Establishing secure connection…Loading editor…Preparing document…

Project Management Website Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Project Management Website Contract

This Project Management Website Contract (the "Agreement") is entered into as of (Effective Date), between Client Name: with address (Client), and Service Provider: with address (Service Provider).

Project Identification

Scope of Work

Service Provider shall perform project management, design coordination, development oversight, quality assurance, deployment coordination, and related services to deliver a website (the "Work") in accordance with the deliverables, milestones, and acceptance criteria set forth in this Agreement. Services shall conform to professional standards and the specifications described below.

Deliverables and Acceptance Criteria

The Service Provider will deliver the following items. Each deliverable must satisfy the stated acceptance criteria. Acceptance will be deemed given if Client does not provide a written rejection stating specific nonconformities within the stated acceptance period.

Timeline and Milestones

Project timeline and milestone schedule are as follows. Dates listed are target dates; any material change to the schedule shall be processed as a change order.

Budget and Payment

Client shall pay Service Provider the fees set forth below in accordance with the payment schedule. All fees are due in U.S. dollars and are exclusive of taxes unless otherwise stated.

Payment Method:

Change Order Procedure

Any changes to the Scope of Work, deliverables, fees, or schedule shall be documented in a written change order. No change order shall be effective unless signed by authorized representatives of both parties. Change orders may affect price and schedule; revised estimates will be provided in writing and require Client approval prior to commencement of changed work.

Confidentiality

Each party shall keep confidential all nonpublic information disclosed by the other party in connection with this Agreement and shall not use such information except for performance under this Agreement. Confidential information does not include information that is or becomes generally known to the public other than through a breach of this Agreement. Confidentiality obligations shall survive termination of this Agreement for years.

Intellectual Property Rights

Unless otherwise agreed in writing, Service Provider assigns to Client all right, title, and interest in deliverables created specifically for Client under this Agreement upon full payment. Service Provider retains ownership of preexisting tools, methodologies, libraries, and components and grants Client a nonexclusive, perpetual license to any such preexisting intellectual property embedded within the deliverables to the extent necessary to use the deliverables.

Warranties, Support, and Maintenance

Service Provider warrants that the Work will materially conform to the specifications for a period of days after acceptance. During the warranty period, Service Provider will, at its expense, remedy reported defects that cause nonconformity. Ongoing maintenance and support, if required, shall be provided under a separate statement of work or support agreement as set forth below.

Limitation of Liability

Except for breaches of confidentiality and indemnification obligations, in no event shall either party be liable to the other for incidental, consequential, special, punitive, or exemplary damages. The aggregate liability of Service Provider arising out of or related to this Agreement shall be limited to the total fees paid by Client to Service Provider under this Agreement during the month(s) preceding the claim or , whichever is greater.

Termination

Either party may terminate this Agreement for cause if the other party materially breaches any obligation and fails to cure within days after written notice. Upon termination for convenience by Client, Service Provider shall be paid for services performed and work in progress through the effective date of termination, subject to applicable offsets.

Indemnification

Service Provider shall indemnify, defend and hold harmless Client from and against third-party claims alleging that the deliverables infringe third-party intellectual property rights, provided that Client gives Service Provider prompt written notice of any such claim and permits Service Provider to control the defense and settlement of the claim. Client shall indemnify Service Provider for claims arising from Client-provided materials or specifications.

Force Majeure

Neither party shall be liable for delays or failures in performance caused by events beyond its reasonable control, including natural disasters, acts of government, labor disputes, or events of war, provided that the affected party promptly notifies the other party and uses commercially reasonable efforts to resume performance.

Insurance

Service Provider shall maintain commercial general liability insurance with limits not less than and professional liability/errors & omissions insurance with limits not less than . Certificates of insurance shall be provided upon request.

Governing Law and Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the State of , without regard to choice-of-law principles. The parties agree to attempt to resolve disputes in good faith through negotiation or mediation prior to initiating litigation. If unresolved, disputes shall be resolved in the state or federal courts located in the governing state.

Taxes and Expenses

Unless otherwise stated, prices exclude taxes. Client shall be responsible for all sales, use, value-added or similar taxes arising from the transactions contemplated by this Agreement, excluding taxes based on Service Provider’s net income. Reimbursable expenses must be preapproved in writing and will be invoiced in accordance with the payment schedule.

Acceptance Procedure

Upon delivery of each deliverable, Client shall have days to test and provide written acceptance or detailed rejection with reasons. If Client does not provide written notice within the acceptance period, the deliverable shall be deemed accepted.

Miscellaneous

This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes prior proposals, communications and understandings. Any amendment must be in writing and signed by authorized representatives of both parties. If any provision is held unenforceable, the remainder shall remain in full force and effect.

Contact Information for Notices

Signatures

Client Printed Name:

By:

Date:

Service Provider Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Project Management Website Contract Is

A Project Management Website Contract is a written agreement that defines the scope, deliverables, timeline, payment terms, change control, intellectual property assignment, and acceptance criteria for a website project. It allocates responsibilities between the client and the vendor, describes milestones and review cycles, and sets dispute resolution and governing law. For web projects this contract reduces ambiguity about deliverables such as design, development, hosting, integrations, and maintenance, and creates a basis for invoices, change orders, and legal enforcement if performance or payment issues arise.

Why a Clear Contract Matters for Website Projects

A clear contract minimizes scope disputes, speeds approvals, clarifies payment timing, and documents acceptance criteria and intellectual property ownership to protect both parties under applicable U.S. laws such as ESIGN and state contract law.

Why a Clear Contract Matters for Website Projects

Typical Parties Who Prepare or Sign This Contract

The contract is commonly prepared by project managers, web development agencies, in-house product teams, and outside counsel to align expectations before work begins.

  • Project managers and product owners who direct scope, milestones, and acceptance criteria
  • Web development agencies or freelance contractors who deliver design, code, and testing
  • Legal or procurement teams responsible for risk allocation, IP, and payment terms

Each party should confirm authority to bind their organization and ensure the contract is signed by an authorized representative with clear dates and version control.

Who Signs and Why

Project Manager

A project manager signs to confirm acceptance of scope, milestones, and testing procedures on behalf of the client organization. Their signature ties the timeline and acceptance criteria to internal release schedules and procurement controls, and signals operational responsibility for approvals and change-order requests.

Agency Owner

An authorized officer or owner of the vendor signs to accept delivery responsibilities, warranty terms, and IP assignment provisions. This signature binds commercial promises including hosting, maintenance windows, and liability caps, and permits invoicing and royalty or license arrangements specified in the contract.

Essential Sections to Include in a Professional Contract

A well-structured Project Management Website Contract addresses scope, schedule, payment, testing, intellectual property, and dispute resolution. Each section should be specific to reduce later ambiguity.

Scope of Work

Describe deliverables, accepted file formats, platform integrations, third-party services, and exact functionality to be delivered so both parties have a shared baseline for acceptance and change management.

Payment Terms

Specify total price, milestone payments, invoicing schedule, late payment interest, retainers, and responsibility for third-party costs to avoid payment disputes and cash-flow issues.

Timeline & Milestones

List kickoff date, milestone deadlines, review periods, and final acceptance criteria. Include window for client reviews and consequences for delayed approvals to preserve schedule predictability.

Change Control

Define how scope changes are requested, estimated, approved, and priced. Require written change orders signed by authorized representatives before implementation.

Intellectual Property

State whether code, designs, and content are transferred, licensed, or retained. Include work-for-hire language or IP assignment clauses and exceptions for open-source components.

Warranties & Liability

Include limited warranty period for defects, support obligations, liability caps, indemnities, and dispute resolution mechanisms such as arbitration or courts and governing law.

Required Information and Security Considerations

Parties: Full legal names of client and vendor
Addresses: Street address, city, state, ZIP
Contact Details: Primary email and phone for contract notices
Payment Info: Billing address and payment method details
Signature Data: Signer name, title, and signature date
Security: Encryption, access controls, and data handling requirements

Step-by-Step: Completing the Contract

Follow these steps in sequence to prepare, review, and execute the contract so both parties have a clear record and approved change process.

  • 01
    Gather Documents: Collect SOW, proposals, exhibits, and prior agreements for consistent attachment and reference.
  • 02
    Define Milestones: Set measurable deliverables, review windows, and acceptance tests tied to payments.
  • 03
    Legal Review: Have counsel review IP, indemnities, and liability limits before final approval.
  • 04
    Execute Signatures: Sign in the correct order, date the signatures, and retain the executed version for records.

How Electronic Execution Typically Works

Digital signing and routing can streamline execution. The basic workflow for e-signature use is straightforward and audit-ready when done correctly.

  • Upload Document: Add the finalized contract file (PDF or DOCX) to the signing platform.
  • Place Fields: Insert signature, date, and initial fields for each signer in the proper order.
  • Send to Signers: Deliver the document via email link or secure signing portal to the specified signers.
  • Sign and Archive: Signers complete fields, platform captures audit trail, and final PDF is saved for retention.

Typical Digital Workflow Settings for This Contract

Configure authentication, field behavior, reminders, and file formats to match your organization’s compliance and operational needs.

Field Configuration
Authentication Email link or SMS code for signer verification
Field Types Signature, Date, Initials, Checkbox, Text
Conditional Fields Enable for optional exhibits or payment terms
Reminder Schedule Automatic reminders at 3, 7, and 14 days

Technical Considerations for eSigning and Sharing

Verify platform integrations, supported file types, accessibility, and authentication options before eSigning to ensure compliance and usability.

  • Integrations: Salesforce, NetSuite, Google Workspace, Box, Procore support
  • File Formats: PDF, Word DOCX, HTML, Excel supported
  • Accessibility: WCAG 2.0 Level AA compatible workflows

Common eSignature Pricing and Feature Comparison

Compare basic pricing and key features for typical eSignature vendors. signNow is listed first per platform ordering guidelines.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial (no CC) Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Supporting Documents and Export Options

Attach exhibits and choose export formats that preserve signatures and metadata for long-term storage and auditability.

Required Exhibits

Attach SOW, technical specifications, hosting SLA, acceptance tests, and pricing schedule as numbered exhibits for clarity and enforceability.

Export Formats

Save executed contracts as PDF/A where possible to preserve signatures and audit trails for long-term retention and legal admissibility.

Audit Trail

Ensure the signing platform provides time-stamped logs with IP, signer email, and action history for evidentiary support.

Version Control

Label each revision and include amendment clauses that require written signed change orders to prevent oral modification disputes.

Key Dates to Set and Track in the Contract

Define precise dates for project milestones, payment due dates, warranty periods, and termination notice windows to avoid disputes and missed obligations.

Effective Date:

MM/DD/YYYY format; contract obligations begin on this date

Kickoff Date:

Project commencement date tied to initial deliverables and resource allocation

Milestone Deadlines:

Specify deliverable due dates and client review windows for each milestone

Payment Due Dates:

Tie invoicing to milestone acceptance and specify net terms

Termination Notice:

Specify advance notice required, typically 30 days unless otherwise agreed

Milestone Sequence from Proposal to Final Acceptance

A typical project follows discrete stages; map these milestones and associated acceptance criteria to payment triggers to maintain alignment.

01

Proposal & SOW

Define the scope, deliverables, and pricing before any work begins.

02

Project Kickoff

Agree on timeline, resources, and communication cadence to start development.

03

Milestone Reviews

Complete iterative reviews with formal acceptance or documented change requests.

04

Final Acceptance

Complete user acceptance testing, sign-off, and closeout deliverables for final payment.

Common Mistakes to Avoid

  • Vague scope descriptions that invite scope creep and disputes
  • Missing acceptance criteria which delay final payment and launch
  • No change-order process leading to unpaid additional work
  • Incorrect signer authority causing enforceability issues

Consequences of an Incorrect or Incomplete Contract

Payment Disputes: Delayed or withheld payments
IP Ambiguity: Ownership disputes over code or designs
Regulatory Risk: HIPAA or data-handling violations if applicable
Contract Voidance: Enforceability challenges from improper signatures
Operational Delays: Missed deadlines and extended launch windows
Legal Fees: Higher costs for litigation or dispute resolution

Practical Tips for Accurate and Fast Completion

Adopt consistent practices to reduce approval cycles, avoid rework, and make the contract easier to manage over the project lifecycle.

Standardize Templates
Use a single vetted template with modular exhibits to speed review and ensure consistent protections across projects.
Define Acceptance Tests
Create objective acceptance criteria and test cases to avoid subjective sign-off disputes and align development with client expectations.
Limit Open-Ended Language
Avoid terms like 'reasonable efforts' without definition; specify measurable outcomes, delivery formats, and performance thresholds.
Use Version Control
Number contract revisions, date each version, and require sign-off for amendments to preserve a clear audit trail.

Real-World Examples of How Teams Use This Contract

These examples show how parties adapt the contract to project size, integrations, and compliance needs.

Optica Ventures (COO)

A small venture firm standardized the contract for repeat website builds to reduce negotiation time by 50%

  • They used clear milestone payments to manage cash flow during development
  • The firm retained the executed PDFs and audit trails to speed invoicing and to resolve a later scope dispute without legal escalation.

Martin Properties (Founder)

A real estate company used the contract for tenant portal development with defined MLS integration exhibits

  • The contract included data handling and third-party API clauses
  • This approach prevented ambiguous responsibilities during go-live and helped the company meet local disclosure requirements while maintaining a clear support SLA.

FAQs and Troubleshooting When Using the Contract

Answers to common questions about signing, enforceability, retention, and digital workflows for Project Management Website Contracts.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.