Establishing secure connection…Loading editor…Preparing document…

Real Estate Combined MSA

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REAL ESTATE COMBINED MSA

This Real Estate Combined Master Services Agreement ("Agreement") is made effective as of by and between the parties identified below. This Agreement sets forth the terms and conditions under which Owner shall retain Service Provider to perform services for the Property described herein.

Parties

Property Identification

Scope of Services

Service Provider shall perform the services described below at the Property in accordance with the terms of this Agreement. Specific work orders, scopes, and schedules shall be issued as Exhibits or written work orders signed by both parties and shall be governed by this Agreement.

Term; Termination

Term: This Agreement shall commence on and shall continue until unless earlier terminated in accordance with this Agreement.

Either party may terminate for convenience with thirty (30) days' prior written notice. Either party may terminate immediately for material breach if such breach is not cured within fifteen (15) days after written notice of default. Termination does not relieve the parties of obligations that by their nature survive termination.

Compensation; Invoicing

Invoices are due within days of receipt. Late payments shall incur a late fee of or interest at the lesser of 1.5% per month or the maximum lawful rate.

Insurance; Indemnity

Service Provider shall maintain at its sole cost and expense commercial general liability insurance, automobile liability insurance, and workers' compensation as required by law. Minimum limits: Commercial general liability, $1,000,000 per occurrence; automobile liability, $1,000,000 combined single limit. Certificates evidencing coverage shall be delivered to Owner upon execution and upon renewal.

Indemnification: Service Provider shall indemnify, defend and hold harmless Owner, its officers, agents and employees, from and against all claims, liabilities, losses, costs and expenses (including reasonable attorneys' fees) arising out of or resulting from Service Provider's performance of services, except to the extent caused by Owner's gross negligence or willful misconduct.

Disclosures

The parties represent and warrant the following known conditions relating to the Property. Owner shall promptly disclose any material change in these conditions to Service Provider.

Compliance; Permits

Service Provider shall perform all services in compliance with applicable federal, state and local laws, codes and regulations and shall obtain all permits, licenses and approvals required to perform the services, unless otherwise agreed in writing that Owner will obtain specified permits.

Default; Remedies

Upon a material default, the non-defaulting party may pursue any remedy available at law or in equity, including specific performance, monetary damages and termination. The parties agree that irreparable harm may occur and that injunctive relief may be appropriate in certain circumstances.

Confidentiality; Records

Each party shall keep confidential all nonpublic information received from the other party and shall not disclose such information except as required by law or as necessary to perform obligations under this Agreement. Service Provider shall maintain records of services and expenses and shall provide Owner with reasonable access to such records upon request.

Assignment; Subcontracting

Neither party shall assign this Agreement without the prior written consent of the other, which consent shall not be unreasonably withheld. Service Provider may subcontract portions of the work provided that Service Provider remains responsible for subcontractor performance and compliance with this Agreement.

Notices

All notices must be in writing and delivered by personal delivery, nationally recognized overnight courier, or certified mail, return receipt requested, to the addresses below or to such other address as a party may designate by written notice.

Dispute Resolution; Governing Law

The parties shall attempt in good faith to resolve disputes arising under this Agreement through negotiation. If unresolved within thirty (30) days, disputes shall be submitted to mediation. If mediation fails, the parties agree to binding arbitration administered by a neutral arbitrator in the county where the Property is located, unless the parties mutually agree otherwise. The prevailing party in any dispute shall be entitled to recover reasonable attorneys' fees and costs.

This Agreement shall be governed by and construed in accordance with the laws of the State of , without regard to its conflict of laws rules.

Entire Agreement; Amendment

This Agreement, including all exhibits and mutually executed work orders, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings. Any amendment must be in writing and signed by authorized representatives of both parties.

Miscellaneous Provisions

If any provision of this Agreement is held invalid or unenforceable, the remaining provisions shall remain in full force and effect. The parties acknowledge that they have had the opportunity to seek independent legal counsel and that this Agreement is the result of negotiation between parties of equal bargaining power, unless otherwise indicated below.

Signatures

Owner (Printed Name):

By (Signature):

Date:

Service Provider (Printed Name):

By (Signature):

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Real Estate Combined MSA Is

The Real Estate Combined MSA is a consolidated Master Services Agreement used to document recurring commercial real estate services between a property owner or manager and one or more service providers. It bundles standard terms—scope of services, payment, indemnity, insurance, warranties, change orders, dispute resolution, and termination—into a single framework that supports multiple projects, leases, or maintenance engagements. The document reduces repetitive negotiation by establishing baseline obligations and pricing, while allowing task-specific statements of work to attach as exhibits or work orders.

Why use a Combined MSA for real estate operations

A Real Estate Combined MSA centralizes recurring terms to save drafting time, reduce negotiation cycles, and standardize risk allocation across transactions. It provides clarity for billing, insurance, change management, and dispute procedures while enabling flexible project-specific work orders.

Why use a Combined MSA for real estate operations

Who typically drafts, approves, or signs this agreement

Typical parties who draft, approve, or sign this agreement include property owners, asset managers, property management firms, and service contractors.

  • Property owners and real estate investors managing multiple assets nationally.
  • Property management companies coordinating maintenance, vendors, and leasing services daily.
  • General contractors and specialty vendors providing recurring site services and repairs.

Legal counsel, procurement teams, and accounting departments typically review the MSA before execution to confirm compliance and payment terms.

Representative user profiles

Owner/Investor

Typically a portfolio owner or investor who delegates contract management to an asset manager; reviews insurance, indemnity, and payment schedules. Requires a single document controlling multiple projects to reduce legal fees and expedite vendor onboarding across properties.

Property Manager

Operates day-to-day vendor relationships, issues work orders, and enforces performance standards; needs clear change order, approval thresholds, and billing procedures. Seeks an MSA that allows rapid procurement while preserving owner-directed indemnities and insurance requirements.

Required core information and fields

Parties: Legal names and entity types
Effective Date: Enter as MM/DD/YYYY format
Scope of Services: Detailed tasks, deliverables, and locations
Payment Terms: Rates, billing cycle, and late fees
Insurance: Coverage types and minimum limits
Exhibits / SOW: Attach work orders and pricing exhibits

Common preparation pitfalls to avoid

  • Using vague scope language that leads to disputes over which services are included, increasing change orders and project delays.
  • Failing to specify insurance minimums or certificate requirements, resulting in uncovered risks and payment holds when incidents occur.
  • Omitting clear invoicing schedules and approval thresholds, which causes billing disputes and slows accounts payable processing.
  • Using inconsistent governing law or venue provisions across attachments, complicating dispute resolution and increasing litigation costs.

Potential legal and financial risks

Breach Damages: Liability for direct and consequential losses
Insurance Gap: Claims denied for inadequate coverage
Payment Delays: Withheld payments pending dispute resolution
Mechanic's Lien Risk: Contractors can record liens
Tax Reporting: Incorrect 1099 treatment triggers penalties
Notarization Issues: Invalid execution in some jurisdictions

Core contract sections to include in the Real Estate Combined MSA

A professional Real Estate Combined MSA covers contractual backbone items and modular attachments so parties can attach project-specific Statements of Work or schedules without renegotiating core terms.

Scope and SOWs

Define the general scope and permit multiple Statements of Work as exhibits. Each SOW should specify site addresses, milestones, deliverables, acceptance criteria, pricing, and a clear change-order mechanism tied back to the MSA.

Payment & Billing

Specify fee schedules, invoicing cycles, late-payment interest, retainage, and approval process. State whether pricing is fixed, time-and-materials, or unit-rate; include dispute resolution for disputed invoices and withholding remedies.

Insurance & Indemnity

Set minimum insurance types and limits, certificate requirements, additional insured endorsements, and indemnity allocation. Address third-party claims, defense obligations, and how subrogation or waiver of subrogation will be handled.

Change Management

Establish written change order requirements, authorization thresholds by dollar value or role, pricing adjustments, and time impacts. Clarify emergency procedures for critical repairs and after-hours approvals.

Termination & Remedies

Describe termination for convenience and cause, cure periods, obligations on termination, final accounting, and surviving clauses. State liquidated damages only where enforceable under governing law.

Compliance & Records

Include representations about licenses, permits, regulatory compliance, and recordkeeping. Require access for inspections, retention periods for invoices and safety records, and confidentiality obligations for tenant data.

Step-by-step: completing the Real Estate Combined MSA

Follow these steps to complete and execute a Real Estate Combined MSA efficiently with internal approvals and exhibit attachments.

  • 01
    Gather Parties: Collect legal names, entity types, and authorized signers.
  • 02
    Define Scope: Attach SOWs with deliverables, timelines, and locations.
  • 03
    Set Financials: Agree fees, billing cycles, retainage, and invoice approval.
  • 04
    Execute & Archive: Sign, notarize if required, and store executed copies.

How signatures and distribution typically flow

Routing the executed MSA ensures correct file distribution and generates an audit trail for compliance and future amendments.

  • Upload Document: Start with a final draft in PDF or DOCX.
  • Assign Signers: Designate signer roles and order, include witnesses.
  • Authenticate: Choose email, SMS, or advanced signer verification.
  • Distribute Copies: Deliver executed copies to stakeholders and accounting.

Configuring an online workflow to mirror contract execution

Set up digital workflow fields, signer order, and authentication to mirror contractual execution requirements and retention schedules.

Field Configuration
Signer Order Sequential or parallel signing; set signer roles
Authentication Email link, SMS OTP, or KBA as needed
Conditional Fields Show fields when specific answers selected
Retention Automatic archive and export to cloud storage

Platform and integration considerations for electronic execution

Digital platforms must support PDF/DOCX import, robust audit trails, and configurable signer authentication to match legal and company policies.

  • File Types: PDF, DOCX, and HTML supported
  • Integrations: Salesforce, NetSuite, Google Workspace
  • Authentication: Email, SMS, SSO, and 2FA

Typical timelines and processing expectations

Be aware of common processing timelines for execution, insurance proof, and SOW mobilization to avoid project delays.

Execution Window:

Expect 1–7 business days for final signatures

Insurance Proof:

Certificates usually required before work mobilization

SOW Activation:

Work orders often start 5–15 business days after sign

Change Order Turnaround:

Approve within 3–10 business days to prevent delay

Invoice Processing:

Accounting cycles typically 30–45 days net payment

Real-world examples using a Combined MSA

Examples below show how organizations use a Real Estate Combined MSA across common scenarios in leasing and maintenance contexts.

Martin Properties

Martin Properties used an online MSA workflow to process multiple lease and maintenance contracts across suburban rental portfolio without in-person signatures.

  • Eliminated days of scheduling site signings.
  • Tim Martin reported faster turnaround and maintained compliance with security standards; the MSA structure let his team attach work orders per property and preserve consistent insurance and indemnity language, simplifying vendor onboarding and accounting reconciliation across the business.

Optica Ventures LLC

Optica Ventures consolidated service agreements for property renovations and routine maintenance into a single Combined MSA to standardize vendor terms across different markets.

  • Improved contract consistency and review efficiency.
  • Brian Fitzgibbons noted the simplified interface allowed internal teams and external contractors to complete approvals remotely, reducing administrative overhead while keeping document versions, certificates of insurance, and signed exhibits centrally accessible for audits and future asset transfers.

Frequently asked questions about the Real Estate Combined MSA

Frequently asked questions address execution, eSignature validity, notarization, and common compliance concerns for a Real Estate Combined MSA.


Need help? Contact support

Example eSignature pricing and feature comparison relevant to MSAs

Compare common eSignature plan features and starting prices relevant to managing a Real Estate Combined MSA for high-volume contract signing and vendor onboarding.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by vendor Varies by vendor Varies by vendor Varies by vendor
Bulk Send Yes Yes Yes Yes Varies
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes Varies Varies
be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.