Project Management Battery Contract

PROJECT MANAGEMENT BATTERY CONTRACT

Project Identification

Project Title:

Contact:

Scope of Work

The Service Provider shall manage and deliver battery system project work as described in this Contract. Scope includes design coordination, procurement oversight, installation supervision, testing, commissioning, and project closeout as described below. Detailed scope must be performed in accordance with applicable codes and industry standards.

Deliverables and Acceptance

Deliverables will be completed and submitted according to the acceptance criteria below. Final acceptance requires written sign-off by the Client after successful completion of acceptance tests specified herein.

Due Date:

Due Date:

Timeline and Milestones

Project Start Date:    Project End Date:

Milestone 1 Date:

Milestone 2 Date:

Budget and Payment

Total Contract Price: $

Change Order Process

Any modification to the Scope, Schedule, or Price shall be effected only by a written Change Order signed by authorized representatives of both parties. Change Orders must describe changes in work, cost, and schedule, and include an acceptance signature from the Client prior to commencement of changed work.

Warranties and Remedies

The Service Provider warrants that services will be performed in a professional and workmanlike manner consistent with industry standards for a period of following acceptance. Remedies for breach of warranty shall include repair or replacement of defective work at the Service Provider's expense as the exclusive remedy, except for willful misconduct or gross negligence.

Liability, Indemnification and Insurance

Each party shall indemnify, defend and hold harmless the other party from third-party claims arising out of the indemnifying party's negligence or willful misconduct. Except for indemnification obligations and gross negligence, the parties' combined liability for direct damages shall not exceed the total contract price.

Confidentiality

Each party agrees that Confidential Information disclosed by the other party will be used solely to perform obligations under this Contract and will not be disclosed to third parties except as required by law. Confidential Information excludes information that is publicly known or rightfully obtained from a third party without restriction.

Force Majeure

Neither party shall be liable for delay or failure to perform to the extent caused by events beyond its reasonable control, provided the affected party gives prompt written notice and uses commercially reasonable efforts to mitigate the effect.

Dispute Resolution and Governing Law

The parties shall attempt in good faith to resolve disputes by negotiation. If unresolved within thirty (30) days, disputes shall be resolved by binding arbitration administered in the governing jurisdiction. This Contract shall be governed by the laws of the state of without regard to conflicts of law principles.

Termination

Either party may terminate for material breach if the breaching party fails to cure within thirty (30) days after written notice. Termination for convenience by the Client is permitted upon thirty (30) days' written notice, with payment for all work performed to date and reasonable demobilization costs.

Notices

Notices shall be delivered to the addresses below by hand, certified mail, or recognized courier and are effective upon receipt.

Additional Provisions

Relationship of the parties: The Service Provider is an independent contractor and not an employee, agent, or partner of the Client. The Service Provider shall be responsible for all taxes, benefits and insurance applicable to its personnel.

Acknowledgment

By signing below, the parties certify that they have the authority to enter into this Contract, that they have read and agree to all terms contained herein, and that this Contract constitutes the entire agreement between the parties with respect to the subject matter herein.

Sign Now