Establishing secure connection…Loading editor…Preparing document…

Notice to Disburser by Lien Claimant

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

NOTICE TO DISBURSER BY LIEN CLAIMANT-INDIVIDUAL
(Colorado Revised Statute § 38-22-126(4))

Comes now,

and hereby provides notice of the following:

1. The undersigned lien claimant is entitled to a lien for labor performed, materials supplied or laborers furnished, for the purposes of improvements of property located at:

and legally described as:

2. Said improvements were the result of a contract entered into between the undersigned and and the terms of the contract include:

This the

Certificate of Delivery

I, , hereby certify that I have delivered this day a true and correct copy of the foregoing to by:

Personal Service

Leaving a copy at the disburser's residence or at his place of business with some person in charge located at

Mailing a true and correct copy of same by certified U.S. mail, postage prepaid, return receipt requested to:

So certified this the

Enter text

What the Notice to Disburser by Lien Claimant Is

A Notice to Disburser by Lien Claimant is a formal written notice provided by a party asserting a lien or potential lien against funds held by a disburser (for example, an escrow agent, title company, or general contractor). The notice informs the disburser that a claimant alleges unpaid work, materials, or services and requests that funds be withheld or routed according to lien procedures. This document preserves the claimant’s rights, triggers any statutory hold or stop-payment timelines, and supplies the disburser with contact and claim details necessary to evaluate or process payments in compliance with state lien laws.

Why this notice matters

A properly completed Notice to Disburser by Lien Claimant alerts the party holding funds, helps preserve lien rights, and creates a clear administrative record that can prevent inadvertent disbursement of contested funds.

Why this notice matters

Who prepares and receives this notice

Identify the correct disburser and use the notice early to meet state filing or service requirements; late or misdirected notices can limit enforcement options.

  • Subcontractors and suppliers who have not received payment for labor or materials
  • Construction managers, general contractors, or property owners acting as disbursers
  • Title companies and escrow agents handling closing or holdback funds

Decision-makers and signers

Claimant — Authorized Representative

A company owner, project manager, or accounts payable officer may sign on behalf of the claimant. The signer should have authority to assert the lien and provide contract and payment details to support the claim; inaccurate signer authority can invalidate the notice.

Disburser — Fund Custodian

A title officer, escrow agent, or accounts payable manager typically receives and reviews the notice. The recipient must evaluate legal sufficiency, confirm fund availability, and follow statutory procedures for withholding or disbursement.

Step-by-step: preparing and sending the notice

Follow these sequential actions to prepare a legally useful Notice to Disburser by Lien Claimant and minimize processing delays.

  • 01
    Gather evidence: Collect contracts, change orders, and invoices supporting the claim.
  • 02
    Complete the notice: Fill claimant, disburser, project, and claim amount fields accurately.
  • 03
    Choose delivery method: Select certified mail, courier, or e-delivery consistent with state requirements.
  • 04
    Retain proof: Keep return receipts, delivery confirmations, and an executed copy.

How the notice flows from claimant to resolution

This overview shows the typical path a Notice to Disburser follows after submission and what each party must do.

  • Submission: Claimant delivers notice to the disburser with supporting documents.
  • Acknowledgment: Disburser reviews and logs receipt, noting any immediate holds.
  • Investigation: Parties exchange records; claimant verifies invoices and dates.
  • Disposition: Funds are withheld, escrowed, or disbursed following statute or court order.

Digital workflow settings to track and process notices

Configure a consistent electronic workflow and tracking fields so every notice and response is auditable.

Field Configuration
Claimant ID Auto-populate from contractor database
Notice Date MM/DD/YYYY timestamp, system-generated
Delivery Method Select: certified mail, RON, courier, email
Proof Attachment Upload invoices, contracts, lien waivers

Essential elements to include for a professional notice

A complete notice reduces disputes and speeds disburser review. Include the following elements to make the claim actionable and defensible.

Complete identification

Legal names and contact details for both claimant and disburser, plus project address and any parcel or contract identifiers to tie the claim to specific funds.

Clear claim amount

Exact dollar amount and, where applicable, breakdowns by unpaid invoices, retainage, or change orders so the disburser can reconcile against available funds.

Work description

Concise description of labor or materials provided, including dates and invoice references to enable quick verification by the disburser or payer.

Legal basis

Reference relevant contract clauses, purchase orders, or statutory grounds for the lien claim to clarify the claimant’s assertion.

Delivery and service details

Method and date of delivery to the disburser, plus evidence such as certified mail receipt, courier tracking, or RON transcript for auditability.

Signature and authority

Signed by an authorized claimant representative with printed name, title, and date; include company letterhead or notarization if required by state law.

Information you must protect and keep private

Claimant SSN/EIN: Redact or limit distribution where not required
Bank account details: Avoid including unless necessary for disbursement
Contract pricing: Protect confidential pricing data
Medical data: Do not include PHI; follow HIPAA (45 CFR §164.530(j))
Employee info: Limit personal identifiers to necessity
Audit trail: Preserve timestamps and delivery receipts securely

Tips for accurate and efficient completion

Follow these best practices to lower the chance of rejection and accelerate review by the disburser.

Use precise dates and identifiers
Provide MM/DD/YYYY dates and contract or invoice numbers to allow quick cross-referencing and reduce manual follow-up.
Attach supporting documents
Include invoices, purchase orders, and a short summary so the disburser can verify the claim without extra requests.
Select the right delivery method
Use certified mail or RON where statute or contract requires proof of service; electronic delivery should include a signed audit trail.
Keep complete records
Retain submitted copies, delivery receipts, and correspondence for the retention period required by applicable laws.

Common pitfalls to avoid

  • Incorrect disburser name or address leads to misdelivery and lost rights
  • Vague description of work or invoices prompts additional verification delays
  • Missing signatures or incorrect signer authority can invalidate the notice
  • Failure to preserve delivery proof weakens enforcement in disputes

Consequences of incorrect or late notices

Loss of lien priority: Delayed or defective notices can forfeit priority against other claimants
Failure to recover funds: Incorrectly addressed notices may result in full disbursement to the payer
Civil exposure: Improperly asserted liens can prompt counterclaims or penalties
Increased legal costs: Rectifying deficiencies often requires counsel and court filings
Statutory limitations: Missing filing windows can bar lien enforcement under state law
Recordkeeping penalties: Failure to retain records may violate industry or federal rules

Key deadlines and timing expectations

Timeline obligations vary by state; these general deadlines identify common time-sensitive actions claimants and disbursers must track.

Notice before disbursement:

Send notice as soon as nonpayment is identified; some statutes require pre-disbursement notice.

Filing period:

State lien filing windows often range from 60 to 180 days after last work; verify with state statute.

Statute of limitations:

Lien enforcement deadlines vary; missing them can forfeit rights.

Retention period:

Keep documentation for at least the period required by federal or state authorities.

Response windows:

Disbursers typically have a specified period to acknowledge and act on a notice; check contract and state rules.

Milestones from notice to final disposition

Track these sequential stages to manage the claim lifecycle and meet required procedural steps.

01

Prepare and deliver notice

Claimant assembles documents and serves the disburser with proof of delivery.

02

Disburser acknowledgment

Disburser logs receipt and reviews whether funds should be withheld.

03

Claim verification

Parties exchange supporting invoices and contract references for reconciliation.

04

Resolution or enforcement

Funds are escrowed, disbursed under agreement, or subject to court enforcement if contested.

Key differences: Electronic notice versus paper notice

Compare core attributes to decide whether to deliver the notice electronically or by printed, mailed copy based on statute, proof needs, and speed.

Criteria Electronic Paper
Proof of receipt audit trail certified mail receipt
Speed immediate 2–7 business days
Statutory acceptance varies by state universally accepted
Record integrity tamper-evident audit trail physical originals

eSignature vendor pricing and capabilities relevant to notice delivery

Compare starting price and key features that affect large-volume or legally sensitive notice workflows; signNow is listed first per standard comparisons.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Trial available Trial available Trial available Trial available
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year No cap No cap No cap

Real-world examples of notice use

Sample scenarios show how notice details and attachments differ by context and the practical outcome when executed correctly.

Construction Subcontractor

A subcontractor submits a notice with invoices and change orders

  • Claim amount lists unpaid retainage and invoice dates
  • The disburser placed funds into escrow pending reconciliation, preserving the lien priority and prompting rapid settlement discussions.

Title Company at Closing

A supplier alleges unpaid materials for a scheduled closing

  • Notice names the escrow account and parcel ID
  • The title company withheld disputed funds, opened an internal review, and coordinated with counsel to avoid releasing proceeds prematurely.

Delivering notices electronically: technical requirements

Ensure the chosen platform can produce reproducible records for litigation and, where applicable, a BAA for HIPAA compliance.

  • Document formats: PDF, DOCX, and secure HTML accepted
  • Integrations: Salesforce, NetSuite, Microsoft 365, Google Workspace supported
  • Security: TLS 1.2/1.3 in transit; AES-256 at rest

Frequently asked questions about Notice to Disburser by Lien Claimant

Answers to common questions about timing, delivery, signature authority, and how electronic notices interact with state lien rules.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users