Can the agreement be signed electronically?

Yes. Electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. §7001) and state UETA laws when intent, consent, attribution, and retention are documented.

Who must obtain building permits?

The contract should state whether the homeowner or contractor is responsible. Many jurisdictions require the permit holder to be a licensed contractor; verify local building department rules.

Are notarization or witnesses required?

Most remodel agreements do not require notarization, but certain documents (deeds, affidavits, POAs) do. Follow state-specific rules and note any witness requirements in the contract.

How are change orders handled?

Change orders should be written, list added cost or credit, revised schedule, and signed by both parties before the changed work begins to avoid disputes.

What records should I keep after completion?

Retain the signed contract, permits, inspection approvals, warranties, receipts, and final payment proof for at least the applicable retention period and for warranty enforcement.

What if a subcontractor isn’t paid?

Unpaid subcontractors may file a mechanic’s lien. Use clear payment flow language and require lien waivers from paid subcontractors to reduce lien risk.

Electronic Signature
Templates
Miscellaneous
Home Improvement Kitchen Remodel

Home Improvement Kitchen Remodel

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

HOME IMPROVEMENT KITCHEN REMODEL AGREEMENT

Parties

Client Name Client Address Contractor Name Contractor Address Contractor License Number Project Address

Recitals

WHEREAS, Client Name: desires to engage Contractor to perform remodeling services at the Project Address described above; and

WHEREAS, Contractor Name: represents that it is duly licensed, insured and qualified to perform the work described herein; and

NOW, THEREFORE, in consideration of the mutual covenants contained in this Agreement, the parties agree as follows:

Scope of Work

Contractor shall provide labor, materials, equipment and supervision necessary to perform a kitchen remodel at the Project Address. The Work includes, but is not limited to, demolition, cabinetry, countertops, plumbing fixture replacement, electrical modifications as required for installed appliances, flooring, painting and cleanup in accordance with accepted plans and specifications.

Detailed Scope (list inclusions and exclusions)

Payment Terms

Total Contract Price: $

Deposit (Due upon execution): $. Remaining balance payable according to the payment schedule below.

Payment Schedule and Milestones

Late Payment: Any undisputed past-due amount shall accrue interest at (or the maximum lawful rate if less). In addition, Contractor may suspend work if payment is more than days overdue after written notice.

Change Orders

All changes to the Scope of Work shall be made only by written change order signed by both parties. Change orders shall state the change in Work, any increase or decrease in Contract Price, and any change to the Project Schedule.

Change Order Authorization Required? Yes, written authorization required before additional work begins Change Order Procedure (describe approval process)

Term and Termination

This Agreement commences on Start Date: and, unless earlier terminated in accordance with this Agreement, shall terminate on End Date: .

Either party may terminate this Agreement for material breach if the breaching party fails to cure such breach within days after written notice. Either party may also terminate for convenience upon days' prior written notice; in such event, Client shall pay Contractor for all Work performed and materials ordered through the effective date of termination plus reasonable demobilization costs.

Permits, Inspections, and Compliance

Contractor shall obtain and pay for all permits, licenses and inspections required by applicable law unless otherwise agreed in writing. Contractor will perform the Work in compliance with applicable building codes, ordinances and permit conditions. Client is responsible for disclosing any known property conditions that may affect performance of the Work.

Confidentiality

Each party shall maintain in confidence all non-public information and documentation provided by the other party in connection with the Project and shall not disclose such information except to its employees, subcontractors or professional advisors who have a need to know and who are bound to confidentiality obligations consistent with this paragraph. Confidential information does not include information that is or becomes public through no fault of the receiving party, is rightfully received from a third party, or is independently developed.

Insurance and Indemnity

Contractor shall maintain general liability, workers' compensation and automobile insurance in amounts sufficient for the Project and shall provide certificates of insurance upon request. Contractor shall indemnify and hold Client harmless from liabilities arising from Contractor's negligent performance of the Work, except to the extent caused by Client's negligence or willful misconduct.

Warranties

Contractor warrants that labor performed under this Agreement shall be free from defects for a period of months from substantial completion. Manufacturer warranties for materials and appliances, if any, shall be passed through to Client.

Governing Law

This Agreement shall be governed by and construed in accordance with the laws of the State of , without regard to its choice of law rules. Venue for any dispute shall be the state or federal courts located in the county where the Project is located.

Entire Agreement

This Agreement, including any attached exhibits, drawings and signed change orders, constitutes the entire agreement between the parties regarding the subject matter hereof and supersedes all prior negotiations, representations and agreements, whether written or oral. No modification or waiver shall be effective unless in writing and signed by both parties.

Dispute Resolution

The parties shall attempt in good faith to resolve disputes arising out of this Agreement. If unresolved, disputes shall be resolved by binding arbitration administered in the county where the Project is located, pursuant to the rules of the selected arbitration body, and judgment on the award may be entered in any court of competent jurisdiction.

Miscellaneous

If any provision of this Agreement is held invalid or unenforceable, the remaining provisions shall remain in full force and effect. Neither party may assign this Agreement without the other party's prior written consent, except that Contractor may assign receivables to a financing institution.

Contractor Printed Name:

By:

Date:

Client Printed Name:

By:

Date:

What the Home Improvement Kitchen Remodel document covers

A Home Improvement Kitchen Remodel agreement documents the scope, schedule, materials, price, payment milestones, warranties, permit responsibilities, and dispute-resolution terms for a kitchen remodel project between a homeowner and contractor. It serves as the operative contract that allocates risk, lists deliverables (drawings, fixtures, finishes), identifies required permits and inspections, and establishes who is responsible for changes, delays, and final acceptance of work. Use this document to create a clear baseline for expectations, reduce misunderstandings during construction, and provide evidence of agreed terms if a dispute arises.

Why a clear remodel agreement matters and its legal standing

A written remodel agreement clarifies obligations, reduces disputes, and documents consent to terms and payment. When executed electronically it is enforceable under the federal ESIGN Act (15 U.S.C. §7001) and applicable state UETA statutes, provided intent, consent, attribution, and retention requirements are met.

Who typically prepares and signs this remodel agreement

The Home Improvement Kitchen Remodel agreement is used by multiple stakeholders before work begins.

Homeowners organizing a kitchen renovation who need a binding scope, price, and schedule.
Licensed general contractors and subcontractors who need written authorization, payment schedules, and change-order procedures.
Designers, suppliers, or lenders requiring documented acceptance of specifications, allowances, and payment terms.

Clear roles in the agreement help ensure permits, inspections, insurance, and payment flows are handled correctly throughout the project.

Typical signers and their responsibilities

Homeowner

A homeowner signs to accept scope, pricing, payment milestones, and warranty terms. The homeowner typically secures financing, approves selections and change orders, and is responsible for final acceptance and payment per the schedule.

General Contractor

A licensed general contractor signs to confirm scope, schedule, subcontracting, insurance coverage, and compliance with local permit and inspection requirements. The contractor is responsible for execution, coordination, and warranty of labor per contract terms.

Essential components of a professional remodel agreement

A complete remodel agreement groups terms so both parties can find obligations quickly. Include scope, payment, schedule, permits, warranties, and change-order rules to reduce ambiguity and support enforceability.

Scope of Work

Detailed description of demolition, cabinetry, countertops, plumbing, electrical, finishes, and any work excluded from the project.

Price and Payments

Total contract amount, deposit, progress payment schedule, retainage (if any), and accepted payment methods.

Schedule and Milestones

Start date, critical milestone dates (frames, rough-in, finishes), and procedures for delays and extensions.

Permits and Inspections

Which party pulls permits, pays fees, schedules inspections, and provides copies of approved permits.

Change Orders

Process for approving scope changes, price adjustments, change-order signatures, and revised schedules.

Warranties and Remedies

Manufacturer and contractor warranty periods, notice procedures for defects, and remedies for unresolved issues.

Step-by-step: how to prepare and execute the remodel agreement

Follow these steps to create, review, and sign a enforceable Home Improvement Kitchen Remodel agreement before any work begins.

01

Draft Scope: Describe work clearly and attach plans or specs.
02

Set Price & Schedule: Agree total cost, milestones, and completion date.
03

Assign Permits: Specify who obtains permits and pays fees.
04

Sign and Retain: Execute signatures and keep final signed copies.

How to customize the online workflow for this agreement

Configure fields, signer order, and authentication to match the project’s approval chain and compliance needs.

Field	Configuration
Signer Order	Owner first, then contractor, then lender (if any)
Required Fields	Make price, start date, and signature mandatory
Authentication	Use email + SMS or stronger KBA for high-value jobs
Attachments	Attach plans, permits, and manufacturer specs

Where to send or file the executed remodel agreement

Routing the signed contract and supporting documents to the right parties and authorities prevents delays and supports compliance.

Homeowner Copy: Provide a final signed PDF to the homeowner for records and financing.
Contractor Copy: Contractor keeps an executed copy for job scheduling and subcontractor coordination.
Lender / Escrow: If financing, send executed contract to lender or escrow as required.
Permit Office: Submit required signed documents when applying for building permits where local rules require contract documentation.

Digital signing and file-sharing requirements for remodel agreements

Choose signing and storage options that meet authentication, evidence, and integration needs for construction workflows.

Integrations: Connect to Procore, Google Workspace, or Microsoft 365 for job folder sync
Formats: Accept signed PDFs and DOCX; export certificates of completion
Authentication: Support email, SMS code, or SSO for signer verification

Ensure the platform you select preserves an audit trail (timestamps, IP, signer email) and stores final signed files in secure, tamper-evident form.

Common timelines and deadlines in remodel projects

Track permit, payment, inspection, and completion dates to avoid fines and disputes; link payments to milestones for clarity.

Permit Application:

Submit before construction begins; local lead times vary.

Deposit Due:

Typically due at contract signing to secure scheduling.

Progress Payments:

Due at defined milestones such as framing or finish installs.

Required Inspections:

Schedule rough-in and final inspections per local building department.

Final Completion:

Punch-list and final payment due upon owner acceptance.

Key project milestones from contract to closeout

A sequential view of major stages helps coordinate crews, inspections, and payments across the remodel lifecycle.

01

Contract Signing

Agreement executed and deposit collected; schedule is set.

02

Permitting and Approvals

Permits filed and approved before structural work.

03

Rough Work Complete

Framing, plumbing, and electrical rough inspections passed.

04

Finishes and Final Walk

Install finishes, complete punch list, and obtain final sign-off.

Common mistakes to avoid when preparing the remodel agreement

Vague scope descriptions that leave room for differing expectations.
Unclear payment triggers that lead to late payments or disputes.
Failing to specify who secures and pays for permits.
No change-order process, causing disputes over scope and cost.

Key risks and consequences of an incomplete or incorrect agreement

Permit Fines: Local fines and stop-work orders

Contract Disputes: Costly mediation or litigation

Mechanic's Lien: Subcontractors can file liens for unpaid work

Warranty Claims: Unclear warranty terms complicate repairs

Payment Delays: Cashflow interruptions for contractors

Insurance Gaps: Work without proper liability coverage

How to save final copies and which formats to use

Store executed agreements and supporting exhibits in standard formats that preserve integrity and support later retrieval for inspections, financing, or disputes.

Signed PDF

Export a PDF/A or signed PDF for a tamper-evident record with embedded audit trail metadata and certificate of completion.

Editable DOCX

Keep an editable DOCX master for amendments and tracked changes before finalization; convert to PDF for execution.

Cloud Storage

Save signed files to secure cloud storage (Google Drive, Box, or Procore) with access controls and versioning.

Project Folder

Organize permits, plans, invoices, and warranties together to simplify inspections and lender requests.

Comparison: eSignature solutions relevant to remodel agreements

Vendor pricing and feature availability differ; signNow appears first in the table for straightforward comparison of starting price, trial availability, bulk send, audit trail, HIPAA support, and envelope limits.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies by vendor	Varies by vendor	Varies by vendor	Varies by vendor
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No cap	100 envelopes/user/year	Varies by plan	Varies by plan	Varies by plan

FAQs and troubleshooting for the remodel agreement

Answers to frequent questions about signing, permits, revisions, and evidence to help avoid common execution problems.

Need help? Contact support

Can the agreement be signed electronically?
Yes. Electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. §7001) and state UETA laws when intent, consent, attribution, and retention are documented.
Who must obtain building permits?
The contract should state whether the homeowner or contractor is responsible. Many jurisdictions require the permit holder to be a licensed contractor; verify local building department rules.
Are notarization or witnesses required?
Most remodel agreements do not require notarization, but certain documents (deeds, affidavits, POAs) do. Follow state-specific rules and note any witness requirements in the contract.
How are change orders handled?
Change orders should be written, list added cost or credit, revised schedule, and signed by both parties before the changed work begins to avoid disputes.
What records should I keep after completion?
Retain the signed contract, permits, inspection approvals, warranties, receipts, and final payment proof for at least the applicable retention period and for warranty enforcement.
What if a subcontractor isn’t paid?
Unpaid subcontractors may file a mechanic’s lien. Use clear payment flow language and require lien waivers from paid subcontractors to reduce lien risk.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now