Establishing secure connection…Loading editor…Preparing document…

Real Estate Phase Work

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REAL ESTATE PHASE WORK AGREEMENT

Parties and Effective Date

This Real Estate Phase Work Agreement (the Agreement) is entered into as of by and between the Property Owner and the Contractor identified below.

Property Identification

Phase Identification and Scope

Phase Name:    Phase Reference:

Schedule, Milestones and Possession

Phase Commencement Date:    Anticipated Substantial Completion Date:

Possession/Occupancy to Owner: (subject to final acceptance and punchlist completion)

Financial Terms

Total Phase Price: $    Deposit / Mobilization: $

Retainage Percentage: %    Late Payment Fee: $

Change Orders and Extras

Any modification to the Scope of Work that alters price or schedule must be approved in writing by both parties via a Change Order signed by the Owner and Contractor prior to commencement of the changed work. Contractor shall not be entitled to payment for changed work performed without a fully executed Change Order.

Inspections, Acceptance and Punchlist

Owner shall inspect completed Work within days of Contractor notice of substantial completion. Acceptance shall be documented in writing. Any punchlist items shall be completed by Contractor within a reasonable period as mutually agreed.

Warranties and Insurance

Contractor warrants that all materials and workmanship shall be free from defects for a period of months following final acceptance unless otherwise specified herein.

Disclosures

Lead-Based Paint Present? Yes   No

Mold or Water Intrusion Known? Yes   No

Prior Material Damage or Structural Repairs? Yes   No

Asbestos or Hazardous Materials Known? Yes   No

Indemnity, Default and Remedies

Contractor shall indemnify, hold harmless and defend Owner from and against all claims, liabilities, losses and expenses (including reasonable attorney fees) to the extent caused by Contractor's negligent acts or omissions or breach of this Agreement. In the event of Contractor default, Owner may, after written notice and failure to cure within the time specified, terminate this Agreement and pursue all remedies available at law or in equity.

Termination

Either party may terminate this Agreement for material breach if the breaching party fails to cure within thirty (30) days following written notice (unless a different cure period is stated herein). Termination shall not relieve the breaching party of liability for breaches occurring prior to termination.

Governing Law and Entire Agreement

This Agreement shall be governed by the laws of the State of without regard to conflict of law rules. This Agreement, together with all attached exhibits and executed Change Orders, constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.

Notices

Notices under this Agreement shall be delivered to the addresses set forth below by certified mail, personal delivery, or commercial courier and shall be effective upon receipt.

Certifications and Acknowledgments

Each party represents and warrants that it has the full right, power and authority to enter into this Agreement, that the individual signing on behalf of each party is authorized to bind such party, and that no other consents are required to make this Agreement enforceable.

Property Owner:

By:

Date:

Contractor:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Real Estate Phase Work Is

The Real Estate Phase Work is a structured document used to record, approve, and schedule discrete phases of a property transaction or development project, such as inspection, remediation, staging, or closing tasks. It defines scope, deliverables, start and completion dates, assigned parties, cost estimates, and acceptance criteria so progress can be tracked against milestones. Commonly used by brokers, property managers, contractors, and lenders, the form creates a clear operational record that supports invoicing, lien waivers, and compliance with state real estate disclosure or licensing requirements.

Why Clear Phase Documentation Matters

Documenting phase work clarifies responsibilities, reduces disputes over scope or timing, and preserves a dated record for billing, lien releases, and regulatory disclosures. Accurate phase documentation supports contractor payments, lender draw schedules, and audit-ready project histories.

Why Clear Phase Documentation Matters

Roles That Complete and Rely on Phase Work

Brokers, property managers, general contractors, lenders, title officers, and owners commonly complete or review phase work to coordinate tasks and payments.

  • Real estate brokers use it to schedule inspections, repairs, and staging around closing timelines.
  • Contractors attach cost estimates, acceptance criteria, and lien-waiver conditions for each phase.
  • Lenders and title agents use phase records for draw approvals and closing checklists.

These roles rely on dated, signed phase records to reduce payment disputes and support compliance with state disclosure and lien laws.

Essential Sections That Make Phase Work Useful

Core sections that make a Real Estate Phase Work professional, enforceable, and useful to project workflows and audits for stakeholders.

Scope

Define the specific tasks, locations, measurable deliverables, and exclusions for the phase. Clear scope limits change-order disputes and provides a baseline for acceptance testing and contractor payment verification.

Schedule

List start, milestone, and completion dates in MM/DD/YYYY format, include dependencies, and note acceptable delay windows. Accurate dates are required for lender draws and statutory notice periods.

Costs

Itemize estimated labor, materials, permit, and contingency amounts; specify who pays each line item and whether costs require pre-approval. This prevents billing disputes and informs lien waiver staging.

Acceptance

Describe objective acceptance criteria, test procedures, inspection signoffs, and acceptable tolerances. Include remedy or rework requirements if the phase fails to meet inspection or performance standards.

Signatures

Provide signature blocks for all responsible parties with printed name, title, company, date, and witness or notary lines where state law or transaction type requires additional authentication.

Attachments

Include exhibits such as scope drawings, photos, invoices, permit copies, and lien waiver templates. Attachments should be referenced by exhibit number and incorporated into the phase record by reference.

Security and Compliance Considerations

Encryption: TLS 1.2/1.3 in transit; AES-256 at rest
Access Controls: Role-based access and SSO/SAML
Audit Trail: Detailed timestamps, IP addresses, and action logs
BAA Support: HIPAA compliant with BAA available
Certifications: SOC 2 Type II, ISO 27001, PCI DSS
Accessibility: WCAG 2.0 Level AA conformance

Key Risks and Consequences of Errors

Payment Disputes: Delayed or withheld contractor payments
Late Draws: Loan draw denials or delays
Lien Risk: Valid mechanics lien filings possible
Regulatory Noncompliance: State disclosure violation fines
Notarization Errors: Invalid acknowledgements may void records
Fraud Exposure: Insufficient signer authentication increases fraud risk

Common Preparation Pitfalls to Avoid

  • Failing to define measurable acceptance criteria leads to subjective inspections and disputes that delay payment and require costly rework or arbitration.
  • Using ambiguous dates or inconsistent date formats across documents causes lender draw errors and misaligned contractor schedules; use MM/DD/YYYY consistently.
  • Attaching unnumbered exhibits or unsigned invoices makes it difficult to verify charges during audits and impairs enforceability of payment clauses.
  • Not tracking version history or failing to capture signatures with timestamps increases risk in disputes and weakens the document's evidentiary value.

Step-by-Step: Completing Real Estate Phase Work

Follow these sequential steps to complete Real Estate Phase Work accurately and ready it for signing and recordkeeping.

  • 01
    Prepare: Gather contracts, permits, drawings, and cost estimates.
  • 02
    Define: Write measurable scope, deliverables, and exclusions.
  • 03
    Schedule: Enter start, milestone, and completion dates in MM/DD/YYYY.
  • 04
    Sign & Record: Obtain required signatures, notarizations, and retain final signed copy.

Customizing an Online Workflow for Phase Records

Configure an online workflow to route, authenticate, and archive Real Estate Phase Work for digital execution and compliance.

Field Configuration
Routing Order Sequential signer order with conditional branches
Authentication Email, SMS code, or KBA as required
Fields Required, conditional, and formula fields for approvals
Attachments Enforce required exhibits and file type restrictions
Retention Automatic archiving and export to cloud storage

Where to Send Final Signed Phase Records

Typical routing and submission paths for signed phase work, including copies for owner, lender, contractor, and recorded files.

  • Owner Copy: Deliver signed PDF to property owner and file in project folder.
  • Lender Package: Send required phases to lender for draw approval and retain proof.
  • Contractor Records: Provide contractor with signed phase record and any change orders.
  • Title/Closing: Attach final phase work to closing binder or title file.

Distribution Channels and Integration Needs

Distribution channels include email, shared cloud links, API-driven push, and integration with ERP or title systems.

  • Email: Secure signing links and PDF attachments
  • Cloud Storage: Auto-export to Box, Google Drive, or Egnyte
  • Integrations: Native connectors for Salesforce, NetSuite, and Procore

Typical Timelines and Processing Expectations

Common timing expectations for phase submission, approvals, inspections, and lender draw cycles in real estate projects.

Phase Submission Deadline:

Submit phase packet at least five business days before scheduled inspections.

Inspection Response Time:

Inspector or reviewer typically responds within three to seven business days.

Lender Draw Turnaround:

Typical draw approval is five to ten business days after documentation.

Correction Period:

Contractor typically has seven to fourteen days to remedy deficiencies.

Record Processing:

Final signed phase work should be archived within two business days.

Notarization and Witness Steps for Authentication

Authentication steps for signatures, witness acknowledgment, and remote or in-person notarization when the transaction or state law requires it.

01

Determine Need

Verify whether the phase record requires notarization or witness under state law.

02

Choose Notarization Type

Decide between in-person notarization or RON if permitted in jurisdiction.

03

Signer ID

Collect government-issued ID and compare printed legal name to signer.

04

Witness Presence

If witnesses required, have them observe signing and provide printed names.

05

Audio-Visual Record

For RON, record the session and retain per state retention rules.

06

Notary Journal

Notary records journal entry including ID method, time, and actions.

07

Attach Acknowledgement

Include notary acknowledgement or witness affidavits with the final packet.

08

Verify Validity

Confirm notarization meets state statutes before filing or lender submission.

Practical Examples from Property Teams

Real-world examples show how phase documentation and e-signature workflows reduce turnaround time and preserve compliance for property professionals.

Martin Properties

Martin Properties replaced paper phase packets with digital phase records to coordinate staging and repair work across multiple listings.

  • This reduced turnaround and onsite delays.
  • According to founder Tim Martin, the team executes documentation online with consistent compliance and security, enabling faster approvals, reliable audit trails, and timely payment cycles that keep closings on schedule.

Optica Ventures

Optica Ventures streamlined property inspection approvals by attaching photo exhibits and acceptance checklists to each phase record.

  • Customers sign faster on mobile.
  • The COO reports the interface improved customer experience while preserving an audit-ready history of approvals, which simplified lease rollovers and contractor invoicing during rapid portfolio turnover and reduced manual reconciliation across accounting and property management systems.

Who Signs and Certifies Phase Work

Tim Martin, Founder

Tim Martin leads Martin Properties and reports converting phase documentation to online workflows improved compliance and speed. His team relies on mobile signing and centralized records to coordinate contractors, reduce paper handling, and accelerate closing tasks.

Brian Fitzgibbons, COO

Brian Fitzgibbons oversees operations at Optica Ventures and emphasizes simplicity for both staff and customers. Standardized digital phase packets reduced administrative follow-up and improved traceability of payments, approvals, and contractor performance across properties.

How Phase Work Differs from Related Documents

Compare Real Estate Phase Work with related documents to clarify purpose, enforceability, and typical contents.

Document Type Phase Work Change Order Inspection Report Lien Waiver
Primary Purpose plan tasks modify scope record condition release lien
Signed By owner/contractor owner/contractor inspector contractor/owner
Trigger for Payment acceptance criteria approved change inspection pass receipt of waiver
Common Attachments schedules, costs revised schedules photos, notes paid invoice, release

eSignature Pricing and Feature Comparison for Phase Work

Comparison of starter pricing and basic feature availability across common eSignature providers for executing Real Estate Phase Work.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial Yes, 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes Varies by plan
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Varies by plan Varies by plan Varies by plan Varies by plan
Envelope Cap No envelope cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Frequently Asked Questions and Troubleshooting

Answers to common questions about execution, authentication, retention, and disputes for Real Estate Phase Work.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.