Can a Remodeling Contract be signed electronically?

Yes. Electronic signatures are generally enforceable under the federal ESIGN Act (15 U.S.C. ch. 96) and state UETA statutes in most jurisdictions. Ensure intent, consent, attribution and reliable record retention to meet legal validity tests.

When is notarization required?

Notarization is rarely required for ordinary remodeling contracts but may be necessary for related instruments such as easements, deed amendments, or some power of attorney documents; verify municipal or lender requirements.

Do I need witnesses for the contract?

Most states do not require witnesses for a standard remodeling contract. Witness requirements typically apply to wills, deeds, or specific statutory instruments rather than ordinary construction agreements.

How should change orders be documented?

Require written, signed change orders that describe scope adjustments, cost impact, and schedule effects. Link approval authority and thresholds in the contract to prevent oral change disputes.

What if a subcontractor files a lien?

Preserve payment records, lien waivers, and correspondence. Follow state mechanic's lien statutes for notice and contest procedures; timely payment and conditional waivers reduce lien exposure.

How long should I keep signed contracts?

Retain signed contracts at least for the active term plus three years; for tax or real estate matters keep longer. For healthcare settings follow HIPAA retention rules of six years (45 CFR §164.530(j)).

Electronic Signature
Templates
Legal
Remodeling Contract

Remodeling Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

REMODELING CONTRACT

This Remodeling Contract (the "Contract") is entered into as of Effective Date: by and between Client Name: , whose address is , and Contractor Name: , License No.: , with principal place of business at .

RECITALS

WHEREAS, Client desires to have certain remodeling, repair and improvement work performed at the premises described in this Contract and on the terms set forth below; and

WHEREAS, Contractor represents that it is duly licensed, insured and qualified to perform the work, that it will procure labor, materials and equipment necessary for the performance of such work, and that it will perform such work in a professional and workmanlike manner in accordance with applicable law and industry standards; and

WHEREAS, the parties desire to set forth their agreement in writing.

NOW, THEREFORE, in consideration of the mutual covenants contained herein, the parties agree as follows:

1. SCOPE OF WORK

1.1 Contractor shall perform the work described in the Scope of Work attached hereto or described below (the "Work") in a professional manner in accordance with industry standards and all applicable building codes, ordinances and permit requirements. The Work shall include, without limitation, the following:

Project Address Detailed Scope of Work

2. CONTRACT PRICE AND PAYMENT

2.1 Contract Price. Client shall pay Contractor for completion of the Work the total sum (the "Contract Price") of $ , subject to additions and deductions for Change Orders in accordance with Section 3.

2.2 Payment Schedule. Payments shall be made in accordance with the payment schedule described below. Progress payments are due within thirty (30) days of Client's receipt of Contractor's invoice containing the required supporting documentation, including lien waivers when requested. Final payment is due upon Substantial Completion and acceptance of the Work by Client, after Contractor furnishes final lien waivers and releases of claims for payment.

Payment Schedule / Milestones Deposit / Initial Payment Retainage Percentage (if any)

3. CHANGES; CHANGE ORDERS

3.1 No change in the Work shall be effective unless authorized in writing by a Change Order signed by Client and Contractor. Each Change Order shall describe the change in the Work, any adjustment to the Contract Price, and any extension or reduction of the schedule. Contractor shall not be required to perform altered work without a signed Change Order.

Change Order Authority / Instructions

4. TIME FOR COMPLETION

4.1 Contractor shall commence the Work no later than Commencement Date: , and shall achieve Substantial Completion no later than Completion Date: , subject to extensions for excusable delays as described below.

4.2 Time is of the essence. If Contractor fails to achieve Substantial Completion by the Completion Date, Client may recover liquidated damages in the amount of $ per calendar day, and such amount is agreed to be a reasonable estimate of anticipated damages and not a penalty.

5. PERMITS, LAWS AND INSPECTIONS

5.1 Contractor shall obtain and pay for all permits, inspections and approvals required for the performance of the Work unless otherwise agreed in writing. Contractor shall comply with all applicable statutes, regulations, codes and ordinances.

5.2 If permit fees or code-required corrections are the result of concealed conditions not reasonably discoverable by Contractor prior to commencing the Work, Contractor shall notify Client and the parties shall negotiate an equitable adjustment to the Contract Price and/or schedule.

6. MATERIALS; WARRANTIES

6.1 Contractor shall supply materials of good quality and new, unless otherwise specified. Materials and workmanship shall be warranted by Contractor against defects for Warranty Period: from the date of Substantial Completion, during which Contractor shall, at its expense, repair or replace defects caused by faulty workmanship.

7. INSURANCE; INDEMNIFICATION

7.1 Contractor shall maintain commercial general liability insurance, automobile liability and workers' compensation insurance as required by law and with limits sufficient to cover claims arising out of the Work. Contractor shall provide Client with certificates of insurance upon request. Contractor shall name Client as an additional insured under the commercial general liability policy with respect to the Work.

7.2 Contractor shall indemnify, defend and hold harmless Client and its agents, officers and employees from and against all claims, damages, losses and expenses, including reasonable attorneys' fees, arising out of or resulting from the performance of the Work, to the extent caused by Contractor's negligence or willful misconduct.

8. SUBCONTRACTORS; ASSIGNMENT

8.1 Contractor may engage subcontractors to perform portions of the Work, provided Contractor shall be responsible for the acts and omissions of its subcontractors. Contractor shall ensure subcontractors are bound to Contractor by written agreements consistent with Contractor's obligations hereunder.

8.2 Neither party may assign this Contract without the prior written consent of the other, except that Contractor may assign to a lender for financing purposes subject to Client's approval, which shall not be unreasonably withheld.

9. SITE CONDITIONS; CLIENT RESPONSIBILITIES

9.1 Client shall provide access to the premises, utilities and safe working conditions and shall remove personal property as necessary. Contractor shall take reasonable precautions to protect existing improvements and Client property; Client acknowledges some minor damage or cosmetic disturbance may occur and Contractor will repair such damage where practicable.

10. SUSPENSION AND TERMINATION

10.1 If either party materially breaches this Contract and fails to cure such breach within Cure Period (days): days after written notice, the non-breaching party may terminate the Contract. In the event of termination by Client for Contractor's default, Client may complete the Work and charge Contractor for costs in excess of the unpaid Contract Price. In the event of termination by Contractor for Client's default, Contractor shall be entitled to payment for Work performed and reasonable demobilization costs.

11. LIENS AND PAYMENTS

11.1 Contractor shall pay its subcontractors and suppliers when due. Contractor shall not permit any liens to remain on the property for Work performed. Contractor shall, upon final payment, deliver to Client unconditional waivers of lien from Contractor and its subcontractors and suppliers who provided labor or materials for the Work.

12. DISPUTE RESOLUTION

12.1 The parties shall attempt in good faith to resolve any dispute arising out of or relating to this Contract by negotiation. If the dispute is not resolved within thirty (30) days, the parties shall submit the dispute to non-binding mediation before a mutually agreed mediator. If mediation fails, the dispute shall be finally resolved by binding arbitration conducted in accordance with the rules of a recognized arbitration institution selected by the parties. The arbitrator's award shall be final and binding and may be entered in any court having jurisdiction.

13. NOTICES

13.1 All notices, demands or other communications required or permitted under this Contract shall be in writing and shall be delivered personally, by certified mail (return receipt requested), or by nationally recognized overnight courier to the addresses set forth below or such other address as a party may designate by written notice.

Client Notice Address Contractor Notice Address

14. DEFAULT; REMEDIES

14.1 If Contractor fails to perform the Work in accordance with this Contract and does not cure within the Cure Period, Client may withhold payments, provide Contractor written notice and pursue any remedies available at law or in equity, including specific performance or termination for cause. The election of any remedy shall not preclude the election of any other remedy.

15. GOVERNING LAW; VENUE

15.1 This Contract shall be governed by and construed in accordance with the laws of the State of , and the parties submit to the exclusive venue of the state and federal courts located therein for any proceedings not subject to arbitration.

16. ENTIRE AGREEMENT; SEVERABILITY; AMENDMENT

16.1 This Contract, including any exhibits, attachments and duly executed Change Orders, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, representations and agreements, whether written or oral.

16.2 If any provision of this Contract is held invalid or unenforceable, such provision shall be severed and the remaining provisions shall remain in full force and effect.

16.3 No modification, amendment or waiver of any provision of this Contract shall be effective unless in writing and signed by both parties.

17. MISCELLANEOUS

17.1 Waiver. No waiver by either party of any breach or default hereunder shall be effective unless in writing and signed by the waiving party. A waiver of any breach or default shall not constitute a waiver of any subsequent breach or default.

17.2 Counterparts. This Contract may be executed in counterparts, each of which shall be deemed an original and all of which together constitute one and the same instrument. Signatures exchanged by electronic transmission shall be binding.

REPRESENTATIONS

Each party represents and warrants that it has the full right, power and authority to enter into this Contract, that the person signing below is authorized to bind the party, and that the execution and performance of this Contract will not violate any other agreement to which the party is subject.

Client:

By:

Date:

Contractor:

By:

Date:

What a Remodeling Contract Is and When it Applies

A Remodeling Contract is a written agreement between an owner and a contractor that sets out the scope, materials, schedule, price, payment terms, change-order process, warranties, insurance and dispute resolution for a renovation or repair project. It documents responsibilities, timelines, completion milestones, and conditions for payment to reduce misunderstandings and support enforcement. Well-drafted remodeling contracts allocate risk for permits, inspections, liens, and concealed conditions, and they may include attachments such as plans, specifications, pricing schedules, and lien waiver forms that become part of the binding agreement.

Why a Clear Remodeling Contract Matters

A precise contract protects both owner and contractor by defining deliverables, payment milestones, remedies for delays, and obligations for permits and inspections. Clarity reduces disputes, supports lien and warranty enforcement, and creates an auditable record for permits, insurance and potential litigation.

Who Typically Uses a Remodeling Contract

Use the contract whenever parties want a clear allocation of duties, reduced litigation risk, or evidence for permit and lien processes.

Homeowners and property owners seeking to define scope, protect deposits, and require permits and insurance.
General contractors who need subcontractor scopes, payment schedules, lien waivers and warranty flow‑downs.
Project managers and property managers coordinating multiple trades and verifying milestones and inspections.

Key Parties and Typical Signers

Owner

A homeowner, landlord, or property owner who commissions the work. The owner must provide accurate property information, authorize access, pay per the schedule, and sign to accept final work and releases.

Contractor

The licensed contractor or contracting business responsible for performance. The contractor must confirm licensing, insurance, subcontractor use, materials, schedule, and sign to accept payment terms and warranty obligations.

Core Elements Every Professional Remodeling Contract Needs

A complete remodeling contract combines commercial, legal, and project management terms so expectations, payments, and remedies are clearly defined for all parties and for third parties such as inspectors and lien claimants.

Scope of Work

A detailed description of tasks, materials, brand/model specifications, drawings and measurable acceptance criteria so change orders and claims can be evaluated objectively and work quality is unambiguous.

Price and Payment

Clear total price, itemized allowances, deposit amount, installment or draw schedule, retainage, and accepted payment methods to prevent disputes and trigger remedies for nonpayment.

Schedule and Milestones

Start and completion dates, milestone definitions, delay notification procedures, and liquidated damages or extension mechanisms to manage timeline risk and inspection coordination.

Change Orders

Process for proposing, pricing, approving and documenting changes, including authorization thresholds and how extra time or cost will be calculated and invoiced.

Insurance and Indemnity

Required liability and workers' compensation coverage, certificate delivery, indemnity language, and responsibilities for damage to property or third‑party claims during the project.

Warranties and Liability

Express workmanship and material warranties, warranty period, remedies for defects, and limitations or disclaimers consistent with state consumer protection laws and contractor licensing rules.

Step-by-Step: How to Complete a Remodeling Contract

Follow these steps in order to create a clear, enforceable contract before work begins.

01

1. Verify Parties: Confirm legal names and authority to sign.
02

2. Define Scope: Attach plans and specifications; itemize allowances.
03

3. Set Payments: Establish milestone amounts and retainage.
04

4. Sign and Date: Obtain all required signatures and dates.

Where the Completed Contract Should Go and How It Moves

A signed contract should be stored by each party, provided to permitting authorities if required, and used to trigger payments, permits, and inspections.

Owner Copy: Keep original signed contract and attachments for warranty and lien defense.
Contractor Copy: Store on project file and share with subcontractors as applicable.
Permit Office: Submit contract if municipality requires proof for permit issuance.
Insurance Carrier: Provide certificate and contract terms if requested for claims or coverage verification.

How to Configure a Digital Workflow for This Contract

Map your digital steps to contract milestones to automate routing, reminders, and archive storage.

Field	Configuration
Signer Order	Owner first, contractor second, subcontractors as needed
Authentication	Email plus SMS code or KBA for added identity assurance
Reminders	Schedule automated reminders before payment and permit deadlines
Archive	Save signed PDF and audit trail to secure storage

Digital Signing and Submission Considerations

Verify the platform meets privacy, notarization and record retention needs before relying on electronic execution.

Document Formats: PDF and DOCX support for editable and locked templates
Audit Trail: Timestamps, IP, and signer metadata retained
Integrations: Connectors for cloud storage and project management

Typical Deadlines and Timelines in a Remodeling Contract

Track critical dates in the contract and related filings to avoid permit delays, lien exposure, and payment disputes.

Permit Application Deadlines:

Apply before work starts; municipal timelines vary by jurisdiction

Progress Payment Dates:

Tie draws to milestone completion and inspection signoffs

Inspection Scheduling:

Schedule inspections promptly after completed stages

Final Completion Date:

Document acceptance procedures and punchlist deadline

Warranty Start:

Specify when warranty begins—typically at final acceptance

Key Project Milestones from Contract to Closeout

Use sequential milestones to manage payments and inspections and to trigger reporting and archiving obligations.

01

Contract Execution

Agreement signed and effective date established

02

Permit Acquisition

Permits obtained and posted at job site

03

Midpoint Inspection

Progress inspection and intermediate payment release

04

Final Acceptance

Completion inspected, punchlist cleared, final payment released

Common Mistakes to Avoid When Preparing a Remodeling Contract

Vague scope descriptions that rely on verbal instructions and lead to disputes over what work is included or excluded.
Undefined payment triggers and retainage terms that create disagreement about when invoices are due or what constitutes a completed milestone.
Missing permit and inspection responsibilities which can lead to municipal stop-work orders and increased costs.
Failing to require proof of insurance and lien waivers, exposing the owner to unpaid subcontractor claims or the contractor to uncovered risk.

Penalties and Risks from an Incomplete or Incorrect Contract

Permit Violations: Stop-work orders

Lien Exposure: Mechanic's lien claims

Payment Disputes: Withheld payments or litigation

Warranty Gaps: Denied defect claims

Insurance Denial: Coverage disputes on claims

Regulatory Fines: Municipal penalties

Supporting Documents Commonly Attached to a Remodeling Contract

Attach and reference key documents so the contract controls and parties know which exhibits and plans form part of the agreement.

Construction Plans

Detailed drawings, specifications and scope exhibits that define finished work, dimensions, materials and installation standards referenced in the contract as enforceable attachments.

Permit Documents

Copies of permit applications and issued permits; include permit numbers and issuance dates so inspections and municipal records match contract milestones.

Insurance Certificates

Current certificates of liability and workers' compensation naming required additional insured parties and policy effective dates for the project period.

Lien Waivers

Conditional and unconditional waivers tied to payments to document releases of lien rights as draws are completed and paid.

Examples of How Remodeling Contracts Are Used

Real-world scenarios show typical contract choices for scope, payment, and dispute handling in residential and light commercial remodels.

Owner Renovation Scenario

A homeowner hires a licensed contractor for kitchen remodel with fixed price and 10% retainage

Contractor requires 30% deposit for materials
The contract attaches plans, payment schedule, and a 1‑year workmanship warranty and specifies final acceptance procedures to release retainage.

Multi‑Trade Coordination

A property manager contracts a general contractor for apartment rehab using milestone draws and lien waiver chain-of-title

General contractor coordinates subs and provides certificates of insurance
The contract mandates permits, staggered inspections, and a 2‑year defect remediation period.

Comparing eSignature Options for Executing Remodeling Contracts

This table summarizes basic pricing and feature distinctions across common eSignature providers; signNow is listed first per comparison convention.

	signNow	DocuSign	Adobe Sign	PandaDoc	HelloSign
Starting Price	$8/user/mo	$15/user/mo	$14/user/mo	$19/user/mo	$15/user/mo
Free Trial	7-day free trial	Free trial available	Free trial available	Free trial available	Free trial available
Bulk Send	Yes	Yes	Yes	Yes	No
Audit Trail	Yes	Yes	Yes	Yes	Yes
HIPAA Compliant	Yes	Yes	Yes	No	No

Frequently Asked Questions About Remodeling Contracts

Answers to common questions about execution, electronic signatures, notarization, and dispute prevention for remodeling contracts.

Need help? Contact support

Can a Remodeling Contract be signed electronically?
Yes. Electronic signatures are generally enforceable under the federal ESIGN Act (15 U.S.C. ch. 96) and state UETA statutes in most jurisdictions. Ensure intent, consent, attribution and reliable record retention to meet legal validity tests.
When is notarization required?
Notarization is rarely required for ordinary remodeling contracts but may be necessary for related instruments such as easements, deed amendments, or some power of attorney documents; verify municipal or lender requirements.
Do I need witnesses for the contract?
Most states do not require witnesses for a standard remodeling contract. Witness requirements typically apply to wills, deeds, or specific statutory instruments rather than ordinary construction agreements.
How should change orders be documented?
Require written, signed change orders that describe scope adjustments, cost impact, and schedule effects. Link approval authority and thresholds in the contract to prevent oral change disputes.
What if a subcontractor files a lien?
Preserve payment records, lien waivers, and correspondence. Follow state mechanic's lien statutes for notice and contest procedures; timely payment and conditional waivers reduce lien exposure.
How long should I keep signed contracts?
Retain signed contracts at least for the active term plus three years; for tax or real estate matters keep longer. For healthcare settings follow HIPAA retention rules of six years (45 CFR §164.530(j)).

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now