Can a remodeling contract be signed electronically?

Yes. Electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. ch. 96, 2000) and UETA where adopted, provided intent, consent, attribution, and record retention requirements are met.

Do I need a notary for the contract to be valid?

Most standard remodeling contracts do not require notarization to be valid between parties, but a notary may be required for related documents like mechanic's lien releases or when a lender requests notarized signatures.

How do I change the contract after signing?

Use a written change order signed by the parties that states the revised scope, cost, and schedule. Verbal agreements are risky and may not be enforceable without written confirmation.

Who can sign on behalf of a contractor or homeowner?

A person with authority—an owner, officer, or authorized agent—should sign. For businesses, include printed name and title. Verify authorization to avoid disputes over signature validity.

What records should I keep after project closeout?

Retain the signed contract, change orders, permits, inspection reports, lien waivers, warranties, and final payment records for the retention periods that apply to tax and construction disputes.

What if a dispute arises after work is complete?

Follow contract dispute-resolution steps such as negotiation, mediation, or arbitration. Preserve all correspondence, invoices, and inspection evidence to support claims or defenses.

Electronic Signature
Templates
Miscellaneous
Home Remodeling Contract

Home Remodeling Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

HOME REMODELING CONTRACT

This Home Remodeling Contract ("Agreement") is made on between:

PARTIES

Contractor (Remodeler) Contractor Business Name (if different) Contractor License/Registration Number Contractor Address Owner (Property Owner) Owner Address

WHEREAS

WHEREAS, Owner is the legal owner of the real property located at (the "Property"); and

WHEREAS, Contractor is duly licensed and qualified to perform remodeling and construction services and agrees to perform the work described in this Agreement in accordance with the terms herein; and

WHEREAS, the parties desire to set forth their respective obligations, the scope, schedule, and payment terms for the remodeling of the Property.

SCOPE OF WORK

Contractor shall furnish all labor, materials, equipment, tools, and supervision necessary to complete the remodeling work described below and in any attached exhibits. Work shall conform to applicable building codes, manufacturer specifications, and good commercial practices.

Detailed Scope of Work (include demolition, construction, materials, finishes, and exclusions)

PAYMENT TERMS

The total contract price for the Scope of Work is $ (the "Contract Sum"), subject to adjustment for approved Change Orders.

Initial Deposit / Retainer Payment Schedule / Milestones

Final payment is due upon substantial completion and acceptance by Owner, subject to any agreed holdback for punch list items. Contractor shall provide lien waivers for payments received if requested.

Late Payment Fee (if payment not received when due)

SCHEDULE / TERM

Work to commence on or about and to reach substantial completion by on or about , subject to adjustments for approved Change Orders, delays beyond Contractor's control, and weather conditions.

Notice Period for Termination by Either Party

Either party may terminate this Agreement for material breach if the breaching party fails to cure such breach within the notice period above. Upon termination, Owner shall pay Contractor for all work performed and materials procured to date, less any damages or offsets.

PERMITS, INSPECTIONS, AND CODE COMPLIANCE

Contractor shall obtain and pay for all required permits, inspections, and approvals unless otherwise agreed in writing. Permit costs not included in the Contract Sum will be billed to Owner as an additional charge with documentation.

Who obtains permits?

Contractor Owner

CHANGE ORDERS

Any modification to the Scope of Work, Contract Sum, or Schedule shall be made only by written Change Order signed by both Contractor and Owner. Contractor shall not be obligated to perform changes absent an executed Change Order.

Change Order Procedure / Notes

WARRANTIES, LIENS, AND INSURANCE

Contractor warrants that labor and materials furnished under this Agreement will be of good quality and free from defects for a period of from the date of substantial completion, except for defects caused by normal wear, Owner misuse, or acts beyond Contractor's control.

Contractor shall maintain commercial general liability and worker's compensation insurance as required by law. Upon request, Contractor shall provide certificates of insurance to Owner prior to commencing work.

Contractor shall be entitled to file mechanic's or construction liens for unpaid work, and Owner shall have the right to require lien releases upon payment.

CONFIDENTIALITY

Each party shall treat as confidential all non-public business and technical information disclosed in connection with this Agreement and shall not disclose such information to third parties except as required to perform the Scope of Work, to comply with law, or with the other party's prior written consent. Confidentiality obligations shall survive termination of this Agreement for a period of two (2) years.

INDEMNIFICATION

Contractor agrees to defend, indemnify, and hold harmless Owner from and against claims, damages, losses, and expenses arising out of Contractor's negligent acts or omissions in the performance of the work, except to the extent caused by Owner's negligence or willful misconduct.

DISPUTE RESOLUTION AND GOVERNING LAW

The parties shall attempt in good faith to resolve disputes arising under this Agreement by negotiation. If unresolved, disputes shall be submitted to binding arbitration administered in accordance with the rules agreed upon by the parties. This Agreement shall be governed by and construed in accordance with the laws of the state where the Property is located.

Governing Law State

ENTIRE AGREEMENT

This Agreement, including any exhibits and executed Change Orders, constitutes the entire agreement between the parties with respect to the Subject Matter and supersedes all prior proposals, negotiations, and representations. Any amendment must be in writing and signed by both parties.

MISCELLANEOUS PROVISIONS

Headings are for convenience only and do not affect interpretation. If any provision is held unenforceable, the remaining provisions shall remain in full force and effect. Time is of the essence with respect to all dates and time periods contained in this Agreement.

Additional Provisions / Notes

SIGNATURES

Contractor Name:

By:

Date:

Owner Name:

By:

Date:

What a Home Remodeling Contract Covers

A Home Remodeling Contract is a written agreement that sets the scope, timeline, costs, responsibilities, and legal terms for residential renovation work. It documents the parties (homeowner and contractor), detailed work descriptions, materials, payment schedule, change-order procedures, insurance and warranty provisions, permitting responsibilities, and dispute-resolution terms. Using a clear contract reduces misunderstandings, supports permit and inspection workflows, and creates an enforceable record of obligations and remedies if performance or payment disputes arise.

Why a Formal Contract Matters for Remodeling

A written Home Remodeling Contract clarifies expectations, allocates risk, and provides enforceable terms for payment, schedule, and quality standards under state contract law. It helps preserve contractor liens, supports insurance claims, and documents consent for permit and inspection access.

Core Elements to Include in a Professional Contract

A complete Home Remodeling Contract balances operational detail with legal protections. Each element below reduces ambiguity, protects both parties, and supports permit, inspection, and payment workflows.

Scope of Work

A precise description of tasks, materials, finishes, quantities, and exclusions to avoid scope creep and disputed expectations.

Schedule

Start and completion dates, milestones, inspection deadlines, and remedies or liquidated damages for missed deadlines.

Payment Terms

Total price, deposit, progress payments tied to milestones, retainage, accepted payment methods, and late-payment interest rates.

Change Orders

Written change-order process, pricing method for extras, required approvals, and how changes affect schedule and warranties.

Permits & Approvals

Which party obtains permits, pays fees, and schedules inspections; include responsibility for corrections required by inspectors.

Insurance & Warranties

Contractor insurance limits, proof of coverage, indemnity language, and warranty scope and duration for work and materials.

Who Typically Prepares and Signs This Contract

Homeowners, licensed contractors, project managers, and sometimes lenders or home equity lenders commonly use or sign remodeling contracts depending on project scale and financing.

Homeowners: commission the work, approve scope and payments, and retain final acceptance authority.
Licensed contractors: prepare proposals, document qualifications, and accept payment and performance obligations.
Subcontractors and suppliers: may be listed as parties or referenced for payment and lien waiver provisions.

For larger projects, attorneys, architects, or local building departments may review contract terms to ensure compliance with building codes, licensing rules, and financing conditions.

Step-by-Step: Completing a Home Remodeling Contract

Follow these steps in order to create a clear, enforceable contract that supports permits, payments, and inspections.

01

Draft Scope: Describe work in detail and list exclusions.
02

Set Timeline: Agree start, milestones, and completion dates.
03

Agree Payments: Set deposit, milestone payments, and retainage.
04

Sign and File: Execute signatures, retain copies, and submit permits.

Customizing the Contract for Online Completion

Configure a digital workflow to collect signatures, attach permits, and store completed files securely.

Field	Configuration
Template	Use master contract template with editable scope sections.
Signer Order	Set homeowner first or contractor first depending on approval needs.
Authentication	Require email link or SMS code for signer verification.
Storage Location	Save final PDF with audit trail to secure cloud storage.

Where to Send or File the Completed Contract

Determine destinations for executed copies, permit applications, and lender or insurer copies before finalizing signatures.

Homeowner Copy: Keep original executed version for records.
Contractor Copy: Contractor retains signed copy for job control.
Permit Office: Attach contract to permit application when required.
Lender or Insurer: Send copies when financing or coverage requires it.

Digital Signing and Technical Requirements

Use a secure eSignature platform that supports required authentication, audit trails, and file formats for permits and lender submission.

File Formats: PDF and DOCX accepted; PDF preferred for official records.
Integrations: Supports integrations like Salesforce, NetSuite, and Procore.
Security: TLS in transit and AES-256 at rest.

Ensure the chosen platform provides an audit trail and exportable signed PDFs compatible with local building department and lender acceptance criteria.

Typical Deadlines and Timeframes to Track

Track contractual and regulatory deadlines that affect start, inspections, payments, and final acceptance.

Permit Application:

Submit before work begins; processing time varies by jurisdiction.

Payment Milestones:

Due dates tied to milestones or calendar dates in the contract.

Inspection Scheduling:

Schedule required inspections promptly after milestone completion.

Final Acceptance:

Owner sign-off date triggers final payment and warranty start.

Change Order Approval:

Respond within agreed days to avoid work delays.

Key Project Milestones from Contract to Closeout

A milestone timeline helps coordinate inspections, payments, and handoffs across contractor, homeowner, and authorities.

01

Contract Execution

Signatures executed and copies distributed to all parties.

02

Permit Secured

Permit approval received before commencing regulated work.

03

Mid-Project Inspection

Inspections verify work at defined stages to avoid rework.

04

Final Inspection & Closeout

Final inspection passed, punch list completed, and final payment released.

Common Mistakes to Avoid When Preparing a Contract

Vague scope descriptions that leave material, finish, or quantity undefined and lead to disputes over expectations and costs.
Undefined payment triggers such as 'upon completion' without measurable milestones, which can delay payment or incentivize incomplete work.
Failing to specify who is responsible for permit corrections and re-inspection costs, which shifts financial risk unpredictably.
Not including a written change-order process, causing verbal changes to be charged later and increasing conflict over pricing.

Consequences of an Incorrect or Incomplete Contract

Contract Void: Risk of unenforceability

Late Payment Penalties: Interest or fees accrue

Mechanic's Lien Risk: Unpaid parties may file liens

Permitting Violations: Stop-work orders or fines

Insurance Gaps: Claims may be denied

Tax Reporting: Incorrect contractor reporting obligations

eSignature Vendor Comparison for Home Remodeling Contracts

Compare common pricing and capability factors across vendors. signNow is listed first per vendor-comparison convention; check vendor sites for the latest plan terms.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies by plan	Varies by plan	Varies by plan	Varies by plan
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No cap	100 env./user/year	Varies	Varies	Varies

Real-World Examples of Contract Use

These brief examples show how organizations document and execute remodeling work to control risk and improve turnaround.

Martin Properties — Mobile Execution

Founder Tim Martin noted streamlined online execution for property documents and compliance

Mobile signing allowed on-site approvals during inspections
The result was faster document turnaround and consistent recordkeeping across multiple projects and mobile environments.

Optica Ventures — Simple Interface

Brian Fitzgibbons described a straightforward interface that customers can use without training

Ease-of-use reduced follow-up calls during signature collection
This improved customer experience and shortened the time from proposal acceptance to work start.

Practical Tips for Accurate and Efficient Contracts

Adopt these practices to reduce disputes, speed approvals, and ensure enforceability.

Use Clear, Measurable Scope Language

Break work into line items with quantities, materials, brands, and acceptable substitutions. Measurable descriptions reduce later disagreements and support accurate change-order pricing.

Tie Payments to Verifiable Milestones

Link disbursements to inspections or deliverables rather than subjective 'substantial completion' language to protect both owner and contractor from payment disputes.

Include Permitting and Inspection Duties

Specify who applies for permits, pays fees, and corrects code violations. This avoids unexpected costs and ensures timely inspections for milestone acceptance.

Record All Changes in Writing

Require signed change orders for any scope, schedule, or price adjustment, and track cumulative cost impacts to avoid surprise balances at project end.

Frequently Asked Questions About Home Remodeling Contracts

Answers to common questions about execution, legal validity, notarization, and dispute handling for remodeling contracts.

Need help? Contact support

Can a remodeling contract be signed electronically?
Yes. Electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. ch. 96, 2000) and UETA where adopted, provided intent, consent, attribution, and record retention requirements are met.
Do I need a notary for the contract to be valid?
Most standard remodeling contracts do not require notarization to be valid between parties, but a notary may be required for related documents like mechanic's lien releases or when a lender requests notarized signatures.
How do I change the contract after signing?
Use a written change order signed by the parties that states the revised scope, cost, and schedule. Verbal agreements are risky and may not be enforceable without written confirmation.
Who can sign on behalf of a contractor or homeowner?
A person with authority—an owner, officer, or authorized agent—should sign. For businesses, include printed name and title. Verify authorization to avoid disputes over signature validity.
What records should I keep after project closeout?
Retain the signed contract, change orders, permits, inspection reports, lien waivers, warranties, and final payment records for the retention periods that apply to tax and construction disputes.
What if a dispute arises after work is complete?
Follow contract dispute-resolution steps such as negotiation, mediation, or arbitration. Preserve all correspondence, invoices, and inspection evidence to support claims or defenses.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now