Can this waiver be signed electronically?

Yes. Electronic signatures are legally recognized under the federal ESIGN Act and state electronic transactions laws; ensure the signing process captures intent, consent, attribution, and retention for legal validity.

What makes a waiver enforceable?

A clear description of waived rights, evidence of consideration or mutual assent, authorized signatories, and an auditable record of signature and date increase enforceability in disputes.

Do I need a notary or witnesses?

Not usually for internal waivers, but some states or contract clauses may require notarization or witnesses. Check local requirements when dealing with property, durable powers, or state-specific formalities.

How do I revoke a waiver later?

Include a revocation clause that specifies notice method and timing; absent an express clause, revocation may be limited and could require mutual agreement or court intervention.

What records should I retain after signing?

Keep the signed document, audit trail, and any related correspondence for the retention period applicable to your industry and jurisdiction, such as IRS and HIPAA minimums where relevant.

How do I confirm signer authority?

Verify signers against corporate records or a valid ID, record titles and authorization, and, where necessary, obtain a corporate resolution or power-of-attorney confirming signing authority.

Electronic Signature
Templates
Project Management
Project Management Waiver Form

Project Management Waiver Form

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Project Management Waiver Form

Project Identification

Project Title Project ID Client Name Client Address Service Provider Project Manager Statement of Work Reference

Recitals

This Project Management Waiver Form ("Waiver") is entered into effective as of by and between the Client and the Service Provider identified above. The parties have agreed to modify certain rights and remedies under the Statement of Work identified above, and this Waiver sets forth the terms and scope of such modification.

Waiver Details

The Client hereby elects to waive, limit, or defer the following rights, claims, or requirements as specifically described and limited below. Waiver applies only as expressly stated and does not operate as a general release unless explicitly provided.

Select waiver type(s): Waiver of delay-related claims (time extensions or liquidated damages) Waiver of certain change order rights for specified scope Waiver or modification of payment milestones/conditions Conditional waiver of lien or claim for the specific deliverables identified Other (describe)

Scope of Waiver

Describe the specific work items, deliverables, milestones, or contract provisions subject to this Waiver. Include explicit start and end points for the waiver and list any exclusions.

Out-of-Scope Items (items not waived)

Consideration

The parties acknowledge that this Waiver is supported by adequate consideration as set forth below. If monetary or schedule consideration is provided, describe amounts and conditions.

Monetary Consideration Payment Schedule or Other Consideration

Deliverables and Acceptance Criteria

Identify deliverables subject to the Waiver and state specific acceptance criteria and acceptance process. Attach additional schedules if necessary.

Deliverable 1 - Title Deliverable 1 - Acceptance Criteria Deliverable 2 - Title Deliverable 2 - Acceptance Criteria

Timeline and Milestones

The waiver applies to the period commencing on and ending on unless earlier terminated in accordance with this Waiver.

Milestone 1 (description and date) Milestone 2 (description and date)

Budget and Financial Terms

Total Contracted Amount Adjustment to Budget or Payment Terms Resulting From Waiver Change Order Process (as modified, if any)

Representations, Warranties, and Limitations

Each party represents and warrants that it has the authority to enter into this Waiver and that the person signing on its behalf is duly authorized. The waiver granted herein is limited to the express matters stated and shall not be construed as a waiver of any other rights, claims, or remedies except to the extent expressly set forth in writing. Unless expressly specified, no waiver shall constitute a continuing waiver.

Indemnity

To the extent permitted by applicable law, the party receiving the benefit of this Waiver shall indemnify and hold harmless the other party from any third-party claims arising out of the beneficiary's breach of representations made in this Waiver or from use of the Waiver beyond the express scope provided.

Confidentiality

All non-public information disclosed in connection with this Waiver shall be treated as confidential and shall not be disclosed to third parties except as required by law or to enforce rights under this Waiver. Confidentiality obligations shall survive termination of this Waiver for a period of two years.

Governing Law and Dispute Resolution

This Waiver shall be governed by the substantive laws of the jurisdiction agreed upon by the parties. Except for injunctive relief, the parties agree to seek resolution of disputes arising under this Waiver through good faith negotiation followed by non-binding mediation. If mediation fails, disputes shall be resolved by binding arbitration in accordance with rules mutually selected by the parties.

Entire Agreement; Amendment

This Waiver constitutes the entire agreement between the parties with respect to the subject matter herein and supersedes all prior negotiations. Any amendment to this Waiver must be made in writing and signed by authorized representatives of both parties.

Acknowledgment

By signing below, each party acknowledges that it has read, understands, and agrees to be bound by the terms of this Waiver and that it has had the opportunity to obtain independent advice prior to execution.

Client:

By:

Date:

Service Provider:

By:

Date:

What the Project Management Waiver Form Is

A Project Management Waiver Form documents a party's voluntary relinquishment of specified project management rights, obligations, or claims for a defined scope or time. It is typically used to resolve scheduling, scope, or oversight disputes, to accept alternate procedures, or to confirm temporary delegations of responsibility without altering the underlying contract.

Why a Clear Waiver Matters for Projects

A properly drafted waiver reduces ambiguity about responsibilities, limits downstream disputes, and preserves audit trails for later review. It clarifies who retains decision authority, whether financial or schedule risks shift, and under what conditions the waiver expires or may be rescinded.

Who Commonly Completes This Waiver

Use the form to create a clear, signed record that can be referenced in disputes, audits, or closeout procedures.

Project managers and sponsors who need to document delegated authority or temporary scope changes.
Contractors and subcontractors asked to waive management-level oversight or accept alternate inspection schedules.
Legal, procurement, or compliance teams that require a signed record for audit or contract modification trails.

Core Parts of a Professional Waiver Form

A complete waiver combines identity, scope, effective dates, explicit waived rights, consideration, and signatures to ensure clarity and enforceability.

Parties

Full legal names and business entity types for all signatories, including authorized representative titles and contact details for post-signature notices.

Scope

A precise description of the tasks, approvals, or oversight being waived, including project identifiers, contract references, and any excluded activities.

Effective Period

Clear start and end dates or triggering events that define when the waiver applies and when normal responsibilities resume.

Consideration

A description of compensation, concessions, or mutual promises that support enforceability; state the amount or specific deliverables when applicable.

Limitations

Explicit exclusions, safety or regulatory obligations that remain unaffected, and any conditions under which the waiver becomes void.

Signatures

Designated signature blocks for each authorized signer, date fields, and optional witness or notary lines if the jurisdiction or parties require authentication.

Step-by-Step: Filling Out the Waiver

Complete fields in order to create a clear legal record and reduce back-and-forth with stakeholders.

01

Identify parties: Enter full legal names and contact details.
02

Define scope: Describe exactly what is being waived and any exclusions.
03

Set effective dates: Specify MM/DD/YYYY start and end or trigger event.
04

Execute signatures: Collect signatures, initials, witness or notary as required.

Typical Signing and Routing Flow

A standard digital workflow reduces delays and creates an auditable trail showing who signed, when, and under what authentication method.

Prepare document: Upload the waiver and place required fields.
Define signers: Add signer order and roles.
Authenticate signer: Choose email, SMS, or stronger methods.
Archive completed: Store signed copy and audit trail securely.

Typical Online Workflow Settings

Configure these settings for consistent routing, authentication, and recordkeeping when using a digital signing platform.

Field	Configuration
Signer Order	Sequential or parallel as needed
Authentication	Email link, SMS code, or KBA
Retention	Automatic archival with audit trail
Notifications	Reminders and completion alerts

Digital Signing and Integration Considerations

Select settings that meet legal and internal audit standards and ensure signed files are exported to your records system for long-term retention.

Authentication Options: Email, SMS, KBA, or stronger
Audit Trail: IP, timestamp, and action logs
Integrations: CRM and cloud storage links

Timing Considerations and Key Dates

Record the effective date, any interim review dates, and the termination or renewal dates so obligations and liabilities are clear over time.

Effective Date:

Date when the waiver takes effect (MM/DD/YYYY).

Interim Reviews:

Scheduled checkpoints for reassessing the waiver terms.

Expiry or Renewal:

When the waiver ends or conditions for extension.

Rescission Window:

Any period when parties may revoke the waiver.

Record Closure:

Date to finalize archival and retention actions.

Key Milestones from Draft to Archive

Track milestones sequentially to keep stakeholders aligned from draft circulation through final archival and post-project review.

01

Draft Approval

Internal review and modular edits before external distribution.

02

Signer Execution

All parties sign and date the document.

03

Post-Sign Review

Confirm obligations, distribute copies, and file in records.

04

Common Preparation Pitfalls to Avoid

Using vague scope language that fails to specify what is waived and what remains the responsibility of each party.
Collecting signatures without confirming authority or title, which can render the waiver unenforceable.
Failing to capture dates or trigger events precisely, leading to disputes about when the waiver applied.
Neglecting to retain an audit trail or signed copy in a secure repository for future audits or claims.

Risks and Possible Consequences of Errors

Enforceability Risk: Waiver found invalid

Liability Shift: Unexpected cost allocation

Contract Breach: Triggers dispute remedies

Insurance Gaps: Coverage may be denied

Regulatory Violation: Obligations remain despite waiver

Record Loss: Unable to prove consent

Security and Compliance Essentials

Encryption: TLS 1.2/1.3 in transit, AES-256 at rest

Audit Trail: Timestamp, IP, and action logs retained

HIPAA: BAA required for protected health data

21 CFR Part 11: Controls for FDA-regulated records

ESIGN / UETA: Legal recognition of electronic signatures

Certifications: SOC 2 Type II and ISO 27001 available

Typical eSignature Pricing and Feature Comparison

Compare common pricing and feature dimensions for sellers of eSignature services; signNow appears first per vendor ordering rules.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies	Varies	Varies	Varies
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No envelope cap	100 envelopes/user/year	Varies	Varies	Varies

Frequently Asked Questions and Practical Answers

Answers to typical questions about electronic execution, enforceability, signatures, and recordkeeping for Project Management Waiver Forms.

Need help? Contact support

Can this waiver be signed electronically?
Yes. Electronic signatures are legally recognized under the federal ESIGN Act and state electronic transactions laws; ensure the signing process captures intent, consent, attribution, and retention for legal validity.
What makes a waiver enforceable?
A clear description of waived rights, evidence of consideration or mutual assent, authorized signatories, and an auditable record of signature and date increase enforceability in disputes.
Do I need a notary or witnesses?
Not usually for internal waivers, but some states or contract clauses may require notarization or witnesses. Check local requirements when dealing with property, durable powers, or state-specific formalities.
How do I revoke a waiver later?
Include a revocation clause that specifies notice method and timing; absent an express clause, revocation may be limited and could require mutual agreement or court intervention.
What records should I retain after signing?
Keep the signed document, audit trail, and any related correspondence for the retention period applicable to your industry and jurisdiction, such as IRS and HIPAA minimums where relevant.
How do I confirm signer authority?
Verify signers against corporate records or a valid ID, record titles and authorization, and, where necessary, obtain a corporate resolution or power-of-attorney confirming signing authority.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now