Contractor holds the necessary licenses, skills, and experience to perform the services described in this Agreement and agrees to perform such services in accordance with the terms set forth below; and

NOW, THEREFORE, in consideration of the mutual covenants herein contained, the parties agree as follows:

Scope of Work

The Scope of Work includes, but is not limited to: demolition (as needed), framing adjustments, plumbing fixtures and rough-in for lavatory and toilet, cabinetry or vanity installation, tile or floor surface installation, electrical work necessary for lighting and ventilation, finish carpentry, painting, and final cleaning. Any work beyond this description shall require a written Change Order signed by both parties.

Materials, Subcontractors and Permits

Materials Provided By: Contractor Client

Subcontracting: Contractor may engage subcontractors to perform portions of the work. Contractor shall remain responsible for the acts and omissions of subcontractors as for its own acts. Contractor shall ensure subcontractors carry insurance consistent with the insurance provisions below.

Permits and Inspections: Contractor to obtain all required permits and schedule inspections Client to obtain permits (if selected, list permits required below)

Payment Terms

Unless otherwise stated, payments are due within 15 days of invoice. Contractor may suspend work for nonpayment after seven (7) days' written notice. Client is responsible for any costs to collect overdue amounts, including reasonable attorney fees and collection expenses.

Term and Termination

Estimated Start Date:     Estimated Completion Date:

Either party may terminate this Agreement for cause upon written notice if the other party materially breaches any obligation and fails to cure within the notice period specified above. Upon termination, Contractor shall be paid for work performed and materials purchased up to the effective date of termination, less any amounts reasonably incurred by Client to complete outstanding work.

Change Orders

No changes to the Scope of Work or Contract Price shall be effective unless reduced to a written Change Order signed by both parties. Change Orders shall specify any increase or decrease in price and any adjustment to the schedule.

Warranties

Contractor warrants that work performed under this Agreement will be free from defects in workmanship for the period specified above, excluding damage or failure resulting from normal wear and tear, misuse, or modifications not performed or authorized by Contractor.

Insurance and Indemnity

Contractor shall maintain, at its expense, commercial general liability insurance and workers' compensation as required by law. Contractor agrees to indemnify and hold harmless Client from liabilities arising out of Contractor's negligence, willful misconduct, or breach of this Agreement, except to the extent caused by Client's negligence.

Completion and Acceptance

Final payment shall be due upon substantial completion and Client's written acceptance, provided Contractor has completed the work in accordance with this Agreement and all applicable inspections have been passed.

Confidentiality

Each party agrees that confidential information disclosed in connection with this Agreement shall not be disclosed to third parties and shall be used solely for performance of this Agreement. Confidential information does not include information that is or becomes publicly known through no breach of this Agreement, or is rightfully received from a third party without restriction. Confidentiality obligations shall survive termination of this Agreement for a period of two (2) years.

Governing Law; Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the state where the Project Address is located. The parties shall attempt in good faith to resolve disputes through negotiation. If unresolved within thirty (30) days, either party may pursue litigation in the courts of the governing jurisdiction.

Entire Agreement

This Agreement, together with any attached Change Orders and exhibits signed by the parties, constitutes the entire agreement between Client and Contractor with respect to the Project and supersedes all prior agreements and understandings, whether written or oral. Any amendment must be in writing and signed by both parties.

Miscellaneous Provisions

Force Majeure: Neither party shall be liable for delays or failures in performance due to causes beyond its reasonable control, including acts of God, strikes, shortages, or governmental actions. The time for performance shall be extended for the period of such delay.

Sign Now