Establishing secure connection…Loading editor…Preparing document…

Roofing Contractor Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

ROOFING CONTRACTOR AGREEMENT

Parties and Recitals

This Roofing Contractor Agreement (the Agreement) is entered into between Owner: , whose address for notices is , and Contractor: , license number: .

WHEREAS, Owner is the legal owner of the property located at: (the Property); and

WHEREAS, Contractor represents that it is duly licensed, insured and experienced in roofing construction and renovation and agrees to furnish labor, materials and supervision necessary to perform the Work described herein; and

WHEREAS, Owner desires to engage Contractor, and Contractor agrees to perform the roofing Work on the terms and conditions set forth in this Agreement.

Scope of Work

Contractor shall furnish all labor, materials, equipment and supervision necessary to complete the Work in a professional and workmanlike manner in accordance with standard industry practices and applicable codes. Materials shall be new unless otherwise agreed in writing. Any deviations from the Scope of Work shall require a written Change Order signed by both parties.

Payment Terms

Owner shall make payments in accordance with the Payment Schedule. If any undisputed amount is not paid when due, Contractor may suspend work after providing days' written notice. Late payments shall accrue the Late Payment Fee specified above and Contractor's reasonable collection costs, including attorney fees.

Change Orders

Any change in the Scope of Work, contract price, or schedule shall be made only by written Change Order executed by both parties. Change Orders shall set forth the additional cost or credit and adjustment to the completion schedule.

Term and Termination

This Agreement commences on Start Date: and is estimated to be Substantially Complete by End Date: subject to adjustments for delays and Change Orders.

Either party may terminate this Agreement for material breach by the other if the breaching party fails to cure the breach within days' written notice. Owner may terminate for convenience upon payment of Contractor's documented costs, reasonable profit on work performed to date, and demobilization expenses.

Warranties and Final Completion

Contractor warrants that materials and workmanship furnished under this Agreement shall be free from defects for a period of from the date of final completion. This warranty does not cover damage due to acts of God, improper maintenance, or Owner-caused damage.

Permits, Inspections, Insurance

Contractor shall secure and pay for all permits and inspections required for the performance of the Work unless otherwise stated in the Scope of Work. Contractor shall maintain commercial general liability insurance, workers' compensation and automobile liability insurance with limits customary for the industry and shall provide proof of insurance to Owner upon request.

Indemnification and Liens

Contractor shall indemnify, defend and hold harmless Owner from losses, claims, damages and liabilities arising from Contractor's performance of the Work, except to the extent caused by Owner's negligence. Contractor shall pay subcontractors and suppliers and shall promptly release and discharge any mechanics' or materialmen's liens arising from Contractor's failure to pay.

Confidentiality

Neither party shall disclose confidential business information of the other party obtained in connection with this Agreement to third parties without prior written consent, except as required by law. Confidential information does not include information that is publicly available or rightfully received from a third party without obligation of confidentiality.

Safety and Compliance

Contractor shall comply with all federal, state and local safety and environmental laws and regulations, including OSHA requirements. Contractor shall maintain a safe jobsite and promptly remove debris and waste associated with the Work.

Governing Law; Dispute Resolution

This Agreement shall be governed by the laws of the State selected by the parties: . The parties shall attempt to resolve disputes in good faith. If unresolved, disputes shall be resolved by binding arbitration or litigation as selected by the parties in writing.

Entire Agreement

This Agreement, including all referenced exhibits and Change Orders, constitutes the entire agreement between the parties with respect to the Work and supersedes all prior negotiations and agreements. No amendment shall be effective unless in writing and signed by both parties.

Notices

Notices under this Agreement shall be delivered to the addresses below. Notice to Owner: , Address: , Phone: .

Notice to Contractor: , Address: , Phone: .

Attachments and Exhibits

Certifications

Each party certifies that the person executing this Agreement on its behalf is authorized to bind the party to the terms and conditions herein and that the party will comply with all applicable laws, codes and regulations in performing its obligations.

Contractor Name:

By:

Date:

Owner Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Roofing Contractor Agreement Covers and Why it Matters

A Roofing Contractor Agreement is a written contract that defines the relationship between a property owner and a roofing contractor, including the scope of work, materials, timeline, price, payment schedule, permits, warranties, insurance, and dispute-resolution terms. It allocates risk, establishes expectations for change orders and inspections, and creates a record used for permitting, lien rights, insurance claims, and tax reporting. Using a clear, signed agreement reduces misunderstandings on-site and supports enforcement of payment and warranty obligations if a dispute arises.

Why a Clear Agreement Protects Both Parties

A well-drafted Roofing Contractor Agreement clarifies deliverables, reduces change-order disputes, enables lien and insurance processes, and documents acceptance. It supports compliance with licensing and permit requirements and strengthens legal enforceability under ESIGN/UETA when signed electronically (15 U.S.C. §7001; UETA).

Why a Clear Agreement Protects Both Parties

Who Typically Prepares and Signs This Agreement

Common participants include property owners, residential and commercial roofing contractors, project managers, and financing parties who need documented terms before work begins.

  • Homeowners and landlords seeking clarity on materials, schedule, and warranties.
  • Licensed roofing contractors establishing scope, payment milestones, and liability limits.
  • Property managers and general contractors coordinating multiple trades and permitting.

The agreement also serves lenders, insurers, and counsel as an evidentiary record for financing, claims, and dispute resolution.

Step-by-step: Completing a Roofing Contractor Agreement

Follow a consistent sequence to reduce errors: gather license/insurance info, define scope, set price and schedule, include change-order and lien clauses, obtain signatures, and distribute copies to stakeholders.

  • 01
    Gather Documents: Collect contractor license, insurance certificates, and project plans.
  • 02
    Define Scope: Describe specific roof areas, materials, and workmanship standards.
  • 03
    Set Price & Schedule: List total price, payment milestones, and completion dates.
  • 04
    Sign & Distribute: Obtain signatures and keep executed copies for permits and claims.

Essential Clauses Every Roofing Contractor Agreement Should Include

A complete agreement organizes responsibilities and remedies by grouping related terms into clear, enforceable clauses tailored to roofing projects and local regulatory requirements.

Scope of Work

Detailed description of work, materials, locations, and workmanship standards so deliverables and inspections are unambiguous.

Price and Payment

Total contract price, deposit, payment milestones, retainage, and remedies for nonpayment to protect cash flow and enforce collection.

Schedule

Start date, completion date, and deadlines for change orders and inspections to manage expectations and delay claims.

Change Orders

Procedure for authorizing and pricing extra work, including signed written approval before additional work begins.

Warranties

Express workmanship and material warranties, duration, and procedures for claims and repairs.

Insurance & Indemnity

Required liability and workers' compensation coverage, certificate delivery timing, and indemnification language for third-party claims.

Required Information to Collect on the Agreement

Contractor License: State license number
Insurance Details: Carrier and policy limits
Project Address: Street, city, state, ZIP
Payment Schedule: Deposit and milestone amounts
Materials Spec: Manufacturer and model
Signatory Info: Name, title, contact

How to Configure the Agreement for Online Completion

Set up field rules and signer roles before sending: choose authentication, add conditional fields for change orders, attach insurance docs, and enable payment collection if required.

Field | Configuration Name and role | Required | Format validation
Authentication Level Email + SMS code or ID verification
Conditional Fields Show change-order block only when selected
Payment Collection Enable ACH/card collection on signature
Attachments Required Require upload of insurance certificate

Where to Send or File the Executed Agreement

After signatures, distribute the executed agreement to parties and relevant agencies; keep signed copies for permitting, lien rights, insurance, and tax records.

  • Owner / Contractor: Each party retains an executed copy for records.
  • Local Building Department: Attach to permit application when required.
  • Insurance Carrier: Provide for claims and certificate verification.
  • Lender or Escrow: Submit if construction financing or escrow is used.

Digital Signing and Delivery Requirements

Choose a signing platform that supports PDF/DOCX, secure authentication, and an auditable completion certificate for evidentiary purposes.

  • File Formats: PDF and DOCX supported
  • Integrations: Procore, NetSuite, Google Workspace
  • Authentication: Email, SMS code, or KBA

Ensure the provider offers tamper-evident signed copies and a reliable audit trail to satisfy permitting, lender, and insurance requirements.

Common Timelines and Filing Deadlines to Track

Track permit, payment, lien, and tax deadlines to avoid penalties; some federal tax reporting deadlines also apply to payments made to contractors.

Permit Filing:

Submit before work begins per local schedule

Payment Milestones:

Due on stated milestone completion dates

Mechanic's Lien Notice:

State-specific deadline to preserve lien rights

1099-NEC Reporting:

Issue contractor Form 1099-NEC by Jan 31 (IRS)

Warranty Period Deadlines:

Start on effective or completion date

Common Preparation Errors to Avoid

  • Using vague scope language that omits specific materials, roof sections, or workmanship standards, which leads to disputes.
  • Failing to confirm contractor licensing or adequate insurance limits before starting work, risking uncovered claims.
  • Missing permit or local code references in the agreement, resulting in stop-work orders or fines.
  • Omitting a clear change-order process and pricing method, allowing disagreements over extra work and costs.

Key Risks and Legal Consequences of an Incomplete Agreement

Mechanic's Lien Risk: Late or improper notice can bar lien enforcement
Permit Violations: Fines and stop-work orders
Insurance Claim Denial: Coverage gaps from missing certificates
Contractor Licensing: Fines or suspension for unlicensed work
Payment Disputes: Collection cost and litigation exposure
Tax Reporting: 1099 errors may trigger IRS penalties

Practical Examples of Agreement Clauses in Use

Two short examples illustrate how specific clauses resolve common project issues and reduce disputes.

Case Study 1

A homeowner required a detailed materials list before approving work

  • The contractor added a product schedule to the agreement
  • Having the list prevented a dispute over shingle grade and streamlined the warranty claim process.

Case Study 2

A contractor included a written change-order clause and pricing matrix

  • The owner requested extra flashing during installation
  • The pre-agreed process and pricing avoided a payment delay and preserved project schedule.

eSignature Pricing and Feature Snapshot for Contract Execution

Compare typical starting prices and core features for common eSignature providers; signNow is listed first per platform comparison conventions.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Frequently Asked Questions About Roofing Contractor Agreements

Answers to common questions on signing, enforceability, notarization, and changes during construction.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.