Establishing secure connection…Loading editor…Preparing document…

Miscellaneous Shower Door Addendum

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Miscellaneous Shower Door Addendum

This Shower Door Addendum (the "Addendum") is entered into as of Effective Date: by and between Client Name: and Contractor/Installer Name: . This Addendum amends and supplements the existing contract between the parties where applicable.

Recitals

WHEREAS, Client and Contractor previously entered into a written agreement identified as Original Agreement dated (the "Original Agreement"); and

WHEREAS, the parties desire to modify the Original Agreement to add, revise, or specify the scope of work for the installation, removal, repair, or replacement of a shower door and related components at the property located at: .

WHEREAS, the parties intend that this Addendum govern and control to the extent of any conflict between this Addendum and the Original Agreement.

Scope of Work

Materials and Specifications

Select applicable options and provide specifics for glass, hardware, and finishes:

Frameless glass panel(s)

Framed glass with metal surround

Sliding door configuration

Payment Terms

Late payments shall incur a fee of % per month on the outstanding balance, or the maximum permitted by law, whichever is less.

Term and Termination

Either party may terminate this Addendum for material breach if the breaching party fails to cure within days after receipt of written notice. Termination shall not relieve Client of responsibility for payment for work performed through the termination date.

Warranty

Contractor warrants that all labor performed under this Addendum will be free from defects for a period of months from the completion date, and that materials supplied shall conform to manufacturer specifications. This warranty does not cover damage caused by abuse, misuse, alterations, or failure to provide reasonable maintenance.

Permits and Compliance

Contractor shall obtain and pay for all permits, inspections, and approvals required by applicable codes for the performance of the work described herein unless otherwise agreed in writing. Work shall comply with all applicable building codes and industry standards.

Access and Site Conditions

Client shall provide Contractor reasonable access to the premises and a clean, safe work area. Any unforeseen site conditions discovered during performance that materially affect scope or price will be reported to Client and addressed as a change order in accordance with the Payment Terms above.

Confidentiality

Each party shall treat as Confidential Information all non-public information disclosed in connection with this Addendum. Confidential Information shall not include information that is or becomes public other than through a breach of this clause, lawfully obtained from a third party, or independently developed. The receiving party shall not disclose Confidential Information to third parties except to those employees, agents, or subcontractors who have a need to know and who are bound by obligations of confidentiality no less protective than those contained herein.

Governing Law

This Addendum shall be governed by and construed in accordance with the laws of the State of , without regard to its conflict of laws principles. Venue for any dispute arising out of or relating to this Addendum shall be the courts located in the county where the Property is located.

Entire Agreement

This Addendum, together with the Original Agreement and any prior written modifications thereto, constitutes the entire agreement of the parties with respect to the subject matter hereof and supersedes all prior negotiations, representations, warranties, promises, or agreements, written or oral. Except as expressly modified by this Addendum, all terms and conditions of the Original Agreement remain in full force and effect.

Change Orders

Any modifications to the scope, materials, price, or schedule shall be made only by written change order signed by both parties. No verbal agreement shall modify this Addendum.

Client Printed Name:

By:

Date:

Contractor Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Miscellaneous Shower Door Addendum Is and When It Applies

The Miscellaneous Shower Door Addendum is a short supplemental contract that modifies or records specific terms about shower door items within a primary construction, remodeling, or real estate agreement. Typical uses include documenting scope changes, specifying product models or finishes, establishing allowances or extra charges, setting installation and inspection dates, and listing warranty terms or acceptance criteria. The addendum should identify the parties, reference the original agreement, detail precise measurements and item descriptions, record any price adjustments, and include dated signatures from authorized signatories to bind the change.

Why Using a Dedicated Addendum Matters

A focused addendum protects both parties by clearly recording changes, costs, and timelines separate from the main contract.

Why Using a Dedicated Addendum Matters

Who Typically Prepares and Signs This Addendum

The addendum is most often completed by contractors, installation subcontractors, property managers, and homeowners or buyers when shower door items differ from the original scope.

  • General Contractors — Document manufacturer, model, and installation tolerances before ordering.
  • Homeowners / Buyers — Confirm finish, glass type, and acceptance conditions in writing.
  • Property Managers — Record maintenance responsibilities and warranty handoff for multiunit sites.

Accurate completion prevents disputes, speeds approvals, and clarifies warranty and acceptance responsibilities for all parties.

Step-by-Step: Completing and Executing the Addendum

Follow these steps to prepare, approve, and retain the addendum so it attaches cleanly to the base contract.

  • 01
    Review Contract: Locate the original agreement and reference its date and parties.
  • 02
    Detail Scope: Specify the exact shower door items, measurements, and installation requirements.
  • 03
    Set Costs: Record allowances, firm prices, or change-order pricing and payment terms.
  • 04
    Sign and Distribute: Obtain authorized signatures, date the addendum, and share copies with all parties.

Frequently Asked Questions About the Addendum

Common practical and legal questions about use, signatures, and corrections for the Miscellaneous Shower Door Addendum.


Need help? Contact support

Six Elements a Professional Addendum Always Includes

A well-formed addendum is concise but complete; include these six elements to reduce disputes and streamline administration.

Reference

Base agreement citation with date and parties so the addendum unambiguously attaches to the original contract.

Scope

Clear description of the shower door items, finishes, model numbers, and exact measurements to avoid substitution disputes.

Pricing

Allowance or firm price language, taxes, labor, and how cost overruns will be handled, with payment schedule if applicable.

Schedule

Installation start and completion dates, dependency notes (e.g., tile completion), and inspection or acceptance milestones.

Acceptance

Criteria for homeowner acceptance, corrective work procedures, and warranty handoff terms to govern post-install issues.

Execution

Signature lines, printed names, titles, and effective date to create an enforceable amendment to the contract.

Essential Data Fields to Capture and Protect

Signer Identity: Full legal name
Dates: Execution and effective dates
Measurements: Exact width/height/depth
Model/Finish: Manufacturer and finish
Price Terms: Allowance or fixed amount
Warranty: Duration and coverage

Top Risks and Consequences of an Incorrect Addendum

Scope Ambiguity: Price disputes
Missing Signatures: Enforceability issues
Wrong Measurements: Rework costs
Schedule Conflicts: Project delays
Warranty Gaps: Voided coverage
Permit Problems: Inspection failures

Common Preparation Errors to Avoid

  • Using vague descriptions such as 'standard glass' instead of naming the exact glass tempering and thickness causes ordering mistakes and disputes.
  • Failing to reference the original contract date and parties can make it unclear whether the addendum attaches to the correct agreement.
  • Leaving pricing terms unspecified or labelled as estimates without maximum limits leads to unexpected cost claims and payment disagreements.
  • Signing without verifying measurements or installation dependencies (tile, framing) increases rework and scheduling conflicts.

Where the Signed Addendum Goes and Who Sees It

After execution, route the addendum to contract stakeholders and retain it with project records to ensure enforceability and auditability.

  • Contract File: Attach signed addendum to original contract record.
  • Project Manager: Deliver copy for scheduling and procurement.
  • Permitting Office: Provide if permit conditions require change documentation.
  • Owner / Client: Send final signed copy for acceptance and warranty records.

Typical Digital Workflow Settings for the Addendum

Recommended workflow configuration for a smooth e-sign and recordkeeping process.

Field Configuration
Signer Order Contractor first | Owner second
Authentication Email link + SMS code optional
Reminders 3 reminders at 3-day intervals
Storage Store PDF in project folder

Technical Requirements for Electronic Completion and Distribution

Use a platform that supports common file formats, signer authentication, and audit trails for legal certainty.

  • File Formats: PDF and DOCX supported
  • Integrations: Salesforce, NetSuite, Procore
  • Notarization: RON availability varies

Common Timing and Deadline Expectations

Typical timing milestones to include with the addendum so duties and remedies are clear.

Issue Addendum By:

At least 7 days before ordering

Owner Acceptance Window:

Within 5 business days of delivery

Installation Window:

Specify start and completion dates

Inspection / Punchlist:

Allow 3–7 days after install

Final Payment Due:

On acceptance or as stated

eSignature Vendor Pricing Snapshot for Addendum Workflows

Basic pricing and feature availability for commonly used eSignature providers; signNow appears first per the vendor comparison convention.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by vendor Varies by vendor Varies by vendor Varies by vendor
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Real-World Examples of Addendum Use

Examples illustrate practical outcomes when the addendum is used to manage scope and signatures in field and closing workflows.

Martin Properties Example

Tim Martin streamlined online execution for on-site upgrades to fixtures, shortening turnaround time by eliminating in-person signings.

  • Field teams recorded models and acceptance criteria directly into project files.
  • The result was clearer acceptance records, fewer change-order disputes, and faster final payments, while ensuring compliance with contracting procedures.

Optica Ventures Example

Brian Fitzgibbons noted simpler customer interactions when addenda were clear and digital, reducing back-and-forth by email.

  • Model and finish details were attached to work orders.
  • Clear documentation improved procurement accuracy, lowered order rework, and provided auditable records for owner approvals and warranty handoffs.

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.