Establishing secure connection…Loading editor…Preparing document…

Remodeling Agreement Template

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REMODELING AGREEMENT

This Remodeling Agreement ("Agreement") is entered into as of the Effective Date set forth below by and between:

Owner Name:     Owner Address:

Contractor Name:     Contractor License No.:

Recitals

WHEREAS, Owner is the owner of the real property located at (the "Property"); and

WHEREAS, Contractor is duly qualified and experienced to perform remodeling, repair and related construction services and represents that Contractor holds all licenses, permits and insurance required by law to perform such services; and

WHEREAS, Owner desires to engage Contractor, and Contractor agrees to perform the work described herein under the terms and conditions set forth in this Agreement.

Scope of Work

Contractor shall furnish all labor, materials, equipment and services necessary to complete the remodeling work described below at the Property. The Scope of Work shall include the work described in the Project Description and any attachments incorporated by reference. All work shall be performed in a good and workmanlike manner and in compliance with applicable codes.

Payment Terms

Contract Price (Total): $     Deposit (due upon signing): $

Retainage:     Late Payment: Interest at on outstanding amounts, accruing from the due date.

All payments due under this Agreement are exclusive of sales, use or other taxes, which, if applicable, shall be paid by Owner. Contractor shall maintain full and accurate records of payments and shall provide invoices identifying labor, materials and approved change orders.

Change Orders

Any change to the Scope of Work, materials, or schedule shall be performed only upon a written change order signed by both Owner and Contractor specifying the change, the cost adjustment, and any change to the timeline. Contractor shall not be obligated to proceed with any work outside the agreed Scope of Work without a signed change order.

Term and Termination

Commencement Date:     Estimated Completion Date:

Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure such breach within days after written notice. Upon termination for Owner's convenience, Owner shall pay Contractor for work performed and materials purchased to date plus reasonable demobilization costs.

Permits; Compliance; Subcontractors

Contractor shall obtain and pay for all permits and inspections necessary for the lawful performance of the Work unless otherwise agreed in writing. Contractor shall perform all Work in compliance with applicable laws, codes and regulations. Contractor may engage subcontractors but remains responsible for their performance.

Insurance; Indemnification; Limitation of Liability

Contractor shall maintain commercial general liability insurance and workers' compensation as required by law. Contractor shall indemnify and hold Owner harmless from claims arising from Contractor's negligence in performance of the Work, except to the extent caused by Owner's gross negligence or willful misconduct. Neither party shall be liable for consequential, incidental or punitive damages except for willful misconduct or fraudulent acts.

Warranties

Contractor warrants that labor performed under this Agreement shall be free from defects in workmanship for a period of from completion. Warranties for materials are limited to the manufacturers' warranties and do not extend to damage caused by normal wear, misuse, or modifications by others.

Confidentiality

Each party shall maintain in confidence all non-public business information and documents disclosed by the other party in connection with this Agreement and shall not disclose such information to any third party except as required by law or with the disclosing party's prior written consent. This obligation shall survive termination of this Agreement for a period of two (2) years.

Default; Remedies

In the event of a default, the non-defaulting party may pursue any remedies available at law or in equity, including specific performance, recovery of damages, and attorney's fees if provided by statute or contract. The exercise of one remedy shall not preclude the exercise of others.

Governing Law; Dispute Resolution

This Agreement shall be governed by and construed in accordance with the laws of the State of without regard to its conflicts of law principles. The parties shall first attempt in good faith to resolve disputes through mediation. If mediation fails, either party may pursue binding arbitration or litigation as agreed in writing.

Entire Agreement; Amendments

This Agreement, including any attachments and signed change orders, constitutes the entire agreement between the parties with respect to the subject matter herein and supersedes all prior negotiations, representations, or agreements. No amendment shall be effective unless in writing and signed by both parties.

Owner:

By:

Date:

Contractor:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Remodeling Agreement Template Covers

A Remodeling Agreement Template is a standardized contract that documents the rights, responsibilities, and expectations between a property owner and a contractor for renovation work. Typical elements include the project scope, materials, labor, payment schedule, milestone dates, permit and inspection responsibilities, change order procedures, insurance and licensing assurances, warranties, and dispute-resolution terms. Using a template helps ensure consistent coverage of legal and operational issues, reduces negotiation time, and creates a single record suitable for electronic signing and later enforcement if disputes arise.

Why a Clear Remodeling Agreement Matters

A well-drafted template reduces misunderstanding, protects parties from liability, ensures regulatory compliance, and preserves evidence of agreed terms for permitting, insurance, and potential disputes.

Why a Clear Remodeling Agreement Matters

Who Typically Uses This Template

Each party uses the template to align expectations, protect rights, and reduce post-project disputes.

  • Homeowners and property owners seeking to document project scope, timelines, and payment protections for renovation work.
  • Licensed contractors and subcontractors who need clear payment schedules, change order processes, and lien waiver terms.
  • Architects, project managers, and construction consultants who attach specifications, plans, and schedules as exhibits.

Essential Clauses to Include

A professional remodeling agreement should include sections that clearly allocate responsibility, outline deliverables, and provide remedies for delays or defects.

Scope of Work

Detailed description of tasks, materials, finishes, and any drawings or specifications that define project deliverables and exclusions.

Payment Schedule

Staged payments tied to milestones, retainage terms, accepted payment methods, and conditions for withholding for defective work.

Change Orders

Procedure for authorizing scope changes, pricing method for variations, and how schedule or payment adjustments are recorded.

Schedule & Milestones

Start and completion dates, milestone definitions, site access expectations, and remedies for excusable delays.

Insurance & Permits

Which party obtains permits, required insurance types and limits, certificate of insurance obligations, and permit fee allocations.

Warranties & Remedies

Warranty period, remedy process for defects, final inspection, punch list handling, and dispute-resolution method.

Step-by-Step: From Draft to Signed Contract

Follow clear sequential steps to reduce back-and-forth and ensure a complete, enforceable agreement.

  • 01
    Prepare Draft: Populate template fields and attach drawings or specs.
  • 02
    Review Terms: Confirm scope, schedule, insurance, and dispute provisions with counsel if needed.
  • 03
    Approve Changes: Execute change orders in writing before work begins.
  • 04
    Sign & Store: Obtain signatures and retain the final executed copy for records.

Typical Digital Signing Flow

Electronic workflows speed execution while preserving an auditable record of each action and signer.

  • Upload Document: Add the template and any exhibits in PDF or DOCX format.
  • Add Fields: Place signature, initial, date, and conditional fields where required.
  • Send to Signers: Specify signer order and optional authentication methods.
  • Complete Audit: Receive signed copy and certificate of completion with timestamps.

Recommended Digital Workflow Settings

Configure a reliable workflow to match your approval, authentication, and retention needs for remodeling contracts.

Field Configuration
Authentication Email link with optional SMS code for signer verification
Conditional Fields Enable to show payment or change-order fields only when applicable
Routing Order Set owner, contractor, and lender sequence as needed
Storage Location Save executed copies to secure cloud repository (PDF/A recommended)

Technical Considerations for Digital Execution

Ensure your eSignature provider supports audit trails, encryption, and any industry-specific compliance requirements prior to use.

  • File Formats: PDF and DOCX supported
  • Integrations: Salesforce, Procore, Google Workspace available
  • Authentication: SMS codes, email links, and KBA options

Security & Compliance Features to Look For

In-Transit Encryption: TLS 1.2/1.3
At-Rest Encryption: AES-256
HIPAA Support: BAA available when required
21 CFR Part 11: Compliant options exist
SOC 2 Type II: Report available on request
Access Controls: SSO, role-based permissions

Common Pitfalls When Preparing a Remodeling Agreement

  • Unclear scope of work leading to disputes about what is included and who pays for extras.
  • Missing permits or incorrect permit responsibility language that can cause stop-work orders or fines.
  • Ambiguous payment language or milestone definitions that trigger late payments and bonding issues.
  • Omitting lien waiver procedures or notice requirements can expose parties to unexpected lien claims.

Key Legal Risks and Consequences

License Violations: Fines, stop-work orders
Mechanic's Lien: Lien filings and foreclosure risk
Permit Noncompliance: Municipal fines or corrective work
Payment Disputes: Withholding, arbitration, litigation
Warranty Claims: Repair costs and potential liabilities
Recordkeeping Gaps: Weakened enforcement and audit exposure

eSignature Pricing Snapshot for Remodeling Agreements

Compare common plan and feature dimensions when selecting an eSignature provider for managing remodeling contracts.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes (Business Premium) Varies by plan Varies by plan Varies by plan Varies by plan
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Time-Critical Dates to Track

Monitor key deadlines to avoid fines, payment disputes, or lost lien rights during a remodeling project.

Effective Date:

Date obligations begin and warranties run from (enter MM/DD/YYYY)

Permit Submission:

File permits before work starts to avoid stop-work notices

Milestone Payments:

Trigger payments only on verified milestone completion

Final Acceptance:

Set final inspection and punch-list completion deadline

Lien Notice Deadlines:

Track preliminary notice and lien filing windows per state law

Practical Tips for a Clear, Enforceable Agreement

Adopt straightforward drafting and execution practices to reduce disputes and improve project control.

Use Clear Exhibits
Attach detailed drawings, material specifications, and an itemized budget as numbered exhibits to avoid disputes about what is included and to create an objective reference for change orders and inspections.
Define Payment Triggers
Link each payment milestone to measurable deliverables and inspection acceptance criteria; require invoices and lien waivers on progress payments to protect owners from double-payment risks.
Record Change Orders
Require written, signed change orders that state scope, cost, and schedule impact; deny verbal authorizations and be explicit about pricing method for unforeseen conditions.
Preserve Records
Keep all permits, inspection reports, correspondence, vendor invoices, and signed waivers for the retention period to support warranty claims, tax reporting, and dispute resolution.

Real-World Examples of Digital Contract Use

Organizations use digital execution and templates to accelerate approvals and maintain compliance for construction and property projects.

Tim Martin, Martin Properties

We moved to online execution for property documents to reduce processing time.

  • The result was consistent compliance across transactions.
  • I can process and execute all of these documents online with 100% compliance and built-in security, which makes closing and project starts more predictable for our business.

Kodi-Marie Evans, Xerox

Templates and integrations reduced manual entry and errors across contracts.

  • Integration with ERP sped routing and approvals.
  • airSlate SignNow provides the flexibility needed to get the right signatures on the right documents, in the right formats, based on our integration with NetSuite.

Frequently Asked Questions About Remodeling Agreements

Answers to common questions about validity, notarization, digital signatures, and disputes for remodeling agreements.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.