Establishing secure connection…Loading editor…Preparing document…

Project Management D365 Services

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Project Management D365 Services

This Project Management D365 Services Agreement (the "Agreement") is made effective as of between Client Name: , Client Address: , and Service Provider: , Provider Address: .

Project Identification

Scope of Work

The Service Provider shall provide professional project management services specifically tailored to Microsoft Dynamics 365 (D365) implementation and lifecycle support. Services include project governance, schedule management, risk and issue management, stakeholder coordination, change control facilitation, and status reporting as further described below.

Deliverables and Acceptance

The Service Provider will deliver the items listed below. Each deliverable shall include acceptance criteria and an acceptance period during which the Client may review and either accept or provide written rejection with remedy requests.

Delivery Date:

Delivery Date:

Timeline and Milestones

Project Start Date:   Project End Date:

Milestone 1 Date:

Milestone 2 Date:

Budget and Payment

Fixed Price    Time & Materials    Milestone Based

Change Order Process

All changes to the Scope of Work shall be documented by a written change order signed by authorized representatives of both parties. Change orders shall include a description of the change, impact on schedule, additional cost (if any), and revised acceptance criteria.

Confidentiality

Each party shall treat all non-public information disclosed by the other party in connection with this Agreement as Confidential Information. Confidential Information shall not be disclosed to third parties and shall be used solely for performance under this Agreement. Confidential obligations do not apply to information that is publicly known or independently developed.

Intellectual Property and Deliverable Ownership

Unless otherwise agreed in writing, Service Provider grants Client a perpetual, non-exclusive, worldwide license to use deliverables created specifically for the Client under this Agreement. Pre-existing tools, templates, methodologies and intellectual property of the Service Provider remain the sole property of the Service Provider. Any transfer of ownership of developed source code or customizations will be documented in a separate assignment provision or statement of work.

Warranties; Limitation of Liability

Service Provider warrants that services will be performed with reasonable skill and care consistent with industry standards. EXCEPT AS EXPRESSLY PROVIDED HEREIN, NO OTHER WARRANTIES ARE PROVIDED. LIABILITY OF EITHER PARTY FOR DIRECT DAMAGES SHALL BE LIMITED TO THE TOTAL AMOUNT PAID BY CLIENT UNDER THIS AGREEMENT DURING THE PRIOR SIX (6) MONTH PERIOD; IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR CONSEQUENTIAL, INDIRECT, OR PUNITIVE DAMAGES.

Data Security and Compliance

Service Provider shall implement reasonable administrative, technical, and physical safeguards appropriate to the nature of Client data processed in performance of the services. Each party agrees to comply with applicable data protection laws and to notify the other promptly in the event of a data breach affecting Client data.

Termination

Either party may terminate this Agreement for material breach if the breach remains uncured thirty (30) days following written notice. Upon termination, Client shall pay Service Provider for all services performed and approved deliverables to the effective date of termination, and Service Provider shall deliver any work in progress.

Governing Law and Dispute Resolution

This Agreement shall be governed by the laws of the State of without regard to conflict-of-law principles. The parties shall first attempt to resolve disputes in good faith. If unresolved, disputes will be resolved by binding arbitration administered in the governing state unless the parties agree otherwise in writing.

Acceptance Testing

Client shall have calendar days from delivery of each deliverable to perform acceptance testing. If Client fails to provide written rejection within the acceptance period, the deliverable will be deemed accepted.

Miscellaneous

Notices under this Agreement shall be in writing and delivered to the addresses set forth above. Neither party may assign this Agreement without the prior written consent of the other, except to a successor by merger or sale of substantially all assets.

Client:

By:

Date:

Service Provider:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What Project Management D365 Services Covers

Project Management D365 Services describes a structured project documentation and workflow package designed for use with Microsoft Dynamics 365 and related project tools. It standardizes scope, schedule, roles, budgets, deliverables, and change-control procedures so teams can plan, execute, and audit projects consistently. The document framework supports integration with CRM and ERP systems, records approval events, and can be combined with electronic signatures and notarization where permitted to produce legally durable project agreements and client deliverables.

Why a Formal Project Management D365 Services Document Helps

A formal Project Management D365 Services document clarifies responsibilities, reduces scope disputes, preserves an auditable approval trail, and aligns project costing with billing. It supports regulatory and procurement requirements by documenting decisions and change orders, improving traceability for internal auditors and third parties while enabling consistent handoffs across teams and systems.

Why a Formal Project Management D365 Services Document Helps

Who Typically Uses Project Management D365 Services

Typical users span operational and commercial roles across client and vendor organizations.

  • Project Manager — Prepares project plan, resource allocation, milestones, and documents progress for stakeholders and sponsors.
  • Program Office — Sets standards, approves baseline changes, and enforces governance across multiple projects and portfolios.
  • Implementation Consultant — Maps D365 entities, configures workflows, and coordinates handoffs between technical and business teams.

These roles collaborate to maintain a single source of truth for schedules, budgets, and signed approvals.

Who Has Authority to Sign

Project Sponsor

Senior stakeholder authorized to commit budget and accept deliverables. Typical signatory for statements of work, budget increases, and major change orders; authority derives from internal delegation and procurement policies.

Implementation Lead

Operational signatory responsible for technical acceptance, configuration approvals, and testing sign-off. May sign acceptance certificates or technical change notices under delegated limits.

Essential Document Data Elements

Project Name: Unique title
Project ID: Internal identifier
Effective Date: Start date
Budget: Total approved amount
Scope Summary: Concise deliverables
Primary Stakeholders: Names and roles

Step-by-Step: Completing the Project Management D365 Services Document

Follow these core steps to prepare, approve, and record a Project Management D365 Services document in your project lifecycle.

  • 01
    Prepare draft: Populate fields and attach scope exhibits.
  • 02
    Assign reviewers: Notify stakeholders for technical and commercial review.
  • 03
    Collect approvals: Obtain signatures and record audit events.
  • 04
    Update systems: Link signed document to D365 project record.

How to Update or Revise an Existing Document

Use a controlled revision process to preserve version history, track approvals, and communicate changes to all stakeholders.

01

Version control:

Assign a new version number and record change author.
02

Change summary:

Summarize modifications and rationale for auditability.
03

Stakeholder notice:

Send revision notice with redline and impact.
04

Re-approval:

Obtain required signatures for amended terms.
05

Update D365:

Attach revised document to the project record.
06

Archive prior:

Retain previous version for the retention period.

How to Configure the Digital Approval Workflow

Map fields to workflow triggers and assign roles so approvals route automatically and actions are recorded in the project system.

Trigger event Project creation triggers SOW workflow
Approver role mapping PM, Sponsor, Legal sequenced approval
Notification method Email and in-app alerts enabled
Conditional routing Budget increases require finance approval
Final record Signed PDF saved to D365

Distribution and Platform Requirements

Confirm system integrations, file formats, and authentication options before sharing documents.

  • Integrations: Microsoft Dynamics 365, NetSuite, Salesforce
  • File formats: PDF and DOCX supported
  • Authentication: Email, SMS, or stronger methods

Ensure recipients can open the chosen file type and that authentication matches the transaction risk level.

Where to File, Send, and Archive the Document

A clear routing plan reduces processing time and ensures the executed document is discoverable for audits and billing.

  • Project record: Attach signed file to the D365 project.
  • Client copy: Send executed PDF to the client contact.
  • Legal retention: Store original in legal or contract repository.
  • Finance system: Link budget and billing to ERP records.

Key Components of a Professional Project Management D365 Services Document

A comprehensive document includes contractual, technical, scheduling, and financial elements to support execution, billing, and dispute resolution.

Scope of Work

Defines deliverables, acceptance criteria, and exclusions in clear, measurable terms so parties agree on what constitutes successful completion and avoid scope disputes.

Deliverables Schedule

Lists milestones, delivery dates, and dependencies with owner assignments and acceptance steps to enable progress tracking and tie payments to verified outputs.

Roles and Responsibilities

Specifies who performs tasks, who approves work, and escalation paths to reduce ambiguity and streamline decision-making during execution and change requests.

Budget and Billing

Details fixed fees or time-and-material rates, invoicing intervals, expenses policy, and payment terms to align accounting and cashflow expectations.

Change Control

Describes how changes are requested, estimated, approved, and documented so scope adjustments and associated cost or schedule impacts are managed consistently.

Acceptance Criteria

Provides objective tests, deliverable sign-off forms, or test scripts to establish when deliverables meet contractual requirements and trigger payment or closure.

How to Download, Export, and Attach Supporting Documents

Signed project documents should be exported in standard formats and paired with supporting exhibits, purchase orders, or test results for a complete record.

Export Formats

Save as PDF/A for long-term archival and as DOCX when edits are needed. Use PDF/A when retention or legal admissibility is a priority.

Attach Exhibits

Include SOW exhibits, technical specs, and bills of materials as separate attachments so reviewers can inspect referenced materials without altering the main contract.

Signed Copy

Store the certificate-of-completion or audit trail with the signed PDF to document signer identity, timestamps, and IP evidence for enforceability.

Archive Location

Place the final package in D365 contract repository or corporate contract management system for discovery and audit access.

Common Preparation Mistakes to Avoid

  • Using inconsistent project titles that create duplicate records and confuse reporting across finance and delivery systems.
  • Omitting effective dates or using ambiguous date ranges that delay milestone measurement and payment triggering.
  • Failing to list exclusions, which leads to repeated scope questions and time-consuming change orders during execution.
  • Not capturing approval limits for signatories, resulting in unsigned changes or unauthorized commitments to additional costs.

Risks and Consequences of Incorrect Documents

Contract Invalidity: May be unenforceable
Billing Disputes: Delayed or withheld payments
Scope Creep: Uncontrolled cost growth
Audit Findings: Noncompliance with policies
Regulatory Exposure: Industry penalties possible
Data Loss: Incomplete retention risks

Examples: How Organizations Use Project Management D365 Services

Real-world implementations highlight integration with ERP/CRM systems and the value of standardized, signable project documents.

Optica Ventures — COO

Optica standardized project documentation across its portfolio to reduce errors during handoffs.

  • "The interface is simple and easy-to-use for our team; more importantly, it is just as easy for our customers."
  • The change reduced turnaround time for executed agreements and improved client transparency during onboarding and delivery.

Xerox — Director of NetSuite Ops

Xerox integrated signed project agreements into ERP-backed billing processes for accurate invoicing.

  • "airSlate SignNow provides us with the flexibility needed to get the right signatures on the right documents, in the right formats."
  • Integration removed manual upload steps, reduced reconciliation efforts, and streamlined contract-to-cash workflows across departments.

eSignature Pricing and Feature Comparison for Project Documents

Comparing common vendor price points and core capabilities helps choose an eSignature option suited to project workflows and compliance needs.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies Varies Varies Varies
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No envelope cap 100 envelopes/user/year Varies Varies Varies

Typical Deadlines and Processing Expectations

Align project documentation with scheduled milestones, billing cycles, and approval SLAs to avoid payment delays or delivery gaps.

Kickoff and Baseline Approval:

Baseline schedule must be approved before work begins; typically within 7 business days of signature.

Milestone Reviews:

Monthly or milestone-based reviews, with acceptance within 10 business days of deliverable submission.

Invoicing Cycle:

Standard net 30 payment terms are common; confirm billing intervals in the contract.

Change Order Turnaround:

Estimate and approval often within 5–10 business days, depending on complexity.

Contract Renewal:

Begin renewal discussions at least 60 days before expiration to prevent service gaps.

Key Project Stages and Approval Milestones

A sequential milestone view helps stakeholders understand dependencies, approvals, and expected outputs at each stage.

01

Initiation

Define objectives, draft SOW, and secure sponsor approval.

02

Planning

Develop schedule, assign resources, and baseline scope.

03

Execution

Deliver milestones, conduct reviews, and manage changes.

04

Closeout

Complete acceptance, finalize invoicing, and archive records.

FAQs: Common Questions About Project Management D365 Services

Answers to frequent questions about legality, eSignature use, notarization, storage, and troubleshooting for project documents.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.