Establishing secure connection…Loading editor…Preparing document…

Owner-Architect Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

OWNER-ARCHITECT CONTRACT

This Owner-Architect Contract (the "Agreement") is made as of Effective Date: , by and between Owner Name: , Owner Address: , and Architect Name: , Architect Address: .

RECITALS

WHEREAS, Owner intends to construct or renovate the project known as Project Name: , located at Project Location: (the "Project"); and

WHEREAS, Architect is duly licensed to provide architectural services and represents that Architect has the professional competence and resources to perform such services; and

WHEREAS, Owner desires to engage Architect to provide architectural services for the Project as set forth in this Agreement and Architect accepts such engagement on the terms and conditions contained herein.

NOW, THEREFORE, in consideration of the mutual covenants contained in this Agreement, the parties agree as follows:

1. ARCHITECT'S SERVICES

1.1 Basic Services. Architect shall provide professional architectural services ("Basic Services") which shall include programming review, schematic design, design development, preparation of construction documents, assistance in obtaining building permits, and construction administration, all as described in the Scope of Services below. The detailed Scope of Services is:

1.2 Additional Services. Services beyond Basic Services shall be "Additional Services" and provided only upon written authorization by Owner. Examples of Additional Services include landscape design, extensive code review beyond normal practice, multiple bidding phases, or services after Substantial Completion. Describe anticipated Additional Services, if any:

2. PERIOD OF SERVICE

2.1 Commencement and Substantial Completion. Architect shall commence services upon receipt of a fully executed Agreement and any required retainer. Architect shall use commercially reasonable efforts to achieve Substantial Completion of the Project in accordance with the Project schedule below.

3. COMPENSATION

3.1 Architect's Fee. Owner shall pay Architect for Basic Services as set forth below. The fee is exclusive of reimbursable expenses, permit fees, and consultants unless otherwise stated.

Lump Sum (Stipulated Sum)    Percentage of Construction Cost    Hourly Rates

3.2 Reimbursable Expenses. Reimbursable expenses shall be invoiced at cost plus any agreed mark-up. Typical reimbursables include printing, courier, travel, and specialized consultants.

3.3 Invoicing and Payment. Architect will submit monthly invoices based on percentage complete or hours expended. Owner shall pay invoices within days of receipt. Late payments shall accrue interest at .

4. OWNER'S RESPONSIBILITIES

4.1 Owner shall provide available information, decisions, and approvals in a timely manner, and shall designate a representative authorized to act on Owner's behalf. Owner shall secure financing as required for the Project and make payments in accordance with this Agreement.

5. TERMINATION

5.1 Termination for Cause. Either party may terminate this Agreement if the other party materially breaches and fails to cure within thirty (30) days of written notice specifying the breach. Termination shall not relieve the breaching party of liability for damages resulting from the breach.

5.2 Termination for Convenience. Owner may terminate this Agreement for convenience upon fourteen (14) days' written notice to Architect. In such event, Owner shall pay Architect for services rendered and reimbursable expenses incurred to the date of termination, together with termination expenses reasonably resulting from such termination.

6. OWNERSHIP OF DOCUMENTS; LICENSE

6.1 Original Documents. Originals of studies, drawings, specifications and other documents prepared by Architect shall remain Architect's instruments of service. Architect grants Owner a nonexclusive, perpetual license to use the documents for the Project as constructed, provided Owner has paid all amounts due to Architect.

6.2 Reuse. Any reuse of documents by Owner for other projects or modifications without Architect's written consent is prohibited and Owner shall indemnify Architect for any claims arising from such reuse.

7. INSURANCE AND PROFESSIONAL LIABILITY

7.1 Architect shall maintain professional liability insurance, commercial general liability insurance, and workers' compensation as required by law and in amounts reasonable for the Project. Architect shall provide certificates upon request.

8. INDEMNIFICATION

8.1 Architect's Indemnity. Architect shall indemnify, defend, and hold harmless Owner from third-party claims arising out of Architect's negligent performance of professional services, to the extent caused by Architect's negligence. Architect's indemnity shall be subject to the limitations of available insurance and applicable law.

8.2 Owner's Indemnity. Owner shall indemnify, defend, and hold harmless Architect from third-party claims arising out of Owner's negligent acts or omissions, except to the extent caused by Architect's negligence.

9. LIMITATION OF LIABILITY

To the fullest extent permitted by law, neither party shall be liable to the other for consequential, special, indirect, or punitive damages arising out of this Agreement. Total liability of Architect for claims arising out of this Agreement shall be limited to amounts recoverable under Architect's insurance coverage and, where permitted by law, to the greater of the Architect's fee for the Project or the limit of liability expressly stated below:

10. FORCE MAJEURE

Neither party shall be liable for delays or failures in performance caused by circumstances beyond the reasonable control of the affected party, including acts of God, strikes, government regulations, shortages of materials, or unavoidable delays in transportation. The time for performance shall be extended for a period equal to the duration of such delay.

11. DISPUTE RESOLUTION

The parties shall first attempt to resolve disputes by good faith negotiation between senior representatives. If unresolved within thirty (30) days, the parties agree to non-binding mediation. If mediation does not resolve the dispute, the parties agree to binding arbitration under the rules agreed in writing. Judgment upon the award may be entered in any court having jurisdiction.

12. NOTICES

All notices required or permitted under this Agreement shall be in writing and delivered to the parties at their respective addresses set forth below or to such other address as a party may designate by written notice.

13. AMENDMENTS; WAIVER

This Agreement may be amended only by a written instrument executed by both parties. The waiver of any right under this Agreement shall not be effective unless in writing and signed by the waiving party.

14. GOVERNING LAW; SEVERABILITY; ENTIRE AGREEMENT

14.1 Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State specified below, without regard to its conflict of laws principles.

14.2 Severability. If any provision of this Agreement is held invalid or unenforceable, the remaining provisions shall remain in full force and effect.

14.3 Entire Agreement. This Agreement, together with any exhibits or schedules expressly incorporated, constitutes the entire agreement between the parties and supersedes all prior negotiations and agreements concerning the Project.

15. MISCELLANEOUS

15.1 Counterparts. This Agreement may be executed in counterparts, each of which shall be deemed an original.

Owner:

By:

Date:

Architect:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What an Owner-Architect Contract Is and What It Covers

An Owner-Architect Contract is a written agreement that sets out the professional services, deliverables, schedule, and compensation for architectural work on a construction or renovation project. It identifies the owner and architect, describes the scope of services (schematic design, design development, construction documents, bidding/negotiation, construction administration), allocates responsibilities for approvals, permits, insurance, and intellectual property, and includes payment terms, change-order procedures, dispute resolution, and termination rights. Typically it attaches project plans, specifications, a fee schedule, and a timeline as exhibits to reduce ambiguity during design and construction.

Why a Clear Owner-Architect Contract Matters

A precise contract reduces disputes, defines payment and scope, and protects professional and owner interests during design and construction.

Why a Clear Owner-Architect Contract Matters

Who Typically Prepares and Uses This Agreement

The template is used by project owners, licensed architects, and project managers to formalize design services and responsibilities.

  • Project Owner — hires architect and approves scope; responsible for payments and providing site information.
  • Architect / Design Firm — delivers services under license; certifies documents and provides construction administration.
  • General Contractor / Construction Manager — uses contract exhibits for bidding and coordination during construction.

Stakeholders including lenders, contractors, and municipal reviewers rely on the contract to confirm scope, schedule, and compliance obligations.

Core Clauses to Include in a Professional Contract

A complete Owner-Architect Contract bundles technical scope, payment mechanics, timelines, risk allocation, and termination mechanics into clear, enforceable clauses.

Scope of Work

Describe deliverables by phase (schematic, design development, construction documents, bidding, construction administration) and list excluded services to avoid scope creep.

Compensation

Specify fee basis (lump sum, percentage, hourly), payment schedule, invoicing cadence, reimbursable expenses, and late payment interest.

Schedule

Set milestone dates, review turnarounds, and responsibilities for owner-provided information that affect the architect’s schedule.

Change Orders

Define procedures for written change orders, pricing methodology for extra work, and authority for approving scope adjustments.

Insurance & Indemnity

State required insurance limits, professional liability terms, and indemnity obligations consistent with state law and owner requirements.

Termination

Outline termination for convenience and for cause, notice periods, final accounting, and ownership of work-in-progress documents.

Step-by-Step: Complete and Execute the Owner-Architect Contract

Follow these steps to prepare, review, and sign the agreement so it is enforceable and operationally effective.

  • 01
    Prepare Draft: Populate parties, scope, fees, schedule, and exhibits before internal review.
  • 02
    Internal Review: Have legal and project leads confirm terms, insurance, and licensing.
  • 03
    Signatures: Execute by authorized signers; confirm signatory authority in entity records.
  • 04
    Distribute Copies: Send executed copies to owner, architect, contractor, lender, and permit file as needed.

How to Configure an Online Signing Workflow for This Agreement

Set up fields, required signers, and attachments to ensure complete, auditable execution when using an eSignature platform.

Field Configuration
Signature Field Required for Owner and Architect; set as mandatory
Initials Place at each appendix or exhibit page requiring acknowledgement
Date Field Auto-populate with signer date on execution
Attachments Attach plans, specs, and insurance certificates as required exhibits

Digital Signing and File Format Recommendations

Use signed PDFs and a platform that records an audit trail, stores certificates, and supports common integrations.

  • File Formats: PDF, DOCX supported
  • Integrations: Salesforce, NetSuite, Procore available
  • Authentication: Email, SMS, or advanced methods

Where to Send Executed Copies and Related Submissions

After execution, route copies to all parties, file required permits, and archive a signed PDF with audit evidence.

  • Owner Copy: Owner retains contract and all exhibits
  • Architect Copy: Architect archives signed contract for project records
  • Permitting Authority: Provide required documents during permit application
  • Contractor / Lender: Distribute copies for bidding, funding, and compliance

Key Dates and Deadlines to Track

Identify milestone dates and trigger conditions so payments and design reviews occur on schedule and permits are filed timely.

Effective Date:

Date when contract obligations begin

Design Milestones:

Dates for schematic, DD, and CD submissions

Permit Submission:

Deadline to submit documents to building department

Construction Start:

Scheduled mobilization date for contractor

Final Delivery:

Date for final deliverables and closeout documents

Project Milestones: From Agreement to Closeout

A sequential milestone view clarifies what each party must deliver and when to avoid delays and claims.

01

Negotiation Complete

Contract terms agreed and exhibits finalized for signature

02

Contract Execution

Authorized signers sign and date the agreement

03

Design Submissions

Schematic and construction documents submitted per schedule

04

Closeout & Record

Deliver final documents, warranties, and record drawings

Common Preparation Mistakes to Avoid

  • Undefined scope or missing exhibits that allow differing expectations about deliverables and fees, often causing disputes.
  • Vague change-order processes that fail to specify pricing or approval authority and lead to unbilled work.
  • Incomplete signatory information or lack of proof of signing authority, which can delay enforcement or payment.
  • Failing to require current insurance certificates and licensure verification before work begins increases exposure to liability.

Consequences of an Incomplete or Incorrect Contract

Payment Disputes: Delayed or withheld payment
Schedule Delays: Extended completion and cost overruns
Liens Risk: Contractor claims may lead to mechanics’ liens
Regulatory Noncompliance: Permit denials or rework
Professional Liability: Increased claims against architect
Termination Exposure: Costs for early contract termination

Essential Information Every Contract Must Record

Owner: Full legal entity name
Architect: Firm name and license number
Project: Project name and address
Scope: Phases and key deliverables
Fees: Compensation structure
Insurance: Required coverage limits

eSignature Vendor Comparison for Executing Owner-Architect Contracts

Compare common vendor features and starting prices to choose a platform that supports audit trails, integrations, and required compliance.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day trial Varies by vendor Varies by vendor Varies by vendor Varies by vendor
Bulk Send Yes Yes Yes Yes Yes
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year Varies Varies Varies

Supporting Documents Commonly Attached to the Contract

Attach technical exhibits and compliance documents to the agreement to create a single authoritative project record.

Project Plans

Include full set of drawings and revisions as numbered exhibits so both parties reference identical documents during bidding and construction.

Specifications

Attach technical specifications and materials lists that govern workmanship standards and product selections on the project.

Insurance Certificates

Attach current certificates of insurance with the required limits and additional insured endorsements where applicable.

Schedule & Budget

Include a project schedule and cost estimate or schedule of values to coordinate payments and track milestones.

Real-world Examples of Using an Electronic Contract Workflow

These brief examples show how firms and owners executed contracts and preserved compliance using digital tools.

Optica Ventures (Brian Fitzgibbons)

Optica standardized its agreement templates and moved to online execution to reduce turnaround time.

  • The firm required signed exhibits for each project.
  • As a result, drafts were finalized faster and records were centralized for easy retrieval during construction closeout, reducing administrative delays.

Martin Properties (Tim Martin)

A small developer adopted digital signatures to execute architect agreements remotely.

  • Signatures were collected on mobile devices.
  • The company reported consistent compliance with licensing and insurance requirements while reducing in-person meetings and accelerating project starts.

Practical Tips for Accurate and Efficient Contract Completion

Adopt consistent naming, exhibit numbering, and signature conventions to reduce ambiguity and speed review cycles.

Use Consistent Legal Names
Always use the full legal names of entities and confirm signatory authority in corporate records to avoid unenforceability or payment delays.
Number Exhibits Clearly
Label all attachments with exhibit numbers and revision dates so the contract and plans remain synchronized throughout the project.
Document Change Orders
Require change orders to be written and signed with a defined pricing method to prevent disputes over scope and fees.
Retain Audit Evidence
Keep signed PDFs with audit trails and signer authentication records to preserve admissible proof of execution and consent.

Frequently Asked Questions About Owner-Architect Contracts

Answers to common execution, enforceability, and recordkeeping questions when preparing and signing an Owner-Architect Contract.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.