Is an electronic signature legally binding?

Yes — electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. §7001) and UETA where adopted; ensure intent, consent, attribution, and retention requirements are met.

When is notarization required?

Notarization is only required if a statute or counterparty demands it (for recordable deeds or certain POAs). Check state law for specific instruments before attaching a notary block.

Can I use Remote Online Notarization (RON)?

Many states permit RON with identity proofing and audio-video recording; verify your state’s RON rules and the notary commission requirements before relying on remote notarization.

Who must sign to bind an organization?

A person with actual or apparent authority should sign. Confirm corporate signing authority by reviewing bylaws or board resolutions to avoid claims of unauthorized execution.

How do I revoke or amend the agreement?

Follow the amendment and termination clauses in the contract. Mutual amendment usually requires signed written consent; unilateral revocation may breach the agreement unless permitted by terms.

How should executed copies be stored?

Keep a secure, tamper-evident electronic copy with an audit trail and backup. Ensure retention meets IRS, HIPAA, or other applicable regulatory timelines.

Electronic Signature
Templates
Project Management
Project Management Superior Agreement

Project Management Superior Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

PROJECT MANAGEMENT SUPERIOR AGREEMENT

Project Identification

Project Title Project ID Client Name Service Provider Project Manager (Client) Project Manager (Provider)

Recitals and Definitions

This Project Management Superior Agreement (the Agreement) is entered into by the parties identified above for the purpose of defining the scope, deliverables, timeline, compensation, and governance applicable to the Project. The parties agree that the Provider shall perform project management services described herein and the Client shall pay for those services in accordance with the Budget and Payment Schedule.

Capitalized terms used in this Agreement shall have the meanings set forth in this Agreement. Unless otherwise defined, "Deliverable" means any tangible or intangible work product specified in the Deliverables section and accepted by the Client in accordance with the stated Acceptance Criteria.

Scope of Work

Scope of Work — Detailed Description Out-of-Scope Items

Deliverables and Acceptance

The Provider shall produce the following Deliverables. Each Deliverable is subject to the Acceptance Criteria set forth below; Client approval is required in writing for acceptance.

Deliverable 1 — Title Deliverable 1 — Description Deliverable 1 — Acceptance Criteria Deliverable 2 — Title Deliverable 2 — Description Deliverable 2 — Acceptance Criteria Deliverable 3 — Title Deliverable 3 — Description Deliverable 3 — Acceptance Criteria

Timeline and Milestones

The Provider shall perform services according to the following timeline and milestone schedule. Time is of the essence for milestone completion except where excused under Force Majeure.

Project Start Date Project End Date (Estimated) Milestone 1 — Name Milestone 1 — Target Date Milestone 1 — Deliverables / Acceptance Milestone 2 — Name Milestone 2 — Target Date Milestone 2 — Deliverables / Acceptance Milestone 3 — Name Milestone 3 — Target Date Milestone 3 — Deliverables / Acceptance

Budget, Fees and Payment Schedule

Client shall pay Provider for the Services in accordance with the following Budget and Payment Schedule. All amounts are stated in the currency agreed between the parties.

Total Contract Value Payment Schedule — Deposit Payment Schedule — Milestone Payments Payment Terms

Change Order Process

Any change in scope, schedule, deliverables, or price shall be documented in a written Change Order. No Change Order will be effective unless signed by authorized representatives of both parties. Change Orders shall specify the nature of the change, impact on schedule, additional fees, and revised acceptance criteria.

Change Order Lead Time Change Order Approval Authority

Confidentiality and Data Protection

Each party shall treat the other party's Confidential Information as strictly confidential and shall not disclose such information except as required by law. Confidential Information may only be used to perform obligations under this Agreement. Confidentiality obligations shall survive termination for the period set forth below.

Confidentiality Period (years)

Intellectual Property

Unless otherwise agreed in writing, Provider retains ownership of pre-existing intellectual property and methodologies. Client shall receive a perpetual, non-exclusive license to use Deliverables for internal business purposes upon full payment. Any third-party licensed software or components shall be identified and licensed separately.

Special IP Provisions

Liability, Indemnity and Insurance

Each party shall indemnify the other for claims arising from its negligence or willful misconduct. Except for liability arising from gross negligence or willful misconduct and indemnities, total liability of either party under this Agreement shall be limited to the amount paid by Client to Provider under this Agreement in the preceding twelve months.

Required Insurance

Termination and Suspension

Either party may terminate this Agreement for material breach if the breach is not cured within a reasonable cure period following written notice. Client may suspend work for convenience upon written notice; Provider shall be entitled to payment for work performed and reasonable demobilization costs.

Cure Period (days)

Force Majeure

Neither party shall be liable for delay or failure to perform to the extent such delay is caused by events beyond the reasonable control of that party, provided that the affected party gives prompt written notice and uses commercially reasonable efforts to resume performance.

Notices

All notices required or permitted under this Agreement shall be in writing and delivered to the addresses below by certified mail, courier, or email with confirmation of receipt.

Client Notice Address Client Notice Contact Provider Notice Address Provider Notice Contact

Governing Law and Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the jurisdiction specified below without regard to conflict of law principles. The parties shall attempt to resolve disputes through good-faith negotiations; unresolved disputes shall be resolved by binding arbitration unless the parties agree otherwise in writing.

Governing Law (State/Country) Dispute Resolution — Selected Method

Representations, Warranties, and Compliance

Each party represents and warrants that it has the full corporate power and authority to enter into this Agreement, that the execution and performance will not violate other agreements, and that it will comply with applicable laws and regulations in performing its obligations.

Regulatory or Compliance Notes

Miscellaneous Provisions

This Agreement, including any executed Change Orders and attachments, constitutes the entire agreement between the parties concerning the subject matter hereof and supersedes all prior agreements. Amendments must be in writing and signed by authorized representatives of both parties. If any provision is found invalid, the remaining provisions continue in full force and effect.

Attachments and Exhibits

Execution

The undersigned representatives certify that they are authorized to bind their respective parties to this Agreement and that by signing below the parties agree to be bound by the terms and conditions set forth above.

Client — Printed Name:

By:

Date:

Service Provider — Printed Name:

By:

Date:

What the Project Management Superior Agreement Is

The Project Management Superior Agreement is a formal contract that defines responsibilities, deliverables, timelines, and authority for project managers and supervising parties. It sets scope, acceptance criteria, change control, payment terms, and dispute resolution mechanisms so parties understand who makes decisions and how project milestones will be measured and accepted. The document is typically used by service providers, clients, and internal program offices to reduce ambiguity and create enforceable expectations for project governance and performance.

Why this agreement matters for project outcomes

A clear Project Management Superior Agreement allocates authority, minimizes scope disputes, and documents acceptance criteria and escalation paths. That clarity reduces delays, supports contract enforcement, and provides a defensible record for auditing and regulatory compliance under applicable law.

Who typically prepares and signs this agreement

Use this agreement when authority, milestones, and acceptance rules must be documented to reduce execution risk and provide a clear dispute-resolution path.

Project sponsors and executives responsible for funding and strategic decisions.
Program or portfolio managers who oversee multiple projects and set governance standards.
External contractors or vendors supplying project services and deliverables.

Core components to include in a professional agreement

A robust Project Management Superior Agreement combines scope, roles, timelines, acceptance, payment, and change control to create an auditable contract that supports project delivery and dispute resolution.

Scope

Define deliverables, exclusions, and measurable acceptance criteria so parties share one clear definition of 'done' for each milestone and deliverable.

Authority

Specify who has decision-making power, approval limits, and escalation steps to avoid conflicting directions and scope creep during execution.

Schedule

List key milestones, delivery dates, dependencies, and remedies for delay to support tracking and contractual remedies for missed deadlines.

Compensation

Detail payment terms, invoicing schedule, holdbacks, and acceptance-triggered payments to align financial incentives with successful delivery.

Change Control

Include a formal change-request process with approval criteria, impact assessment, and how cost or schedule adjustments are authorized.

Dispute Terms

Describe governing law, mediation/arbitration preferences, and remedies for breach to reduce litigation risk and clarify enforceability.

Step-by-step: completing the Project Management Superior Agreement

Follow these steps to prepare, review, and execute the agreement so it is complete, signed, and enforceable.

01

Draft: Populate fields, attach scope exhibits, and note pricing.
02

Review: Have legal and finance check terms, payment, and risk clauses.
03

Approve: Get authorized signers to confirm authority and sign.
04

Distribute: Share fully executed copies and store securely for retention.

Configuring a digital signing workflow for this agreement

Set a clear digital workflow with roles, field placement, and authentication so signers complete only required fields in the correct order.

Field	Configuration
Signer Order	Sequential or parallel based on approval hierarchy
Required Fields	Make names, dates, and signature blocks mandatory
Authentication	Email link or SMS code; use stronger methods for sensitive projects
Audit Trail	Enable full event logging and certificate of completion

Typical eSignature flow for contract completion

A standard eSignature flow reduces friction while capturing evidence of intent, identity, and consent required for enforceability.

Upload Document: Prepare final PDF or DOCX for signing
Assign Fields: Place signature, date, and initial fields
Send to Signers: Use ordered or parallel delivery
Capture Completion: Save signed copy plus audit trail

Technical and platform considerations for e-execution

Ensure the vendor offers compliant retention, optional notarization or RON workflows, and the ability to export a certificate of completion to support audits and legal reviews.

File Formats: PDF, DOCX supported
Integrations: CRM and storage connectors
Authentication: Email, SMS, or advanced MFA

Typical timelines and processing expectations

Identify milestone dates, payment triggers, and acceptance review windows so obligations and penalties for missed deadlines are clear to all parties.

Milestone Delivery Dates:

List dates for each milestone and acceptance period.

Acceptance Review Window:

Specify how many days the reviewer has to accept or reject deliverables.

Payment Trigger Dates:

Tie payments to accepted milestone sign-off.

Change Request Turnaround:

Define response times for scope or schedule changes.

Contract Termination Notice:

State required notice period to terminate the agreement.

Consequences and legal risks for incorrect or incomplete agreements

Contract Voidance: Incomplete signatures may render the agreement unenforceable

Payment Disputes: Vague consideration clauses lead to withholding or litigation

Scope Creep: Undefined deliverables increase cost and schedule risk

Regulatory Noncompliance: Failure to follow HIPAA or other rules can trigger penalties

I-9/Employment Risk: Incorrect onboarding documents violate 8 CFR §274a.2

Tax Exposure: Improper contractor classification can trigger IRS penalties

Common preparation mistakes to avoid

Leaving blank or optional signature fields that prevent clear attribution and raise enforceability questions.
Using ambiguous scope language such as 'as required' without objective acceptance criteria or measurable deliverables.
Failing to confirm signer authority, resulting in signatures from individuals without contractual power to bind a party.
Neglecting retention and audit-trail requirements that support dispute resolution and regulatory review.

eSignature vendor comparison for executing this agreement

Key commercial criteria for signing and storing Project Management Superior Agreements across platforms. signNow is listed first in the vendor comparison per platform ordering rules.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies	Varies	Varies	Varies
Bulk Send	Yes	Yes	Yes	Yes	Varies
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No

Frequently asked questions about execution and validity

Answers to common legal and operational questions about signing, notarization, revocation, and storage for this agreement.

Need help? Contact support

Is an electronic signature legally binding?
Yes — electronic signatures are generally enforceable under the ESIGN Act (15 U.S.C. §7001) and UETA where adopted; ensure intent, consent, attribution, and retention requirements are met.
When is notarization required?
Notarization is only required if a statute or counterparty demands it (for recordable deeds or certain POAs). Check state law for specific instruments before attaching a notary block.
Can I use Remote Online Notarization (RON)?
Many states permit RON with identity proofing and audio-video recording; verify your state’s RON rules and the notary commission requirements before relying on remote notarization.
Who must sign to bind an organization?
A person with actual or apparent authority should sign. Confirm corporate signing authority by reviewing bylaws or board resolutions to avoid claims of unauthorized execution.
How do I revoke or amend the agreement?
Follow the amendment and termination clauses in the contract. Mutual amendment usually requires signed written consent; unilateral revocation may breach the agreement unless permitted by terms.
How should executed copies be stored?
Keep a secure, tamper-evident electronic copy with an audit trail and backup. Ensure retention meets IRS, HIPAA, or other applicable regulatory timelines.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now