Who must sign the form?

The authorized representative of each named contracting entity must sign. For companies, the signer should be an officer or agent with express authority; attach a corporate resolution if authority is unclear to avoid future enforceability issues.

Can the form be signed electronically?

Yes. Electronic signatures are valid under the ESIGN Act (15 U.S.C. ch.96) and UETA where adopted, provided intent, consent, attribution, and retention requirements are met. Confirm any consumer-facing disclosure obligations where applicable.

Is notarization required?

Not always. Notarization depends on state law and the document’s purpose. Some jurisdictions or specific filings require notarization or witness attestations; check local notary rules before assuming it's optional.

How do I fix an error after signing?

Do not alter the executed copy. Prepare an amendment or corrected form indicating the change, have all parties sign the amendment, and attach it to the original to preserve an auditable record for claims or audits.

How long should I keep signed forms?

Retain for the contract term plus applicable statutory periods: at least 3 years generally, 6 years for HIPAA-related documents (45 CFR §164.530(j)), and longer where state law or industry rules require.

How do I revoke or cancel a form?

Revocation requires agreement between parties or a contract clause permitting termination. Provide written notice per the form’s notice provisions, execute a termination amendment, and preserve records of the revocation for audit and claims prevention.

Electronic Signature
Templates
Miscellaneous
Project Liability Form

Project Liability Form

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

PROJECT LIABILITY FORM

Project Identification

Project Name Project Address / Location

Estimated Start Date: Estimated Completion Date:

Parties

Client Name Client Address Contractor / Vendor Name Contractor Address

Recitals

WHEREAS, Client Name: seeks to retain Contractor for work at the project identified above; and

WHEREAS, Contractor Name: represents that it has the skill, experience, personnel and insurance to perform the work in a professional manner; and

NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows:

Scope of Work

Detailed Scope

Payment Terms

Contract Amount: $

Payment Schedule / Milestones

Late Payment: A late fee equal to per month on past due amounts or the maximum permitted by law, whichever is less, plus reasonable collection costs.

Term and Termination

Term Commencement Date: Anticipated Termination Date:

Either party may terminate this Agreement for material breach if the breaching party fails to cure such breach within days after written notice. Termination for convenience by Client requires days' prior written notice and payment for work performed to date.

Insurance and Indemnification

Contractor shall maintain, at Contractor's expense, commercial general liability insurance with limits not less than $ per occurrence, workers' compensation as required by law, and automobile liability insurance where applicable. Certificates of insurance evidencing coverage shall be provided upon request.

Indemnification: Contractor agrees to indemnify, defend and hold harmless Client, its officers, employees and agents from and against all claims, damages, losses and expenses, including reasonable attorneys' fees, arising out of or resulting from Contractor's performance under this Agreement, provided such claim is caused in whole or in part by any negligent act or omission of Contractor, anyone directly or indirectly employed by Contractor, or anyone for whose acts Contractor may be liable.

Limitation of Liability

Except for Contractor's indemnification obligations and willful misconduct, neither party shall be liable to the other for consequential, incidental, special, or punitive damages. The aggregate liability of each party for direct damages under this Agreement shall not exceed the total amount paid to Contractor under this Agreement.

Confidentiality

Each party shall maintain in confidence all non-public information disclosed by the other party that is reasonably understood to be confidential ("Confidential Information") and shall not disclose such information to third parties except as required by law or with prior written consent. Confidentiality obligations survive termination for a period of three (3) years.

Safety; Compliance

Contractor shall perform all work in a safe manner and in compliance with all applicable federal, state and local laws, codes and regulations. Contractor shall be responsible for obtaining and maintaining any required permits or licenses.

Subcontractors and Changes

Contractor may engage subcontractors provided Contractor remains responsible for their performance. All material changes to scope, schedule or price must be authorized in a written change order signed by both parties prior to commencement of changed work.

Dispute Resolution and Governing Law

The parties shall attempt in good faith to resolve disputes promptly by negotiation. If unresolved, disputes shall be resolved by binding arbitration in the county where the Project is located, under the laws of the State of .

Entire Agreement; Severability

This Project Liability Form and any attachments constitute the entire agreement between the parties with respect to the subject matter and supersede all prior and contemporaneous agreements. If any provision is held invalid, the remainder shall remain in full force and effect.

Acknowledgment and Certification

The undersigned certify that they are authorized representatives of their respective parties, they have read and understand the terms of this Agreement, and that the information provided in this form is true and correct to the best of their knowledge.

Client Name:

By:

Date:

Contractor Name:

By:

Date:

What the Project Liability Form Is and when it applies

A Project Liability Form documents how liability, indemnity, and insurance responsibilities are allocated among parties working on a defined project. It identifies the contracting parties, scope of work, limits of liability, required insurance certificates, indemnity clauses, and signature blocks. Common in construction, professional services, and subcontracting arrangements, the form supports risk management, clarifies financial exposure, and becomes a contractual record when properly executed and retained under applicable electronic signature laws.

Why a clear Project Liability Form matters

A well-prepared Project Liability Form reduces ambiguity about who bears loss, documents insurance requirements, and helps prevent costly disputes. When signed in compliance with ESIGN (15 U.S.C. ch.96) and applicable state UETA rules, the form is admissible and enforceable as a written agreement.

Who typically completes or signs this form

Use the form whenever contractual liability or insurance allocation is material to project performance.

Project owners and developers who require proof of insurance and defined liability allocations.
General contractors and subcontractors who accept or assign indemnity and responsibility.
Risk managers, brokers, and insurers who verify coverage meets contract requirements.

Typical signer profiles and responsibilities

Project Manager

Responsible for collecting signed forms, ensuring certificates of insurance meet contract limits, and confirming that liability clauses are consistent with procurement and project risk policies. They coordinate between legal, procurement, and operations to avoid gaps.

Contractor

Signs to acknowledge indemnity, liability limits, and insurance obligations; must ensure subcontractors provide matching forms. Contractors should confirm name matching with W-9s and insurance endorsements to avoid coverage disputes.

Security and compliance considerations

Encryption in transit: TLS 1.2/1.3

Encryption at rest: AES-256

Audit records: SOC 2 Type II

Healthcare compliance: HIPAA (BAA required)

Regulatory standards: 21 CFR Part 11

Privacy frameworks: GDPR and CCPA compliant

Key risks from incorrect or incomplete forms

Coverage gap: Insurance may not respond

Unenforceable clause: Ambiguous indemnity language

Incorrect signer: Signature attribution dispute

Missing certificate: No proof of coverage

Late submission: Claims notice missed

ESIGN exception: Certain statutes exclude e-signing

Frequent preparation mistakes to avoid

Using informal or vague liability language that fails to identify limits, time frames, or triggers for indemnity obligations, creating room for differing legal interpretations.
Mismatched party names between the liability form, insurance certificate, and tax documents, which can void coverage or cause payment withholding.
Failing to require an insurance endorsement naming the contracting party as additional insured, leaving the obligee exposed in third-party claims.
Relying on generic templates without updating state-specific obligations, statutory exceptions, or project-specific insurance minimums.

Step-by-step: completing the Project Liability Form

Follow these steps to prepare, verify, and execute the form so it allocates risk clearly and legally.

01

Prepare: Gather contracts, insurance certificates, and W-9 information.
02

Identify parties: Enter full legal names and entity types exactly as on ID.
03

Define liability: Specify limits, exclusions, and indemnity triggers in plain terms.
04

Execute: Obtain signatures, dates, and any required notarization or witness attestations.

How to configure an online signing workflow

Recommended settings for digital completion and secure routing when using an eSignature platform.

Field	Configuration
Signature Authentication	Email link with optional SMS code or KBA
Conditional Fields	Show insurance fields only for subcontractors
Notifications	Automated reminders at 3 and 7 days
Retention Settings	Auto-archive signed copies to secure storage

Digital signing in four stages

A typical e-sign workflow reduces delay while preserving the legal record and audit trail.

Draft: Prepare the form and add required fields.
Upload: Upload to the signing platform and set signer order.
Authenticate: Signers verify identity and sign electronically.
Archive: Save completed form with audit trail and certificates.

Core elements of a professional Project Liability Form

A complete form includes identification, allocation of risk, and clear performance and insurance obligations tailored to the project.

Party Identification

Full legal names, entity types, addresses, and tax identification references to ensure correct attribution and to match insurance and payroll records.

Scope of Work

Concise project description and location details that limit liability exposure to the defined activities and timeline of the contract.

Liability Allocation

Clear clause assigning indemnity responsibilities, specifying whether liability is shared, severable, or limited to specified damages.

Insurance Requirements

Minimum coverage amounts, required endorsements, policy types, expiration handling, and any additional insured or waiver of subrogation terms.

Notice and Claims

Procedures and timeframes for providing notice of claims, including required documentation and contact information for claims handling.

Signature and Authentication

Designated signature blocks, signer authority statements, and notarization or witness requirements where legally necessary.

Platforms and integrations to support the form

Verify that your chosen system preserves audit trails, supports required authentication, and aligns with your retention policy.

Document formats: PDF, DOCX, or PDF/A
Common integrations: Salesforce, NetSuite, Microsoft 365
Storage options: Box, Google Drive, or enterprise S3

Typical deadlines and submission expectations

Project timelines and insurance start dates create fixed deadlines for completing and submitting the liability form.

Before mobilization:

Form and COI should be submitted prior to site work starting

Insurance effective date:

Coverage must be effective no later than the project start date

Subcontractor upload window:

Require subcontractor documents within 7 calendar days of onboarding

Claims notice deadline:

Provide written notice of claims within contract-specified period, often 30 days

Record retention:

Retain signed forms per corporate retention policy and regulatory requirements

Key milestones from drafting to archive

Milestones show the sequence from form creation through long-term retention and post-project review.

01

Draft Approval

Legal and risk teams review and approve clauses before issuance.

02

Execution

All parties sign and date the form; notarization if required.

03

Insurance Verification

Confirm endorsements and policy effective dates after signing.

04

Archive & Audit

Store signed copy and audit trail and schedule retention review.

eSignature vendor pricing snapshot for Project Liability Form workflows

Platform pricing and compliance options vary; place priority on audit trails, HIPAA support, and the required authentication level.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies by vendor	Varies by vendor	Varies by vendor	Varies by vendor
Bulk Send	Available on premium tier	Varies by plan	Varies by plan	Available	Varies by plan
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No

Real-world examples of form use and outcomes

These examples show how organizations use a Project Liability Form to reduce dispute risk and speed approval workflows.

Optica Ventures (Small Portfolio)

Optica standardized liability forms across projects to improve clarity for subcontractors and owners.

The change required consistent insurance endorsements from vendors.
As a result, claim processing time decreased and procurement could verify coverage remotely without repeated email exchanges, improving project onboarding efficiency over multiple sites.

Tech Data (Enterprise Integration)

Tech Data embedded liability forms into its contract lifecycle system for consistent risk allocation.

Integration automated certificate verification.
This reduced manual review, ensured matching endorsements, and helped legal enforce indemnity provisions without delaying go-live milestones across global vendor relationships.

Frequently asked questions about the Project Liability Form

Answers to common questions about signing, enforceability, notarization, and corrections to completed forms.

Need help? Contact support

Who must sign the form?
The authorized representative of each named contracting entity must sign. For companies, the signer should be an officer or agent with express authority; attach a corporate resolution if authority is unclear to avoid future enforceability issues.
Can the form be signed electronically?
Yes. Electronic signatures are valid under the ESIGN Act (15 U.S.C. ch.96) and UETA where adopted, provided intent, consent, attribution, and retention requirements are met. Confirm any consumer-facing disclosure obligations where applicable.
Is notarization required?
Not always. Notarization depends on state law and the document’s purpose. Some jurisdictions or specific filings require notarization or witness attestations; check local notary rules before assuming it's optional.
How do I fix an error after signing?
Do not alter the executed copy. Prepare an amendment or corrected form indicating the change, have all parties sign the amendment, and attach it to the original to preserve an auditable record for claims or audits.
How long should I keep signed forms?
Retain for the contract term plus applicable statutory periods: at least 3 years generally, 6 years for HIPAA-related documents (45 CFR §164.530(j)), and longer where state law or industry rules require.
How do I revoke or cancel a form?
Revocation requires agreement between parties or a contract clause permitting termination. Provide written notice per the form’s notice provisions, execute a termination amendment, and preserve records of the revocation for audit and claims prevention.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now