Establishing secure connection…Loading editor…Preparing document…

Project Progress Release

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

PROJECT PROGRESS RELEASE

Parties and Project

Project Name:

Project Address:

Client Name:    Contractor Name:

Recitals

WHEREAS, Client has contracted with Contractor for certain construction, renovation or related services at the Project described above; and

WHEREAS, Contractor has performed a portion of the Work and requests release of progress payment in accordance with the parties' agreement; and

WHEREAS, Client is willing to make the progress payment subject to the conditions and certifications set forth in this Project Progress Release.

Scope of Work

Progress Summary

Percent Complete:   Subcontractor and Supplier Paid to Date:

Payment Terms

Retainage Withheld:   If checked, Retainage Percentage:

Late Fee for Overdue Payment:    Payment Due Within (days):

Term and Termination

Term Start Date:   Term End Date:

Either party may terminate this Release for material breach upon written notice delivered to the non-breaching party. Notice Period (days):

Release, Waiver and Certifications

Upon receipt by Contractor of the Payment Amount described above, Contractor hereby releases and forever discharges Client, its agents, employees and lenders from any and all claims, demands, liens, causes of action and liabilities for Work performed and materials supplied through the date of payment, except for latent defects, expressly retained claims set forth in writing, or items excluded herein. This release applies only to the portion of the Work specifically described in the Scope of Work of this Release.

Contractor certifies that, to the best of Contractor's knowledge, all subcontractors, laborers and suppliers who have furnished labor or materials for the portion of the Work covered by this Release have been paid or will be paid from the funds received pursuant to this Release, and Contractor will provide lien waivers from applicable subcontractors and suppliers upon request.

Confidentiality

Each party agrees that proprietary pricing, schedules, trade secrets and other confidential business information disclosed in connection with this Release shall be kept confidential and shall not be disclosed to third parties except as required by law or with prior written consent of the disclosing party. Confidential information does not include information that is or becomes public other than as a result of a breach of this paragraph.

Governing Law

This Release shall be governed by and construed in accordance with the laws of the jurisdiction where the Project is located. Jurisdiction and venue for any dispute shall lie in the courts of that jurisdiction.

Governing Jurisdiction:

Entire Agreement

This Release, together with any documents expressly incorporated herein, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous agreements, representations and understandings, whether oral or written. No amendment or waiver shall be effective unless in writing and signed by both parties.

Additional Provisions

Client

Client Printed Name:

By:

Date:

Contractor

Contractor Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Project Progress Release Is and Why It Matters

A Project Progress Release is a written document used to record and confirm that a party has completed specified project work or reached a contract milestone and consents to release certain claims, payments, or lien rights tied to that progress. Typically used in construction, professional services, and project finance, the release identifies the project, the milestone or percentage complete, the parties, effective date, consideration or payment amount, and any conditions for future draws or retainage. When signed by authorized representatives and retained with agreement records, it creates a clear, auditable record of progress, payment triggers, and any waiver or reservation of rights under the contract.

How the Project Progress Release Reduces Disputes and Clarifies Payments

A clear release aligns expectations about work completed, payment amounts, and remaining obligations, reducing later disputes and accelerating draw processing.

How the Project Progress Release Reduces Disputes and Clarifies Payments

Typical Parties Who Prepare or Sign a Project Progress Release

Common users include contracting parties, project owners, lenders, and construction managers responsible for milestone verification.

  • Contractors and subcontractors verifying completed scope and accepting milestone payments, protecting against future lien claims.
  • Owners, developers, and project managers documenting acceptance of work and authorizing payment or release of retainage.
  • Lenders, sureties, and disbursing agents confirming that draws meet contract conditions before releasing funds.

Different users focus on distinct items: contractors on payment and retainage, owners on acceptance, lenders on draw conditions.

Core Elements to Include in a Professional Project Progress Release

A complete release is concise but specific: identify parties, scope completed, payment or credit, effective date, applicable reservations, and signature authority.

Parties

List full legal names and roles (payer, payee, owner, contractor) so the release binds the correct corporate or individual entities.

Scope

Describe the milestone, work completed, or percent complete clearly and tie it to contract line items, change orders, or schedule references.

Consideration

State the payment amount, retainage withheld, or credit applied; specify currency and whether amounts are gross or net of prior draws.

Effective Date

Provide the date the release takes effect; this determines when rights are waived and the start of any challenge or dispute window.

Reservations

If the party reserves specific claims (e.g., latent defects, incomplete punch list items), state those exceptions precisely to avoid ambiguity.

Authority

Include signer name, title, corporate capacity, and any required notarization or witness information to confirm signing authority.

Required Data Fields and Record Elements

Project ID: Contract or project number
Party Names: Full legal entity names
Milestone Date: MM/DD/YYYY format
Payment Amount: Dollar amount, specify net/gross
Signature Block: Signer name and title
Notary Info: If required by jurisdiction

Step-by-Step: Completing a Project Progress Release

Follow these sequential steps to prepare, review, and execute a valid release document.

  • 01
    Prepare draft: Populate project, milestone, and payment fields accurately.
  • 02
    Internal review: Legal and finance confirm obligations and reservations.
  • 03
    Obtain signatures: Authorized representatives sign; notarize if jurisdiction requires.
  • 04
    Distribute copies: Share executed copies with owner, contractor, lender, and records.

Configuring an Online Workflow for the Release

A digital workflow ensures consistent routing, authentication, and record retention when executing releases electronically.

Field Configuration
Signature Type Electronic signature with audit trail
Authentication Email link or SMS two-factor
Routing Order Sequential: contractor → owner → lender
Retention Policy Store signed PDF with certificate for minimum retention period

Where to Send or File the Executed Release

After execution, distribute copies to all stakeholders and retain a signed record in your contract management system.

  • Owner / Developer: Primary recipient for payment authorization and project records.
  • Contractor / Subcontractor: Keeps copy for payment proof and lien defense.
  • Lender / Escrow Agent: Receives copy to release draws or update disbursement schedules.
  • Records / PMO: Retain certified PDF and audit trail in project files.

Digital Signing and File Format Requirements

Confirm that chosen software can produce a complete certificate of completion, export ISO-compatible signed PDFs, and meet industry compliance such as ESIGN, UETA, and HIPAA when applicable.

  • Formats Supported: PDF, DOCX, and editable templates
  • Integrations: Connectors for NetSuite, Salesforce, Procore, Google Workspace
  • Security Controls: TLS 1.2/1.3 in transit; AES-256 at rest

Key Deadlines and Timing to Track

Track milestone dates, payment due dates, statutory challenge periods, and any lender-imposed draw deadlines.

Milestone Completion Date:

Date work was inspected and accepted by owner

Payment Due Date:

Date payment must be remitted per contract terms

Lien Challenge Window:

Typically 30–90 days to dispute a waiver depending on contract

Retention Release Date:

Date when retained funds become payable if conditions are met

Record Retention Start:

Effective date from which retention period is measured

Project Progress Release: Typical Milestone Workflow

Sequence the release through drafting, verification, signing, and distribution so each milestone triggers the correct financial action.

01

Draft Release

Populate project and payment details and attach supporting invoices.

02

Verify Work

Owner or inspector confirms milestone completion and signs acceptance.

03

Execute Release

Authorized parties sign electronically or in person; notarize if required.

04

Disburse Funds

Lender or owner releases payment per contract and updates draw schedule.

Common Preparation Errors and How They Cause Delays

  • Vague scope descriptions that do not reference contract line items often lead to disputes and payment holds.
  • Mismatched party names or signer titles can invalidate a release or require re-execution and delay disbursement.
  • Failure to note reservations for incomplete punch-list items may be interpreted as a full waiver of future claims.
  • Not aligning release language with lender draw conditions can prevent escrow from releasing funds on schedule.

Risks and Consequences of Incorrect or Incomplete Releases

Payment Delay: Funds withheld until correction
Lien Exposure: Incomplete waiver may not prevent lien filings
Contract Breach: Risk of claims for improper waiver
Tax Withholding: Incorrect payee details may trigger backup withholding
Notarization Failure: Improper notary undermines enforceability
Signature Invalidity: Unauthorized signer may void the document

Real-World Examples of Using a Project Progress Release

These examples show how organizations document milestones and collect signatures efficiently while preserving legal protections.

Martin Properties

Martin Properties used a progress release to authorize a draw after final inspection

  • Signed on mobile and offline quickly to avoid delays
  • "I can process and execute all of these documents online with 100% compliance and built-in security. Whether on mobile or working offline, I can get forms back to their necessary parties efficiently."

Optica Ventures LLC

A development firm standardized releases to reduce review cycles

  • Template tied releases to change orders to prevent disputes
  • "The interface is simple and easy-to-use for our team; more importantly, it is just as easy for our customers."

Practical Tips to Prepare Accurate and Enforceable Releases

Adopt clear drafting conventions, controlled templates, and consistent digital workflows to reduce rework and legal risk.

Use Standardized Templates
Maintain a single approved template with placeholders for project ID, milestone, amounts, reservations, and signature blocks to ensure uniformity and reduce interpretation disputes.
Confirm Signer Authority
Verify the signer's corporate authority and include a capacity statement; require a corporate resolution when necessary to prevent later challenges to authority.
Document Supporting Evidence
Attach inspection reports, pay applications, change orders, and lien waiver forms so the release is backed by the documented basis for acceptance and payment.
Preserve an Audit Trail
Use an eSignature solution that records timestamps, IP addresses, and signer authentication events and store the certificate with the signed PDF for evidentiary use.

eSignature Pricing Comparison for Executing Project Progress Releases

Compare basic plan costs and capabilities to choose a solution that supports bulk sends, audit trails, HIPAA compliance, and envelope limits where relevant.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial, no card required Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

FAQs and Troubleshooting for Project Progress Releases

Answers to common questions about enforceability, notarization, corrections, and electronic execution to help avoid execution pitfalls.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.