Pavers Installation Document

PAVERS INSTALLATION DOCUMENT

Parties and Recitals

This Pavers Installation Document (the Agreement) is entered into as of (Effective Date) by and between:

Client Name:    Site Address:

Contractor Name:    Contractor License #:

WHEREAS, Client desires that Contractor perform pavers installation, site preparation and related work at the Site Address described above; and

WHEREAS, Contractor represents that it possesses the skill, experience and licensing required to perform the work and will perform in accordance with the Scope of Work and standards described in this Agreement; and

WHEREAS, the parties desire to set forth the terms and conditions governing the installation, payment, warranties and other obligations in this Agreement.

Contact Information

Scope of Work

Contractor shall furnish all labor, materials, equipment and supervision necessary to complete the pavers installation work at the Site, including but not limited to site preparation, excavation, subbase preparation, edge restraints, laying pavers, jointing material, compaction and cleanup, as further described below.

Project Schedule

Commencement Date:    Estimated Completion Date:

Normal working hours will be . Contractor shall notify Client at least days in advance of start and of any material delays.

Payment Terms

Total Contract Amount: $

Late Payment: Amounts not paid within days of invoice shall accrue interest at or the maximum permitted by law, whichever is less.

Change Orders

Any change to the Scope of Work, materials or schedule shall be documented in a written change order signed by both parties, specifying price adjustment and time extension where applicable. Contractor shall not proceed with changed work until a signed change order is executed.

Permits, Site Conditions and Safety

Contractor shall obtain and pay for all required permits unless otherwise agreed. Client shall disclose known underground utilities and site conditions. Contractor is responsible for jobsite safety and shall maintain compliance with applicable safety regulations.

Warranties; Inspection

Contractor warrants that installed workmanship will be free from defects for a period of from completion. Manufacturer warranties for materials, if any, shall pass through to Client to the extent assignable. Client shall inspect work within days of completion and notify Contractor of any defect to be remedied.

Insurance and Indemnification

Contractor shall maintain commercial general liability and workers' compensation insurance in commercially reasonable amounts and provide evidence of insurance upon request. Contractor shall indemnify, defend and hold harmless Client from liabilities, claims or losses arising from Contractor's performance, except to the extent caused by Client's negligence.

Confidentiality

Each party shall keep confidential all non-public information obtained in connection with this Agreement and shall not disclose such information to third parties except as required by law or as necessary to perform the Work. Confidential information does not include information that is or becomes publicly known through no wrongful act of the receiving party.

Term and Termination

Term Start Date:    Term End Date:

Either party may terminate this Agreement for material breach if the breaching party fails to cure within days after written notice. Client may terminate for convenience upon days' written notice, subject to payment for work performed and materials ordered.

Governing Law; Dispute Resolution

This Agreement shall be governed by the laws of the State of without regard to conflict of law principles. Claims arising under this Agreement shall be submitted to the courts located in the same state unless the parties agree in writing to arbitration.

Entire Agreement; Severability

This Agreement, including any exhibits and signed change orders, constitutes the entire agreement between the parties and supersedes prior negotiations and representations. If any provision is held unenforceable, the remaining provisions shall remain in full force and effect.

Additional Provisions

Lien Waiver: Upon receipt of payments, Contractor shall provide lien waivers as requested. Contractor shall perform work in a professional manner and in accordance with customary industry standards.

Sign Now