Establishing secure connection…Loading editor…Preparing document…

Project Management Development Services Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

PROJECT MANAGEMENT DEVELOPMENT SERVICES CONTRACT

Project Identification

Project Title:

Project ID:

Recitals

This Contract is entered into between Client Name: and Service Provider: .

The Provider will perform project management, development oversight, and delivery of specified deliverables pursuant to the terms and conditions set forth in this Contract.

Scope of Work

Deliverables and Acceptance

The Provider shall deliver the following deliverables. Each deliverable is subject to the acceptance procedure set forth below.

Due Date:    Responsible Party:

Due Date:    Responsible Party:

Timeline & Milestones

Project Start Date:    Project End Date:

Due Date:    Responsible:

Due Date:    Responsible:

Budget & Payment

Total Contract Value: $

Late Payment Penalty (if any):

Confidentiality

Each party shall maintain the confidentiality of Confidential Information disclosed in connection with this Contract. Confidential Information means non-public business, technical, financial or other information designated as confidential or that reasonably should be understood to be confidential. Confidential Information shall not include information that is or becomes publicly available through no fault of the receiving party, is already known by the receiving party without obligation of confidentiality, or is independently developed by the receiving party.

The receiving party shall use Confidential Information only to perform its obligations under this Contract and shall disclose Confidential Information only to employees, contractors or advisors who have a strict need to know and who are bound by confidentiality obligations no less protective than those herein.

Intellectual Property & Deliverable Ownership

Subject to Client’s timely payment of all amounts due, Provider assigns to Client all right, title and interest in Deliverables created specifically for Client under this Contract. Provider retains ownership of Provider's pre-existing materials and tools and grants Client a perpetual, non-exclusive license to any incorporated Provider materials necessary for Client's permitted use of the Deliverables.

Warranty; Acceptance Testing

Provider warrants that the Deliverables will materially conform to the agreed acceptance criteria for a period of thirty (30) days after acceptance. Client shall perform acceptance testing within fifteen (15) days of delivery and either provide written acceptance or a written list of deficiencies. Provider shall remedy deficiencies at no additional cost where such deficiencies constitute a breach of warranty.

Indemnification & Limitation of Liability

Each party agrees to indemnify and hold harmless the other party from claims, losses or liabilities arising from its negligent acts or willful misconduct in connection with this Contract. Except for liability arising from gross negligence, willful misconduct, or breach of confidentiality or intellectual property indemnities, the aggregate liability of either party shall be limited to the total amount paid or payable under this Contract during the preceding twelve (12) months.

Insurance

Provider shall maintain commercial general liability and professional liability insurance in amounts consistent with industry standards and provide certificates of insurance upon request by Client.

Force Majeure

Neither party shall be liable for delays or failures to perform caused by events beyond its reasonable control, including but not limited to acts of God, acts of government, natural disasters, pandemics, or labor disputes. The affected party shall notify the other party promptly and use reasonable efforts to mitigate the impact.

Termination

Either party may terminate this Contract upon thirty (30) days’ written notice for material breach that remains uncured at the end of the notice period. On termination, Client shall pay Provider for all work performed and accepted through the effective date of termination, plus reasonable wind-down costs incurred in accordance with the payment schedule.

Notices

Governing Law & Dispute Resolution

This Contract shall be governed by and construed in accordance with the laws of the State of without regard to conflict of law principles. The parties shall first attempt to resolve disputes through good faith negotiation. If unresolved, disputes shall be resolved by binding arbitration in the county of the Client’s primary place of business, except where injunctive relief is sought.

Representations & Authority

Each party represents that it has the full right, power, and authority to enter into and perform this Contract, and that execution and delivery of this Contract has been duly authorized by all necessary corporate or organizational action.

Entire Agreement

This Contract constitutes the entire agreement between the parties with respect to the subject matter and supersedes all prior discussions, proposals, and agreements. Any amendment must be in writing and signed by authorized representatives of both parties.

Client Printed Name:

By:

Date:

Service Provider Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What this Project Management Development Services Contract is

The Project Management Development Services Contract is a written agreement that sets out the scope, deliverables, schedule, payment terms, intellectual property allocation, change control, and acceptance criteria for project management services provided to a client. It defines responsibilities for the development of project plans, resource allocation, risk management, reporting cadence, and milestones so both parties understand performance expectations and remedies for nonperformance.

Why a clear contract matters for project management engagements

A well-drafted Project Management Development Services Contract reduces scope disputes, aligns expectations, and documents payment and termination triggers. When executed electronically it remains enforceable under federal ESIGN (15 U.S.C. ch.96) and state UETA frameworks, provided intent, consent, attribution, and retention requirements are met.

Why a clear contract matters for project management engagements

Who commonly prepares or signs this contract

Typical users include organizations hiring external project managers and vendors providing development or PMO services.

  • Internal PMO or Procurement Teams — Draft contracts to align vendors with internal delivery standards and oversight responsibilities.
  • Independent Project Management Consultants — Use the contract to scope services, set hourly or milestone billing, and protect IP rights.
  • Legal or Contracts Counsel — Review terms on indemnity, liability limits, and confidentiality clauses before execution.

Parties should confirm signatory authority and review state-specific notarization or witness rules when required.

Step-by-step: completing the contract correctly

Follow a concise sequence to prepare and execute the contract to avoid delays and disputes.

  • 01
    Prepare scope: Describe deliverables, acceptance criteria, and excluded work clearly.
  • 02
    Define schedule: List milestones, delivery dates, and dependencies with calendar dates.
  • 03
    Set payment terms: Specify amounts, invoice schedule, and late-payment interest.
  • 04
    Execute signatures: Obtain authorized signatures and retain the signed record.

Frequently asked questions about this contract

Answers to common execution, enforceability, and recordkeeping questions for Project Management Development Services Contracts.


Need help? Contact support

Vital clauses to include in a professional contract

Ensure the contract includes core protections and operational clauses that govern performance and remedies.

Scope

Precise description of services, milestones, deliverables, and exclusions so both parties share the same expectations and acceptance criteria.

Payment

Clear pricing, invoicing intervals, payment due dates, late fees, and any retainers or milestone-based releases to avoid disputes.

Change Control

Procedure for submitting, approving, pricing, and scheduling changes to scope; include authorization thresholds and impact on timelines.

Intellectual Property

Specify ownership or license grants for deliverables, preexisting IP, and developer contributions to avoid future ownership disputes.

Confidentiality

Define confidential information, permitted uses, duration, and required safeguards, including data protection obligations.

Liability & Indemnity

Limitations of liability, indemnity scope, and insurance requirements calibrated to project risk and regulatory obligations.

Security and compliance checkpoints to verify

Encryption in Transit: TLS 1.2/1.3
Encryption at Rest: AES-256
Audit Trails: Timestamped logs
HIPAA Support: BAA available
Regulatory Certifications: SOC 2 Type II
Accessibility: WCAG 2.0 AA

Key risks and penalties to watch for

Tax Withholding: 24% backup withholding
Information Returns: 1099 penalties apply
I-9 Violations: $281–$2,789 per violation
Breach Damages: Contractual liability limits
IP Misallocation: Loss of ownership rights
Data Exposure: HIPAA fines possible

Common mistakes to avoid when preparing the contract

  • Vague scope language that fails to list deliverables and acceptance criteria, leading to disputes over what 'completed' means.
  • Missing or incorrect party names and titles that complicate enforcement, payment, and tax reporting; always match legal entity names.
  • No change‑order process, which results in scope creep and unbilled work when additional tasks are assumed verbally.
  • Failure to specify data protection responsibilities and access rights, exposing parties to regulatory penalties under HIPAA or state privacy laws.

How to configure an online signing workflow

Configure fields, authentication, routing, and templates before sending to streamline execution and preserve an audit trail.

Field Configuration
Signature Fields Assign to specific signer roles with required date fields
Authentication Select email, SMS code, or KBA as needed
Routing Order Set sequential or parallel signer order
Integrations Connect to CRM or document storage

Digital signing and eSubmission considerations

Choose an eSignature platform that supports required authentication, audit trails, and file formats for your project documents.

  • File Formats: PDF, DOCX
  • Integrations: Salesforce, NetSuite
  • Authentication: Email, SMS, KBA

Ensure the selected platform can produce a tamper-evident signed PDF and maintain a reproducible audit trail to meet ESIGN/UETA and any industry compliance needs.

Typical contract dates and timing expectations

Track contractual and administrative dates to avoid missed milestones, payment delays, or statute issues.

Effective Date:

Date contract obligations commence; use MM/DD/YYYY.

Project Start:

Date work must begin per schedule or notice to proceed.

Payment Milestones:

Specify due dates for milestone-based invoices and retainers.

Termination Notice:

Number of days required for notice before termination.

Record Retention:

Retention period for executed contract and related invoices.

eSignature vendor pricing and capability snapshot

Comparison of starter pricing and key capabilities for common eSignature vendors; signNow is listed first per platform reference guidance.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial, no credit card required Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes (Business Premium) Depends on plan Depends on plan Depends on plan Depends on plan
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Real-world examples of use

Representative case notes showing how organizations use a Project Management Development Services Contract in practice.

Optica Ventures

Their PM team standardized a development services contract to reduce onboarding time by defining milestones and acceptance criteria.

  • The change clarified payment milestones.
  • The standardized form reduced disputes and accelerated approvals for subsequent projects across portfolios.

Martin Properties

A property manager used a PM services contract for renovation programs that required phased acceptance.

  • Phased acceptance prevented payment holds.
  • The contract coupled milestones with inspections and improved cash flow while limiting contractor claims.

Practical tips for accurate and efficient completion

Adopt standardized language and templates to reduce review cycles and ensure consistent risk allocation across projects.

Standardize templates
Maintain a master template with preapproved clauses to speed reviews and ensure consistent legal protections.
Use clear milestones
Define measurable acceptance criteria and associated deliverables to prevent subjective disputes and payment delays.
Specify communications
Include regular reporting cadence and escalation paths to keep stakeholders aligned and reduce scope drift.
Preserve audit trails
Capture execution metadata and store signed PDFs with a reproducible audit log for forensic and compliance needs.
be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.