Establishing secure connection…Loading editor…Preparing document…

Rehabilitation Project BoQs

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REHABILITATION PROJECT BILL OF QUANTITIES AND AGREEMENT

Parties and Project Identification

This Agreement is entered into by and between Client Name: and Contractor Name: .

Project Title: — Project Location:

WHEREAS

WHEREAS, Client desires to undertake rehabilitation works at the Project Location described above and requires a detailed Bill of Quantities and binding agreement for the scope of rehabilitation; and

WHEREAS, Contractor represents that it has the experience, personnel and resources necessary to supply labor, materials and services as set forth in the Scope of Work and Bill of Quantities attached hereto; and

WHEREAS, the parties agree that the Bill of Quantities will form the basis for valuation, payment and contractor obligations under this Agreement.

Scope of Work

Bill of Quantities (BoQ)

The following items constitute the Bill of Quantities. Unit rates and totals shall be used to determine payments. Where measurements differ from actual site quantities, final payment will be adjusted in accordance with the Measurement and Valuation clause herein.

No.
Description
Unit
Quantity
Unit Price
Total

Payment Terms

Contract Sum (as per BoQ total):

Mobilization Amount (if any):

Payment Terms: All invoices are due within days of invoice date. Invoices will be issued in accordance with the approved progress valuations derived from the BoQ.

Late Payment Fee: Any undisputed amount not paid within the stated terms shall accrue interest at per month, calculated pro rata, until paid. The parties agree that interest is a remedy in addition to any other remedies available at law.

Term and Termination

Contract Commencement Date: — Estimated Completion Date:

Either party may terminate this Agreement for cause upon written notice if the other party materially breaches any obligation and fails to cure such breach within days of receipt of written notice. For convenience, either party may terminate upon days' prior written notice, subject to settlement of completed works and costs reasonably incurred.

Confidentiality

Each party shall keep confidential all non-public information disclosed in connection with this Agreement, including BoQ pricing, methodologies, and site reports, and shall not disclose such information except to employees, subcontractors or advisors on a need-to-know basis or as required by law. This obligation survives termination for a period of five (5) years.

Measurement, Variations and Adjustments

Quantities stated in the BoQ are estimates for contracting and valuation. Variations required by site conditions or Client instruction will be valued at agreed rates or, if no rate exists, at rates derived from rates for similar items and documented overhead and profit. Contractor must submit proposals for variations in writing and obtain Client written approval prior to commencing varied work unless an emergency prevents delay.

Governing Law and Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of State/Jurisdiction: . Disputes shall first be subject to good faith negotiation; if unresolved, disputes shall be referred to mediation and, if still unresolved, to binding arbitration in accordance with the rules agreed by the parties.

Entire Agreement

This document, including the BoQ, Scope of Work and Payment Schedule, constitutes the entire agreement between the parties and supersedes all prior negotiations, representations and agreements, whether written or oral, concerning the subject matter herein. Any amendment must be in writing and signed by both parties.

Acknowledgement and Certifications

By signing below, each party certifies that the person signing has authority to bind the respective party, that the BoQ accurately reflects the pricing basis for the described works, and that the parties accept the terms and conditions set forth in this Agreement.

Acceptance of BoQ and Terms: I acknowledge and accept the BoQ, scope, payment terms and conditions of this Agreement.

Client - Printed Name:

By:

Date:

Contractor - Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Rehabilitation Project BoQs Is and when it's used

A Rehabilitation Project Bill of Quantities (BoQs) is a structured itemized schedule that quantifies materials, labor, and unit rates for a building rehabilitation or retrofit. It organizes work items by trade and location, links quantities to specifications and drawings, and enables consistent pricing, bid comparison, and progress measurement. For procurement and contract administration, a professional BoQs reduces ambiguity by listing units, quantities, unit prices, and total line values, and by referencing measurement rules and contingencies that apply to the rehabilitation scope.

Why a clear BoQs matters for rehabilitation projects

A well-prepared BoQs improves bid comparability, reduces disputes, and supports accurate change orders and payments by establishing clear measurement and pricing conventions tied to drawings and specifications.

Why a clear BoQs matters for rehabilitation projects

Who prepares and who relies on Rehabilitation Project BoQs

Typical preparers and primary users of BoQs include estimating teams, quantity surveyors, general contractors, and procurement officers.

  • Estimating teams and quantity surveyors: produce detailed quantities and measurement rules for accurate pricing and risk allocation.
  • General contractors and subcontractors: use BoQs to prepare bids, schedule work, and price change orders consistently.
  • Owners and procurement officers: rely on BoQs for fair tender evaluation, budget reconciliation, and progress certification.

Stakeholders across project delivery use the BoQs as a common source of truth for contracting, invoicing, and dispute resolution.

Step-by-step: completing a Rehabilitation Project BoQs

Follow a consistent sequence from document preparation through approvals to avoid omissions and rework.

  • 01
    Gather inputs: Collect drawings, specs, and scopes of work.
  • 02
    Define measurement rules: Set units, tolerances, and inclusion rules.
  • 03
    Quantify items: Measure and enter quantities per rule.
  • 04
    Review and certify: Validate totals, signatures, and references.

Configuring an online BoQs workflow

Set fields, approvals, and integrations before circulating the BoQs to ensure consistent routing and auditability.

Field Configuration
Required signatures Owner | Contractor | QS approval workflow
Version control Enable automatic revision numbering
Authentication Email + SMS code or stronger methods
Cloud storage Set destination (Project folder, SSO account)

Technical requirements for eSubmission and distribution

Ensure your platform supports the file types, signer authentication, and integrations required by procurement and compliance rules.

  • File formats: PDF, DOCX, XLSX supported
  • Integrations: Salesforce, NetSuite, Procore
  • Security: TLS and AES-256 encryption

Configure authentication, storage, and audit-trail settings to meet project and regulatory records requirements before sending for signature.

How electronic BoQs review and sign workflows typically run

A standard eSubmission flow streamlines review and establishes an audit trail for approvals and payments.

  • Upload document: Sender uploads BoQs file to platform.
  • Place fields: Add signature, initials, and date fields.
  • Assign signers: Specify signer order and authentication.
  • Capture audit trail: System records timestamps, IPs, and actions.

Essential components of a professional Rehabilitation Project BoQs

A robust BoQs combines detailed measurement, clear descriptions, pricing rules, and linkage to drawings and contract terms to support procurement, execution, and payment.

Structured item list

A sequential, trade-by-trade schedule listing every work item, identification codes, and cross-references to drawings and specification sections to avoid omissions and misinterpretation.

Units and measurement rules

Defined units (LF, SF, CY) and a measurement methodology statement that explains how to measure irregular shapes, overlaps, and allowances for demolition or remediation.

Quantities and takeoff notes

Calculated quantities with source references (drawing sheet, scale, or survey), rounding rules, and any assumptions used during takeoff to allow independent verification.

Unit rates and extensions

Unit price entries with clear inclusion or exclusion notes (taxes, waste, temporary works), plus line totals computed to match invoice and valuation templates.

Contingency and provisional sums

Contractually defined allowances for unknown conditions, provisional works, and design development to protect budget and allocate risk.

Change order linkage

Mechanisms to record variations: reference IDs, valuation methodology, and approval fields so changes update totals and payment schedules consistently.

Security and compliance controls relevant to BoQs and eSubmission

Encryption: TLS 1.2/1.3 in transit
Data at rest: AES-256 encryption
Audit trail: Detailed event logs
Access controls: Role-based permissions
Regulatory standards: SOC 2 Type II, ISO 27001
Healthcare BAA: HIPAA available with BAA

Key risks and penalties from incorrect BoQs

Cost overruns: Underestimated quantities
Payment disputes: Ambiguous scope descriptions
Contract claims: Inconsistent measurement rules
Delay impact: Unpriced contingencies
Lien exposure: Incorrect subcontract valuations
Regulatory penalties: Procurement noncompliance

Common preparation pitfalls to avoid

  • Using inconsistent units across related items leads to calculation errors and disputed invoices during progress certification.
  • Omitting measurement sources or assumptions makes independent verification difficult and increases the likelihood of later claims.
  • Leaving provisional sums undefined or improperly detailed results in unfair allocation of unknown-condition risks.
  • Failing to link BoQs line items to drawings and specification clauses creates ambiguity during tender evaluation and construction.

Typical timing and deadlines linked to BoQs and procurement

Project schedules and procurement timelines affect when BoQs are finalized and when certified quantities are payable.

Bid submission deadline:

Date and time proposals must be received.

Contract award:

Date owner signs contract and issues notice to proceed.

Mobilization start:

Contractor begins on-site work after notice to proceed.

Monthly valuations:

Payment applications often submitted monthly per BoQs.

Final account:

Submission of as-built quantities for final payment.

Key milestones from BoQs issue to final account

A sequential milestone view shows the critical stages where BoQs must be accurate and approved.

01

BoQs issue

Finalize and publish the BoQs prior to tender release.

02

Tender evaluation

Compare bids using the same BoQs and measurement rules.

03

Interim valuations

Use certified quantities for monthly payment applications.

04

Final reconciliation

Agree as-built quantities and settle final account.

How Rehabilitation Project BoQs differ from standard BoQs

Compare features and typical uses to decide what level of detail and contractual controls to include.

Criteria Rehabilitation BoQs Standard BoQs
Purpose refurbish existing fabric new construction
Detail level high variable
Unknowns management provisional sums less common
Measurement basis existing conditions design intent

eSignature vendor comparison for BoQs eSubmission and signing

Summary of commonly requested vendor features and starting prices. signNow appears first per platform comparison conventions.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes (Business Premium) Varies by plan Varies by plan Varies by plan No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No envelope cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Real-world examples of digital signing and document control

Organizations across real estate and construction use electronic signing to speed approvals and centralize audit trails.

Tim Martin, Martin Properties

We process and execute documents online with full compliance and built-in security.

  • Mobile and offline signing available for field teams.
  • This flexibility reduced turnaround on approvals and helped our teams manage multiple rehabs without physical signings or courier delays.

Dan Rotelli, BIS

We preferred a platform with SOC 2 certification and ESIGN/UETA focus.

  • Integration with existing systems mattered.
  • Centralized electronic workflows improved internal controls for BoQs, reduced manual reconciliation, and created auditable change-order trails.

Practical tips for accurate and efficient BoQs

Adopt standards and internal checks to reduce rework and strengthen defensibility of quantities and valuations.

Standardize measurement
Use a documented measurement standard and apply it consistently across the BoQs. Include a brief measurement rules annex for surveyors, estimators, and valuers to follow.
Cross-check quantities
Run independent quantity checks and reconcile discrepancies before issuing the BoQs to bidders to avoid variation claims after mobilization.
Include assumptions
Explicitly state assumptions and tolerances used in takeoff calculations to reduce ambiguity during change-order negotiations.
Version control
Track revisions and require signed acceptance of BoQs updates so that payments and claims reference the correct document version.

Frequently asked questions and troubleshooting

Answers to common concerns about preparing, signing, and relying on Rehabilitation Project BoQs.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.