Can the HIA Contract be signed electronically?

Yes. Electronic signatures are legally equivalent to handwritten signatures under the ESIGN Act (15 U.S.C. ch. 96) and most states’ adoption of UETA. Verify that the transaction is not one of the ESIGN/UETA exceptions such as wills or certain court filings.

Is a notary or witnesses required to record the document?

Many real estate instruments require a notary acknowledgement for recording. Witness requirements vary by state and document type; for example, Florida often requires two witnesses for deeds. Check the county recorder for local standards.

What if a signer makes a material error after signing?

Minor clerical errors can be corrected by an amendment signed by all parties. Material errors affecting substance generally require a formal amendment or re-execution. Consult counsel before altering recorded instruments.

How do electronic notarization and RON affect recording?

Remote Online Notarization is permitted in most states with specific identity-proofing and recording requirements. Where RON is accepted, recorders may require additional documentation; confirm county acceptance before relying on RON.

How long until the signed contract is available to all parties?

A fully executed electronic contract and audit certificate are typically available immediately after final signature; delivery may be by email or downloadable link depending on the platform configuration.

Who should keep the original signed document?

Maintain a signed, tamper-evident PDF/A copy with the audit trail in your records system. Lenders, title companies, and counsel may each retain their own copies for underwriting, closing, and compliance purposes.

Electronic Signature
Templates
Real estate
Real Estate HIA Contract

Real Estate HIA Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REAL ESTATE HIA CONTRACT

Parties and Contract Date

Owner Name:

Owner Contact Information

Builder/Contractor Name:

Builder Contact / License

Date of Agreement:

Property Identification

Property Address Parcel / APN Legal Description

Contract Sum and Payment

Contract Price (Total):

Deposit / Earnest Money Progress Payment Schedule

Final Payment / Retention:

Scope of Work & Schedule

Scope of Work

Commencement Date: Estimated Practical Completion Date:

Milestones / Delivery Obligations

Permits, Materials & Insurance

Builder to procure all necessary permits and approvals as required by law. Builder's insurer:

Required insurance coverages (minimum): Public Liability: ; Builder's All Risks:

Owner-supplied Items (if any)

Inspections, Defects & Warranties

Inspection Period: Owner shall perform final inspection within days of practical completion. Contractor to rectify defects reported within days.

Warranties

Variations

Changes to the scope of work shall be issued only by written Variation Order signed by both parties. Variation Orders shall state adjustments to price and time. Any oral instruction is not a Variation Order.

Variation Procedure / Notes

Disclosures

Lead-based paint or hazardous materials on site: Yes No

Known water damage or mold: Yes No

Prior structural damage or repairs: Yes No

Additional Disclosures / Facts

Default, Remedies & Termination

If either party materially breaches this Contract and fails to remedy such breach within days after written notice, the non-breaching party may terminate and pursue available remedies including damages or specific performance where permitted by law.

Liquidated Damages / Delays

Dispute Resolution; Governing Law

Parties agree to negotiate in good faith to resolve disputes. If unresolved within 30 days, disputes shall be submitted to mediation; if mediation fails, disputes shall be resolved by arbitration or binding adjudication as elected by the parties. This Contract is governed by the law of the jurisdiction in which the Property is located.

Representations, Indemnity & Entire Agreement

Each party represents it has authority to enter into this Contract. Builder warrants work will be performed in a workmanlike manner in accordance with industry standards. Owner shall indemnify Builder for delays or additional costs resulting from inaccurate or incomplete information supplied by Owner.

This Contract (including any attached schedules and Variation Orders) constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, or agreements, whether written or oral.

Notices

All notices required or permitted under this Contract shall be in writing and delivered to the addresses listed above by hand, certified mail, or commercial courier and shall be effective upon receipt.

Acknowledgment

By signing below, Owner and Builder acknowledge they have read, understood and agree to the terms and conditions contained in this Contract, including scope, price, schedule, and procedures for variations, inspections and dispute resolution.

Owner Printed Name:

By:

Date:

Builder Printed Name:

By:

Date:

What the Real Estate HIA Contract Covers

The Real Estate HIA Contract is a standardized written agreement used to record rights and obligations between parties in residential real estate transactions or property-related construction work. It typically defines the parties, property description, scope of work or transaction terms, payment and consideration, contingencies, timelines, permitting responsibilities, dispute resolution, and signature blocks for all parties involved.

Why a Formal HIA Contract Matters in Real Estate

A clear HIA contract reduces misunderstandings, allocates risk, documents scope and price, and provides an enforceable record when signed electronically in compliance with ESIGN (15 U.S.C. ch. 96) or UETA. Proper execution simplifies closings, lender review, and post-closing audits.

Who Typically Prepares and Signs This Contract

These agreements are used by a small set of professionals and parties in property transactions.

Real estate brokers and agents coordinating offers, disclosures, and contract delivery to buyers and sellers.
Property owners, developers, and general contractors documenting scope, timelines, payment terms, and inspection responsibilities.
Title companies, lenders, and escrow officers reviewing contract terms for recording, closing, and funding conditions.

Each party’s role determines which sections they must complete and which supporting documents they must provide.

Step-by-step: Completing a Real Estate HIA Contract

Follow a consistent sequence to reduce errors and ensure enforceability when using electronic signatures.

01

Collect Documents: Gather IDs, title info, permits, and disclosures before drafting.
02

Enter Parties: Use full legal names and entity types as shown on ID or formation documents.
03

Define Terms: Specify price, payment schedule, contingencies, and completion milestones.
04

Sign and Archive: Execute with proper authentication and store signed copy with audit trail.

Typical eSigning Flow for an HIA Contract

Electronic signing follows a predictable sender-to-signer workflow that preserves intent and an audit trail.

Upload Document: Place the HIA contract PDF or DOCX into the signing platform.
Add Fields: Insert signature, date, initials, and conditional fields where required.
Send to Signers: Provide signer emails or generate secure signing links.
Receive Signed Copy: Platform returns final PDF and certificate of completion.

Configuring an Electronic Workflow for the Contract

Set up authentication, routing, and retention options to match closing and compliance requirements.

Field	Configuration
Authentication	Email link \| Optional SMS code or KBA
Routing Order	Sequential \| Use for lender then buyer then seller
Notifications	Email reminders \| Custom interval settings
Audit & Retention	Enable audit trail \| Export PDF/A for archive

Technical and Integration Requirements

Choose a platform that supports required formats, authentication, and integrations used in your closing workflows.

File formats: PDF and DOCX supported
Authentication: Email, SMS, KBA options
Integrations: Salesforce, NetSuite, MS 365

eSignature vendor comparison for executing HIA contracts

Pricing and basic feature availability across common eSignature vendors. signNow is listed first per comparison rules.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Varies by plan	Varies by plan	Varies by plan	Varies by plan
Bulk Send	Yes (Business Premium)	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No
Envelope Cap	No cap	100 envelopes/user/year	Varies by plan	Varies by plan	Varies by plan

Frequently asked questions about executing and managing the HIA Contract

Answers to common legal, procedural, and technical questions when preparing, signing, notarizing, or storing the contract.

Need help? Contact support

Can the HIA Contract be signed electronically?
Yes. Electronic signatures are legally equivalent to handwritten signatures under the ESIGN Act (15 U.S.C. ch. 96) and most states’ adoption of UETA. Verify that the transaction is not one of the ESIGN/UETA exceptions such as wills or certain court filings.
Is a notary or witnesses required to record the document?
Many real estate instruments require a notary acknowledgement for recording. Witness requirements vary by state and document type; for example, Florida often requires two witnesses for deeds. Check the county recorder for local standards.
What if a signer makes a material error after signing?
Minor clerical errors can be corrected by an amendment signed by all parties. Material errors affecting substance generally require a formal amendment or re-execution. Consult counsel before altering recorded instruments.
How do electronic notarization and RON affect recording?
Remote Online Notarization is permitted in most states with specific identity-proofing and recording requirements. Where RON is accepted, recorders may require additional documentation; confirm county acceptance before relying on RON.
How long until the signed contract is available to all parties?
A fully executed electronic contract and audit certificate are typically available immediately after final signature; delivery may be by email or downloadable link depending on the platform configuration.
Who should keep the original signed document?
Maintain a signed, tamper-evident PDF/A copy with the audit trail in your records system. Lenders, title companies, and counsel may each retain their own copies for underwriting, closing, and compliance purposes.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now