Establishing secure connection…Loading editor…Preparing document…

Mason Contractors Services Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Mason Contractors Services Agreement

This Mason Contractors Services Agreement ("Agreement") is entered into as of (the "Effective Date"), by and between:

Contractor Name:    Contractor Address:

Client Name:    Client Address:

WHEREAS

WHEREAS, Contractor is duly qualified and experienced in the performance of masonry, stonework and related construction services and represents that Contractor maintains necessary licenses, personnel and insurance to perform the work described herein; and

WHEREAS, Client desires to retain Contractor to perform specified masonry services at the location identified below under the terms and conditions set forth in this Agreement; and

NOW, THEREFORE, in consideration of the mutual covenants contained herein, the parties agree as follows:

Scope of Work

Contractor shall furnish all labor, materials, tools, equipment and supervision necessary to perform the masonry services described below and in any attachments incorporated into this Agreement. The work location is:

Payment Terms

Contract Price: $

Deposit Required: $    Payment Terms: Invoices due within  days of invoice receipt.

Late Payment: Amounts unpaid after the due date shall incur a late fee equal to  or the maximum allowed by law, whichever is less. Client shall also be responsible for collection costs and reasonable attorneys' fees.

Term and Termination

Commencement of Work: Contractor will commence work on or about and shall pursue the work in a diligent manner to completion.

Estimated Completion Date: . Time is of the essence subject to excusable delays as set forth herein.

Termination for Cause: Either party may terminate this Agreement upon written notice if the other party materially breaches a material obligation and fails to cure such breach within  days after receipt of written notice specifying the breach.

Termination for Convenience: Client may terminate for convenience upon written notice; in such event Client shall pay Contractor for work performed, materials purchased, and reasonable demobilization costs.

Confidentiality

Each party agrees that all non-public information, drawings, specifications, pricing, and other business information disclosed by one party to the other in connection with the performance of this Agreement ("Confidential Information") shall be held in strict confidence and shall not be disclosed to third parties without the disclosing party's prior written consent, except to the extent disclosure is reasonably required to perform the work or is compelled by law. Confidential Information shall not include information that is or becomes publicly available through no fault of the receiving party, is rightfully received from a third party without restriction, or is independently developed by the receiving party without use of the disclosing party's Confidential Information.

Insurance, Warranties and Indemnity

Contractor warrants that materials furnished will be of good quality and that work will be performed in a workmanlike manner for a period of  months from completion. Contractor shall maintain, at its own expense, commercial general liability insurance and workers' compensation coverage as required by law. Contractor shall indemnify and hold harmless Client from and against claims, damages, liabilities and costs arising from Contractor's negligent performance, except to the extent caused by Client's negligence or willful misconduct.

Subcontracting and Permits

Contractor may engage subcontractors where necessary, provided Contractor remains responsible for the subcontractor's performance. Client shall obtain or pay for any permits or inspections expressly identified in the Detailed Scope of Work; otherwise Contractor shall obtain permits and include permit cost in the invoice where agreed in writing.

Governing Law

This Agreement shall be governed by and construed in accordance with the laws of the State of , without regard to its conflict of laws principles.

Entire Agreement; Amendments

This Agreement, including exhibits and schedules attached hereto, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, representations and agreements. Any modification or amendment to this Agreement must be in writing and signed by authorized representatives of both parties.

Dispute Resolution

The parties shall attempt in good faith to resolve any dispute arising under this Agreement through negotiation. If negotiation fails, disputes shall be resolved by binding arbitration in the county where the Project is located, in accordance with the rules of the selected arbitration provider, and judgment upon the award may be entered in any court of competent jurisdiction.

Notices

Notices under this Agreement shall be in writing and delivered to the addresses set forth above by personal delivery, nationally recognized overnight courier, or certified mail, return receipt requested, and shall be effective upon receipt.

Contractor:

By:

Date:

Client:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Mason Contractors Services Agreement Covers

A Mason Contractors Services Agreement is a written contract that sets out the scope, schedule, payment, and responsibilities for masonry work on a construction project. It defines parties (owner, general contractor, mason), deliverables (materials, labor, tolerances), milestones (start, inspections, completion) and financial terms (fixed price, progress payments, retainage). The agreement also addresses risk allocation — insurance, warranties, indemnities — plus change order procedures and dispute resolution methods to reduce ambiguity during performance.

Why a Clear Services Agreement Matters

A written Mason Contractors Services Agreement clarifies expectations, preserves payment rights such as mechanic’s liens, and reduces costly disputes through defined procedures.

Why a Clear Services Agreement Matters

Who Typically Completes This Agreement

Ensure each party reviews licensing, insurance, and lien waiver obligations before signing to avoid enforcement gaps.

  • Project Owner or Developer — Authorizes scope and pays invoices; needs clear payment and warranty terms.
  • General Contractor — Oversees schedule and coordination; requires flow-down clauses and indemnity alignment.
  • Masonry Contractor/Subcontractor — Defines workmanship standards, materials, and payment milestones for their scope.

Primary Signatories and Their Roles

Project Owner — Signing Authority

The owner or an authorized representative signs to bind payment obligations and to confirm project acceptance criteria. Review insurance and change order authority before signing to ensure funds and approvals are in place.

Masonry Contractor — Company Officer

An officer or authorized agent of the masonry firm signs for scope, schedule, and warranty commitments. Confirm the contractor holds required state license and workers’ compensation coverage prior to execution.

Key Clauses to Include in the Agreement

A professional Mason Contractors Services Agreement organizes technical, commercial, and legal terms so obligations are enforceable and performance is measurable.

Scope of Work

Detailed description of tasks, materials, standards, and tolerances to avoid scope creep and conflicting expectations.

Schedule and Milestones

Start date, critical milestones, inspection windows, and completion criteria tied to payment events.

Payment Terms

Contract price, progress payments, retainage, invoicing schedule, and accepted payment methods.

Change Orders

Procedure for requesting, pricing, approving, and documenting scope changes and their effect on time and cost.

Insurance and Indemnity

Required policies, coverage limits, additional insured language, and mutual indemnification where appropriate.

Warranties and Remedies

Workmanship warranties, material guarantees, correction periods, and remedies for defective work.

Essential Administrative and Compliance Data

Contractor License: State license number
Insurance Certificates: General liability limits
Work Schedule: Start and completion dates
Payment Terms: Price and retainage
Contact Information: Address and phone
Signature Evidence: Signed name and date

Step-by-Step: Completing a Mason Contractors Services Agreement

Follow these sequential steps to prepare, review, and execute the agreement with minimal rework and clear evidence for payment and compliance.

  • 01
    Prepare Draft: Populate scope, schedule, and price from plans and bids.
  • 02
    Review Licensing: Verify contractor license and insurance certificates.
  • 03
    Negotiate Terms: Agree change order, warranty, and payment mechanics.
  • 04
    Execute: Obtain signatures and distribute signed copies to all parties.

Configure an Online Signing Workflow

When using an eSignature platform, configure authentication, signer order, reminders, and templates to match your project workflow.

Field Configuration
Authentication Method Email with optional SMS code
Signature Order Sequential signing by role
Reminders Automated reminders every 3–7 days
Templates Save standard clauses for reuse

Routing and Submission Overview

A typical routing flow ensures the right parties sign in order and retain a verifiable record of the transaction for project controls.

  • Upload Document: Add final agreement and exhibits
  • Place Fields: Insert signature, date, and text fields
  • Send to Signers: Email or secure link per signer role
  • Archive Signed Copy: Save executed PDF with audit trail

Digital Signing and File Format Considerations

Choose a platform that supports required authentication, audit trails, and storage formats for construction records.

  • Formats Supported: PDF, DOCX, and image files
  • Integrations: Procore, Microsoft 365, Google Workspace
  • Authentication Options: Email, SMS code, or advanced methods

How This Agreement Differs from a Subcontractor Agreement

Compare common contract forms so you choose the document that matches party relationships and risk allocation on a given project.

Contract Type Mason Contractor Services Subcontractor Agreement
Purpose direct masonry scope downstream trade scope
Primary Parties owner/contractor/contractor general contractor/subcontractor
Payment Flow owner or gc pays contractor gc pays subcontractor
Lien Waiver often required standard practice

Common eSignature Vendor Pricing Overview

Typical starting prices and key features for eSignature vendors — signNow is listed first per platform comparison conventions.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Common Legal and Financial Risks

Lien Risk: Unpaid work can allow mechanic's lien
Licensing Fines: Performing without license risks penalties
Payment Disputes: Late payments lead to interest or litigation
Tax Reporting: Incorrect 1099s trigger IRS penalties
Defective Work Claims: Remediation and delay costs increase
Recordkeeping Failure: Missing records limit legal defenses

Common Mistakes to Avoid

  • Vague scope descriptions that invite disputes and change orders
  • Failure to verify contractor license and insurance before starting work
  • Not documenting change orders or schedule adjustments in writing
  • Using initials instead of full executed signatures for key terms

Timing Elements and Typical Deadlines

Track key dates in the agreement to trigger payments, inspections and notice periods that preserve rights.

Effective Date:

Date obligations begin

Start Date:

When contractor must mobilize

Progress Payment Dates:

Scheduled payment milestones

Change Order Response:

Time to accept or reject changes

Defect Correction Period:

Window to remedy faulty work

Key Project Milestones from Agreement to Closeout

A milestone timeline helps stakeholders monitor progress and link payments to verifiable events throughout the masonry scope.

01

Contract Execution

Agreement signed and copies distributed

02

Mobilization

Contractor begins site work and supplies

03

Inspections

Milestone inspections and approvals

04

Final Acceptance

Punchlist closed and final payment released

Real-World Examples of Contract Use

Examples show how teams use written agreements and digital signing to reduce delays and document compliance.

Martin Properties

The firm moved lease and contractor paperwork online to speed approvals.

  • Used eSign for remote execution.
  • Project managers reported fewer missing signatures and a consistent audit trail for owner records, improving turnover timelines without in-person signings.

BIS

BIS standardized contract templates for subcontractors on large projects.

  • Centralized templates reduced drafting time.
  • Standard forms reduced negotiation cycles, improved payment timing, and made dispute resolution faster through clearer scope and payment clauses.

Practical Tips for Accurate and Efficient Agreements

Use these best practices to reduce rework and preserve legal and payment rights during project execution.

Use Detailed Scope Exhibits
Attach drawings, material specifications, and tolerances to the agreement so scope is objective and easier to inspect; this reduces change order disputes and supports payment milestones.
Align Payment to Milestones
Specify measurable milestones tied to payments with clear acceptance criteria and inspection steps to minimize subjective disputes and delayed invoices.
Document All Changes
Require written, signed change orders for scope, time, or price adjustments to maintain a traceable record and avoid competing oral claims later.
Verify Insurance and Licenses
Obtain certificates of insurance and license validation before mobilization; keep copies with the executed agreement to support indemnity and claims defenses.

Frequently Asked Questions About the Mason Contractors Services Agreement

Answers to common questions about execution, eSigning, retainage, and dispute prevention for masonry contracts.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.