Can the document be signed electronically?

Yes; electronic signatures are generally enforceable under the federal ESIGN Act, 15 U.S.C. ch. 96, and state UETA laws, provided intent, consent, attribution, and record retention are met. Exceptions include wills, certain court filings, and some real estate instruments.

Which form fields must be completed?

Common required fields include project title, effective date (MM/DD/YYYY), full legal parties with addresses, artwork file attachments, installation address, and signature blocks. Accurate TIN/vendor names may affect payments and tax reporting if applicable.

Does this document require notarization or witnesses?

Not generally required for standard wall graphics contracts, but state or client-specific requirements can mandate notarization or witness signatures for certain clauses or property access authorizations. Verify local notary rules or contract provisions before routing for final signature.

How do I download and store the signed document?

Save the fully signed PDF/A or equivalent PDF to your project records. Maintain an audit trail showing timestamps and signer attribution. Store copies in secure cloud storage with access controls and retain per retention policy, including backup and version control.

Can I use an eSignature provider for execution?

Yes; reputable eSignature platforms that comply with ESIGN and UETA provide enforceable signatures, audit trails, and secure storage. For healthcare or regulated projects, ensure HIPAA or 21 CFR Part 11 compliance as required by the project or contracting entity.

Who should be contacted for defects or disputes?

Identify the contract administrator and vendor representative in the Parties section. For installation defects, document issues with photos and notify the vendor per specified response times. Escalate unresolved issues to procurement or legal per the agreement's dispute resolution clause.

Electronic Signature
Templates
Project Management
Project Management Wall Graphics Project

Project Management Wall Graphics Project

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Project Management Wall Graphics Project

Project Identification

Project ID Client Name Client Contact (Name & Title) Client Address Service Provider (Company) Project Manager (Provider) Project Contact (Phone / Email)

Effective Date: Projected Start Date: Projected Completion Date:

Scope of Work

The Service Provider shall furnish all labor, materials, equipment, artwork production, surface preparation, installation and related services necessary to design, produce and install wall graphics as described herein. The work shall conform to the specifications and quantities set forth in this document and any appended attachments signed by both parties.

Detailed Scope of Work (deliverables, methods, materials) Out-of-Scope Items

Deliverables & Acceptance Criteria

Each deliverable must be accepted in writing per the Acceptance Criteria below. Acceptance testing will be limited to the specified acceptance procedures; approval must be provided within the stated review period or shall be deemed approved.

Deliverable 1 — Title Description

Due Date:

Acceptance Criteria Deliverable 2 — Title Description

Due Date:

Acceptance Criteria

Project Timeline & Milestones

Project Start Date Project End Date Milestone 1 — Title

Milestone 1 Due Date:

Milestone 1 Description Milestone 2 — Title

Milestone 2 Due Date:

Milestone 2 Description

Budget & Payment Terms

Total Project Cost Deposit / Initial Payment Payment Schedule (milestones, due on receipt, net terms) Billing and Invoicing Terms Change Order Process

Installation, Site Conditions & Permits

The Client shall provide reasonable site access, electricity where required, and confirm wall surfaces to be free of hazards. The Service Provider will inspect surfaces prior to installation and will notify the Client of any conditions that may affect adhesion or finish. Any additional surface remediation required beyond the agreed scope shall be considered a change order.

Site Access & Installation Requirements Permits and Approvals (responsibility)

Intellectual Property & Artwork

Unless otherwise agreed in writing, the Client grants the Service Provider a non-exclusive license to reproduce Client-provided artwork for the purposes of production and installation of the wall graphics. Final artwork created by the Service Provider for the Client will be transferred upon full payment unless otherwise specified. Any third-party licensing fees due to Client-supplied imagery remain the Client's responsibility.

Artwork Ownership/Transfer Notes

Warranty, Insurance & Indemnity

The Service Provider warrants workmanship for the period specified below. Warranty does not cover damage from third parties, misuse, environmental degradation beyond ordinary wear, or modifications by the Client or other contractors. Provider shall maintain commercial general liability insurance and workers' compensation as required by law; certificates will be provided upon request.

Warranty Period Insurance / Certificate Notes

Confidentiality

Both parties acknowledge that certain information exchanged in connection with this Project may be confidential. Each party agrees not to disclose confidential information to third parties and to use such information solely for the performance of its obligations under this Agreement, except as required by law.

Confidentiality Exceptions / Notes

Governing Law & Dispute Resolution

This Agreement shall be governed by the laws of the state specified below without regard to conflict of laws principles. The parties agree to attempt good-faith negotiation of any disputes prior to commencing litigation. If unresolved, disputes shall be resolved in the courts located in the chosen jurisdiction.

Governing State

Termination & Remedies

Either party may terminate this Agreement for material breach upon written notice if the breach is not cured within a reasonable cure period. Upon termination, Client shall pay for work performed to date and reasonable wind-down costs. Termination does not limit either party from seeking other remedies available at law or equity.

Termination Notice Requirements

Reporting, Meetings & Change Control

Regular project status reports and meetings shall occur at the cadence agreed below. All changes to scope, schedule or budget shall be documented via a written change order signed by both parties prior to commencement of changed work.

Reporting Cadence Primary Change Order Contact

Acknowledgment & Certification

By signing below, each party certifies that it has the authority to bind the entity for which it signs, that the information contained in this document is true and correct to the best of its knowledge, and that it accepts the obligations set forth herein.

Client:

By:

Date:

Service Provider:

By:

Date:

What the Project Management Wall Graphics Project Is

The Project Management Wall Graphics Project is a standardized scope-and-installation document used to plan, approve, and track large-format wall graphics and visual management displays for project environments. It consolidates design specifications, dimensions, materials, installation sequence, responsible parties, and acceptance criteria into a single record that guides vendors, installers, and project managers through procurement, fabrication, site preparation, and final inspection. The document is intended to reduce miscommunication, document change approvals, and serve as a record for warranty and maintenance obligations during the project lifecycle.

Why a Formal Wall Graphics Project Record Matters

Using a Project Management Wall Graphics Project consolidates responsibilities, documents design approvals, and creates a reproducible record that supports quality control, contract enforcement, and future maintenance planning while meeting electronic signature requirements under ESIGN and applicable state law.

Who Typically Uses This Project Document

Project managers, designers, installers, and procurement teams use the Project Management Wall Graphics Project to align scope, costs, schedules, and acceptance criteria before fabrication.

Project managers coordinating visual management and construction schedules across trades.
Designers documenting artwork specs, material finish, color codes, and mounting methods.
Installers confirming site conditions, substrate preparation, and field adjustments before sign-off.

Facilities, legal, and vendor teams reference the document for contract language, warranty obligations, and long-term maintenance planning after installation.

Step-by-Step: Complete the Project Management Wall Graphics Project

Follow this step-by-step process to complete the Project Management Wall Graphics Project accurately and maintain an audit trail for approvals.

01

Gather specifications: Collect dimensions, artwork files, materials, and installation constraints from stakeholders.
02

Prepare scope: Document actions, responsibilities, schedule, and acceptance criteria for each party.
03

Review & approve: Circulate for design and client approval; record approvals with date and name.
04

Finalize & archive: Confirm installation, capture as-built photos, and store signed record securely.

Security and Compliance Snapshot for Recordkeeping

Encryption: TLS 1.2/1.3 in transit; AES-256 at rest

BAA Available: HIPAA BAA available upon request

Audit Trail: Comprehensive timestamps, IP, action log

Certifications: SOC 2 Type II, ISO 27001, PCI DSS

Compliance: ESIGN, UETA, eIDAS, CCPA compliance

Access Controls: SSO, role-based permissions, 2FA options

Key Risks and Potential Consequences

Contract disputes: Claims for nonconforming work

Installation defects: Rework costs and schedule overruns

Tax/reporting exposure: Incorrect vendor data triggers withholding

Permit violations: Fines or stop-work orders

Safety noncompliance: OSHA citations and liabilities

Warranty invalidation: Unapproved changes void warranty

Common Preparation Errors to Avoid

Using low-resolution artwork or incorrect dimensions leads to fabrication errors that require costly reprints and delay installation schedules by days or weeks.
Failing to record approvals or version changes creates disputes over who authorized design or scope changes, complicating invoicing and warranty claims.
Omitting site access instructions or security requirements can cause installers to be denied entry or charged additional mobilization fees.
Not specifying acceptable tolerances, substrates, or mounting adhesives increases risk of failed adhesion or visible defects after installation.

Typical Routing from Design to Signed Completion

This flow outlines common routing from design approval through signed installation completion, including any required inspections and archival steps.

Upload: Attach design files, specs, and mockups for review.
Assign: Tag responsible parties and set due dates for each deliverable.
Approve: Collect signatures for artwork, materials, and installation plan.
Install: Confirm site prep, execute installation, and record as-built details.

Configuring an Online Workflow for the Project

Configure the online workflow to match approval order, notifications, and required attachments for the Project Management Wall Graphics Project.

Field	Configuration
Approval Order	Set signing sequence: reviewers, approvers, final signers.
Notifications	Enable email and in-app reminders at configurable intervals.
Required Attachments	Require artwork, proof of permissions, and permit documents before signing.
Authentication	Choose email link, SMS code, or KBA for signer verification.

Platform and Integration Considerations

Choose platforms that support PDF, DOCX uploads, SSO, API integration, and secure cloud storage to streamline approvals and archiving.

Formats: PDF, DOCX, HTML, Excel supported
Integrations: Salesforce, NetSuite, Microsoft 365, Google Workspace
APIs: REST API and webhooks for automation

Essential Components to Include in the Document

A professional Project Management Wall Graphics Project organizes specifications, responsibilities, and acceptance criteria so stakeholders can execute fabrication and installation with minimal ambiguity and clear accountability.

Scope

Define precise dimensions, placement, permitted color tolerances, and any exclusions. Include reference elevations, mounting heights, and whether graphics cross seams or require special edge treatments to ensure accurate fabrication.

Artwork Specs

Reference file formats, color profiles, font licensing, vector requirements, and acceptable file naming conventions. State preferred file transfer methods and checksum or proofing steps to reduce versioning errors.

Materials

Specify substrate type, UV resistance, flame rating, finish, adhesive type, and expected lifespan. Include manufacturer data sheets and testing requirements for adhesion and colorfastness under expected conditions.

Installation Plan

Detail site prep, anchoring methods, environmental controls, required equipment, crew size, and sequencing with other trades. Include contingency plans for unexpected substrate conditions, safety permits, staging, and fall-protection requirements.

Acceptance Criteria

Define measurements, surface finish tolerances, color matching thresholds, inspection checklists, acceptance photos, and criteria for remedial work. Specify sign-off authority and timeline for defect reporting and correction.

Change Control

Use a formal change-order process capturing requestor, description, cost impact, approval signatures, and schedule adjustments. Track revisions in a version-controlled log attached to the primary document to avoid disputes.

Important Dates and Deadlines to Track

Key calendar dates govern production lead time, permit applications, and coordinated installation windows; recording them prevents schedule conflicts.

Artwork submission deadline (final files):

Final approved files must be submitted at least 21 days before fabrication.

Fabrication start date (estimated production):

Begin fabrication after artwork approval and any required permits are issued.

Installation window including staging and inspections:

Schedule installs during declared site-access hours; allow buffer for weather or trade conflicts.

Punchlist submission and inspection deadline:

Punchlist items documented at install must be corrected within the specified warranty period.

Final acceptance and warranty commencement:

Signed acceptance marks project completion and starts any warranty timelines and final payment terms.

eSignature Pricing and Capability Comparison

Compare common eSignature pricing and capability dimensions relevant when executing the Project Management Wall Graphics Project.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies by plan	Varies by plan	Varies by plan	Varies by plan
Bulk Send	Yes (Business Premium+)	Yes (plan dependent)	Yes (plan dependent)	Yes (plan dependent)	Yes (plan dependent)
Audit Trail	Yes	Yes	Yes	Yes	Yes
Envelope Cap	No cap	100 envelopes/user/year	Varies by plan	Varies by plan	Varies by plan

FAQs: Signing, Filing, and Storing the Project Record

Common questions about completing, signing, and storing the Project Management Wall Graphics Project are answered below to reduce errors and processing delays.

Need help? Contact support

Can the document be signed electronically?
Yes; electronic signatures are generally enforceable under the federal ESIGN Act, 15 U.S.C. ch. 96, and state UETA laws, provided intent, consent, attribution, and record retention are met. Exceptions include wills, certain court filings, and some real estate instruments.
Which form fields must be completed?
Common required fields include project title, effective date (MM/DD/YYYY), full legal parties with addresses, artwork file attachments, installation address, and signature blocks. Accurate TIN/vendor names may affect payments and tax reporting if applicable.
Does this document require notarization or witnesses?
Not generally required for standard wall graphics contracts, but state or client-specific requirements can mandate notarization or witness signatures for certain clauses or property access authorizations. Verify local notary rules or contract provisions before routing for final signature.
How do I download and store the signed document?
Save the fully signed PDF/A or equivalent PDF to your project records. Maintain an audit trail showing timestamps and signer attribution. Store copies in secure cloud storage with access controls and retain per retention policy, including backup and version control.
Can I use an eSignature provider for execution?
Yes; reputable eSignature platforms that comply with ESIGN and UETA provide enforceable signatures, audit trails, and secure storage. For healthcare or regulated projects, ensure HIPAA or 21 CFR Part 11 compliance as required by the project or contracting entity.
Who should be contacted for defects or disputes?
Identify the contract administrator and vendor representative in the Parties section. For installation defects, document issues with photos and notify the vendor per specified response times. Escalate unresolved issues to procurement or legal per the agreement's dispute resolution clause.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now