Establishing secure connection…Loading editor…Preparing document…

Project Management Contract Phase

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

PROJECT MANAGEMENT CONTRACT PHASE

Project Identification

Client Name:

Client Address:

Service Provider Name:

Project Manager (Provider):

Project Manager Contact:

Effective Date (Phase Commencement):

Recitals

This Project Management Contract Phase ("Phase Agreement") is entered into between Client Name: and Service Provider Name: . The parties agree that the Provider will perform the services described in this Phase Agreement under the terms and conditions set forth below.

Scope of Work

Deliverables and Acceptance

Deliverable 1 Description

Acceptance Period (days):

Deliverable 2 Description

Acceptance Period (days):

Timeline and Milestones

Phase Start Date:

Phase End Date:

Milestone 1 Due Date:

Milestone 2 Due Date:

Budget and Payment

Deposit Amount (if any):

Change Orders

All changes to scope, schedule or price shall be executed only by written change order signed by authorized representatives of both parties. Emergency work requested orally must be confirmed in writing within days. Contractor hourly rate for approved change orders:

Written change order required for any scope or price change

Confidentiality

Each party shall treat as Confidential Information all non-public information disclosed by the other party in connection with this Phase Agreement. Confidential obligations survive termination for years. Confidential Information does not include information that is or becomes public through no fault of the receiving party.

Intellectual Property

Ownership of Work Product: Unless otherwise agreed in writing, deliverables prepared specifically for Client under this Phase Agreement shall be the property of Client Service Provider Joint Ownership

Provider retains ownership of its underlying methodologies, tools, templates and pre-existing materials; Provider grants Client a non-exclusive license to use those materials as incorporated into accepted deliverables for Client's internal purposes.

Warranties; Liability; Indemnification

Provider warrants that services will be performed in a professional manner consistent with industry standards. EXCEPT AS SET FORTH ABOVE, NEITHER PARTY MAKES ANY OTHER WARRANTY, EXPRESS OR IMPLIED. IN NO EVENT SHALL EITHER PARTY'S AGGREGATE LIABILITY ARISING OUT OF OR RELATED TO THIS PHASE AGREEMENT EXCEED THE AMOUNTS PAID TO PROVIDER FOR THIS PHASE, PROVIDED THIS LIMITATION SHALL NOT APPLY TO LIABILITY ARISING FROM WILLFUL MISCONDUCT OR GROSS NEGLIGENCE.

Each party shall indemnify and hold harmless the other party from third-party claims arising from the indemnifying party's breach, negligence or willful misconduct, subject to the indemnified party providing prompt notice and reasonable cooperation in defense.

Termination

Either party may terminate this Phase Agreement for material breach if the breaching party fails to cure within days after written notice. Upon termination Client will pay Provider for work performed and approved deliverables through the termination date.

Dispute Resolution; Governing Law

The parties shall attempt in good faith to resolve disputes by negotiation. If unresolved, disputes shall be submitted to binding arbitration administered in accordance with the parties' election: Arbitration Mediation followed by Arbitration.

Governing Law: . Venue for any court action where permitted shall be the state or federal courts located in the governing jurisdiction.

General Provisions

Entire Agreement: This Phase Agreement, including any referenced change orders, constitutes the entire agreement between the parties with respect to the subject matter and supersedes prior agreements. Amendments must be in writing and signed by both parties. Notices shall be sent to the contact details provided above and are effective upon receipt.

Client:

By:

Date:

Service Provider:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Project Management Contract Phase Is and Why it Matters

The Project Management Contract Phase is the formal contractual stage where scope, deliverables, schedules, responsibilities, payment terms, change control, and acceptance criteria are documented and agreed by all parties. This phase converts project planning into legally binding obligations that govern execution, manage risk, and define performance metrics. Properly drafted contract-phase documents reduce ambiguity, set escalation and dispute resolution paths, and allocate liability for delays or defects. For many organizations this phase also triggers procurement, insurance, and compliance checks before work begins.

Why a Clear Contract Phase Improves Project Outcomes

A well-structured Project Management Contract Phase aligns stakeholders on scope, cost, schedule, and quality; reduces disputes; and creates enforceable responsibilities. Clear terms make invoicing, approvals, and change orders easier to execute and audit.

Why a Clear Contract Phase Improves Project Outcomes

Who Typically Prepares and Signs the Contract Phase Documents

Signatories usually include the authorized business representative, the contractor or vendor representative, and any required guarantors or funding authorities.

  • Project managers and PMO leads responsible for scope, schedule, and acceptance criteria.
  • Procurement and contracts teams that negotiate payment, warranties, and indemnities.
  • Legal counsel or in-house attorneys who review liability, IP, and dispute clauses.

Primary Signatory Roles and Typical Responsibilities

Authorized Representative

Chief contract signatory (title: CEO, CFO, VP of Contracts) who has corporate authority to bind the organization and approve financial terms; ensures contract aligns with procurement policy and budget.

Project Lead / Contractor

Operational signatory (title: Project Manager, Director of Services) who accepts scope, milestones, and deliverables; responsible for execution, reporting, and coordination with subcontractors or suppliers.

Core Sections to Include in a Project Management Contract Phase

A professional contract-phase document contains standard sections that make obligations clear, measurable, and enforceable across the project lifecycle.

Scope of Work

Define services, tasks, deliverables, and acceptance criteria in measurable terms; attach schedules, specifications, and exhibits to avoid ambiguity and scope creep.

Schedule & Milestones

List key dates, milestone acceptance tests, and dependencies; include liquidated damages or remedies for missed critical-path milestones when appropriate.

Payment Terms

Specify fees, invoicing cadence, retainage, milestone-based payments, and conditions for withholding payments due to defects or nonperformance.

Change Control

Describe the process to request, price, and approve changes including documentation, response times, and authority levels for approvals.

Warranties & Remedies

State warranty periods, correction obligations, and remedies such as repair, replacement, or price reductions for defective deliverables.

Risk Allocation

Include indemnities, insurance requirements, limitation of liability, force majeure, and dispute resolution procedures such as mediation or arbitration.

Step-by-Step: Completing the Contract Phase Document

Follow these sequential steps to prepare, review, and finalize the contract-phase agreement with minimal rework.

  • 01
    Draft Core Terms: Populate scope, schedule, payment, and change control sections.
  • 02
    Internal Review: Routing to legal, procurement, and finance for approval.
  • 03
    Negotiate Revisions: Track changes, confirm concessions, and update exhibits.
  • 04
    Execute and Archive: Collect signatures, distribute copies, and store originals securely.

How to Configure an Online Contract Phase Workflow

Set up a consistent digital workflow to reduce signer friction and ensure auditability.

Field Configuration
Signer Order Sequential or parallel routing per approval matrix
Authentication Email link, SMS code, or stronger KBA where required
Conditional Fields Show or hide sections based on role or selection
Audit Trail Capture timestamps, IPs, and signer actions automatically

Where to Send and How Documents Move After Signing

Understand routing and final destinations to ensure compliance and recordkeeping.

  • Contract Repository: Store executed copies in a centralized contract management system.
  • Finance / AP: Send executed contract to accounts payable for invoicing setup.
  • Project Team: Distribute relevant exhibits and acceptance criteria to delivery teams.
  • Legal Archive: Retain signed originals and redlines for audit and dispute defense.

Technical and Compliance Considerations for eSigning

Ensure the provider can meet retention, access control, and any industry-specific security requirements before finalizing the workflow.

  • Document Formats: PDF, DOCX, and fillable forms supported
  • Integrations: Works with common CRMs and cloud storage
  • Compliance: Supports ESIGN, UETA, and enterprise controls

Key Contract Phase Deadlines and Timing Expectations

Standard contract-phase timelines include execution, milestone start dates, acceptance windows, and notice periods that affect payments and remedies.

Execution Deadline:

Agree on effective date and sign by the specified contract execution deadline.

Milestone Starts:

Begin work within agreed days after effective date or specified kickoff.

Acceptance Window:

Define how many days reviewers have to accept or reject deliverables.

Change Order Response:

Set maximum days for pricing and approval of change requests.

Invoice Submission:

Specify when invoices are due after milestone acceptance (e.g., Net 30).

Major Project Milestones During the Contract Phase

A clear milestone sequence helps teams track progress and link payments to verified deliverables.

01

Kickoff

Contract executed and kickoff meeting scheduled.

02

Design Approval

Design deliverables reviewed and accepted by stakeholders.

03

Implementation

Work performed against agreed milestone schedule.

04

Final Acceptance

Formal acceptance, final payment, and warranty period begins.

Common Mistakes That Delay Contract Phase Completion

  • Vague scope language that leads to differing expectations and repeated amendments.
  • Missing authorization or incorrect signatory authority, which can invalidate the agreement.
  • Unclear acceptance criteria that leave deliverables open to subjective dispute.
  • Failure to include change control processes, producing unmanaged scope growth and cost overruns.

Risks and Penalties from Incorrect or Incomplete Contract Phases

Payment Disputes: Delayed or withheld payments
Liability Exposure: Broader indemnity or warranty obligations
Contract Invalidity: Enforceability issues from missing authority
Change Order Costs: Unplanned budget increases
Regulatory Breach: Noncompliance with industry rules
Litigation Risk: Increased legal fees and damages

eSignature Platform Pricing: Practical Comparison for Contract Signing

Compare common pricing and capability criteria across vendors to understand per-user and per-signature tradeoffs for contract-phase workflows.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial, no card required Yes, trial available Yes, trial available Yes, trial available Yes, trial available
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
Envelope Cap No cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Real-World Examples of Contract Phase Use

These short examples show how organizations use digital contract-phase workflows to close agreements and start work faster.

Optica Ventures — COO

Optica moved approvals online to reduce turnaround time and centralize records.

  • The team automated templates and routing for consistent reviews.
  • As a result they reduced signature time, improved customer convenience, and maintained a complete audit trail for investor and compliance reviews.

Martin Properties — Founder

Martin Properties used end-to-end digital signing for lease and contractor agreements to avoid in-person meetings.

  • Mobile signing enabled field closures.
  • This allowed continuous closing during offsite inspections, ensured compliance with document retention, and provided secure copies to tenants and vendors immediately after execution.

Essential Contract Data Elements to Capture and Protect

Party Names: Legal entity names
Effective Date: MM/DD/YYYY
Scope Reference: Exhibit and schedule IDs
Payment Terms: Currency and net days
Acceptance Criteria: Measurable tests
Signature Record: Timestamp and audit trail

Frequently Asked Questions About the Contract Phase

Answers to common questions about validity, signing, retention, and corrections during the Project Management Contract Phase.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.