Establishing secure connection…Loading editor…Preparing document…

Sub-Contract Services Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Sub-Contract Services Agreement

This Sub-Contract Services Agreement ("Agreement") is made and entered into as of Effective Date: by and between Prime Contractor: a/an with principal place of business at and Subcontractor: a/an with principal place of business at .

Recitals

WHEREAS, Prime Contractor has entered into or will enter into one or more contracts with third parties for the provision of services and requires certain services to be performed by qualified subcontractors; and

WHEREAS, Subcontractor represents that it has the skill, experience and resources necessary to perform the services described in this Agreement and is willing to perform such services under the terms and conditions set forth herein; and

WHEREAS, Prime Contractor desires to engage Subcontractor on a subcontract basis, and Subcontractor desires to accept such engagement, subject to the terms of this Agreement.

NOW THEREFORE, in consideration of the mutual covenants and promises set forth below, the parties agree as follows:

1. Scope of Services

1.1 Services. Subcontractor shall perform the services described in the Scope of Services attached hereto or described below (the "Services"). Subcontractor shall perform the Services in a professional, workmanlike manner consistent with industry standards.

1.2 Changes. Any material change in the scope, specifications, schedule, or deliverables shall be made only by written change order executed by authorized representatives of both parties. Subcontractor shall not proceed with changed work until authorized in writing.

2. Term

2.1 Term. The term of this Agreement shall commence on Start Date: and shall continue until Completion Date: , unless earlier terminated in accordance with Section 11.

3. Compensation; Payment

3.1 Compensation. Prime Contractor shall pay Subcontractor for the Services the total amount set forth below or calculated in accordance with the pricing method below. Payment is contingent on Subcontractor's compliance with this Agreement and receipt of properly documented invoices.

3.2 Invoices. Subcontractor shall submit invoices itemizing work performed and expenses incurred. Prime Contractor shall pay undisputed portions of invoices within days of receipt.

4. Expenses; Taxes

4.1 Expenses. Unless otherwise agreed in writing, Subcontractor shall bear its own overhead and all costs and expenses incurred in performing the Services. Reimbursable expenses must be pre-approved in writing and will be reimbursed upon presentation of reasonable documentation.

4.2 Taxes. Subcontractor is solely responsible for all federal, state and local taxes, contributions and other liabilities related to its performance under this Agreement.

5. Relationship; Subcontracting

5.1 Independent Contractor. Subcontractor acknowledges that it is an independent contractor and not an employee, agent, or partner of Prime Contractor. Subcontractor shall have no authority to bind Prime Contractor except as expressly provided in this Agreement.

5.2 Subcontracting. Subcontractor shall not assign or subcontract all or any part of the Services without the prior written consent of Prime Contractor. Any permitted subcontracting shall not relieve Subcontractor of its obligations and Subcontractor shall remain fully responsible for the acts and omissions of permitted subcontractors.

6. Confidentiality

6.1 Confidential Information. Each party may disclose confidential or proprietary information to the other in connection with the Services. The receiving party shall hold such information in confidence and shall not disclose it to third parties except as required by law or with the disclosing party's prior written consent.

6.2 Duration. The confidentiality obligations in this Section shall continue for years following termination or expiration of this Agreement.

7. Intellectual Property

7.1 Work Product. Unless otherwise agreed in writing, all right, title and interest in and to any work product, deliverables, inventions, designs, software, documentation, reports and other materials created by Subcontractor in the course of performing the Services (collectively, "Work Product") shall be the exclusive property of Prime Contractor, and Subcontractor hereby assigns to Prime Contractor all right, title and interest therein.

7.2 Pre-Existing Materials. Subcontractor shall identify any pre-existing materials or tools that it brings to the engagement and shall retain ownership of such pre-existing materials, but grants Prime Contractor a nonexclusive, royalty-free license to use such materials as incorporated in the Work Product.

8. Warranties; Compliance

8.1 Subcontractor Warranties. Subcontractor represents and warrants that (a) it has the full power and authority to enter into and perform this Agreement; (b) the Services will be performed in a professional and workmanlike manner in accordance with industry standards; and (c) the Services and Work Product will not infringe any third party intellectual property rights.

8.2 Regulatory Compliance. Subcontractor shall perform the Services in compliance with all applicable laws, rules, regulations and codes and shall maintain all licenses, permits and certifications required to perform the Services.

9. Indemnification

9.1 Subcontractor Indemnity. Subcontractor shall indemnify, defend and hold harmless Prime Contractor and its officers, directors, employees and agents from and against any and all claims, liabilities, losses, damages, costs and expenses (including reasonable attorneys' fees) arising out of or resulting from Subcontractor's negligence, willful misconduct, breach of this Agreement, or infringement of third party rights in connection with the Services or the Work Product.

9.2 Prime Contractor Indemnity. Prime Contractor shall indemnify, defend and hold harmless Subcontractor from claims to the extent caused by Prime Contractor's gross negligence or willful misconduct, or by Prime Contractor-supplied materials, instructions or designs that infringe third party rights.

10. Insurance

10.1 Minimum Coverage. During the term of this Agreement Subcontractor shall maintain and keep in force insurance appropriate to the Services, including commercial general liability, professional liability (where applicable), and workers' compensation, with limits not less than:

10.2 Certificates. Upon request, Subcontractor shall furnish Prime Contractor certificates of insurance evidencing compliance with the requirements of this Section.

11. Termination

11.1 For Cause. Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure such breach within days after written notice specifying the breach.

11.2 For Convenience. Prime Contractor may terminate this Agreement for convenience upon days' prior written notice to Subcontractor, in which case Prime Contractor shall pay Subcontractor for Services performed and reasonable, documented costs incurred through the effective date of termination.

12. Limitation of Liability

Except for liability arising from willful misconduct, gross negligence or breaches of confidentiality or intellectual property obligations, neither party shall be liable to the other for consequential, incidental, special or punitive damages. The aggregate liability of each party for claims arising out of or related to this Agreement shall not exceed or the total amounts paid under this Agreement, whichever is greater.

13. Notices

All notices, requests, consents and other communications required or permitted under this Agreement shall be in writing and delivered to the addresses specified below (or such other address as a party designates by notice to the other).

14. Assignment

Neither party may assign its rights or delegate its obligations under this Agreement without the prior written consent of the other party, except that Prime Contractor may assign this Agreement in connection with a sale or transfer of substantially all of its assets or business relating to the subject matter hereof. Any purported assignment in violation of this Section shall be void.

15. Amendments; Waiver

This Agreement may be amended or modified only by a written instrument signed by authorized representatives of both parties. No failure or delay by either party in exercising any right shall operate as a waiver of that right.

16. Counterparts; Electronic Signatures

This Agreement may be executed in counterparts, each of which shall be deemed an original and all of which together shall constitute one instrument. Signatures delivered by electronic means shall be deemed originals and binding.

17. Governing Law; Venue

This Agreement shall be governed by and construed in accordance with the laws of the State of without regard to its conflict of laws principles. The parties submit to the exclusive jurisdiction of the state and federal courts located in that state for disputes arising out of this Agreement.

18. Entire Agreement; Severability

This Agreement, including any attachments or exhibits hereto, constitutes the entire agreement between the parties with respect to its subject matter and supersedes all prior oral or written agreements, representations and understandings. If any provision of this Agreement is held invalid or unenforceable, the remaining provisions shall remain in full force and effect and the invalid provision shall be reformed to the extent necessary to make it enforceable.

19. Miscellaneous

The parties acknowledge that each has had the opportunity to review and negotiate the terms of this Agreement with legal counsel. Headings are for convenience only and shall not affect interpretation.

Prime Contractor (Printed Name):

By:

Date:

Subcontractor (Printed Name):

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Sub-Contract Services Agreement Is and when it applies

A Sub-Contract Services Agreement is a written contract where a primary contractor engages a subcontractor to perform specified services for a particular project or scope of work. It sets parties' identities, the exact services to be delivered, performance schedule, payment terms, insurance and bonding expectations, intellectual property ownership where relevant, confidentiality, and dispute resolution. These agreements govern the subcontractor relationship without changing the prime contractor’s obligations to the project owner, and they are commonly used across construction, facilities, professional services, and technology engagements to allocate risk and payment flows.

Why a clear Sub-Contract Services Agreement matters

A well-drafted agreement reduces disputes, clarifies payment and insurance responsibilities, supports compliance with tax and labor rules, and preserves evidence for claims or audits. It ensures expectations for scope, timelines, and deliverables are documented and enforceable, helping both contractors and subcontractors manage risk effectively.

Why a clear Sub-Contract Services Agreement matters

Which parties commonly prepare and sign subcontract agreements

Use the agreement to create a clear operational and legal framework; when signing electronically, preserve audit trails and evidence of consent for enforceability.

  • General contractors managing multiple trades and contractual flow-down obligations between owner and subcontractors.
  • Subcontracting firms or independent tradespeople hired to perform discrete portions of a project.
  • Procurement, project management, or legal staff who review terms, insurance, and invoicing requirements.

Primary signers and typical roles

General Contractor — Project Manager

A project manager or authorized contracting officer frequently signs on behalf of the prime contractor. They must ensure contract language aligns with the owner contract, confirm insurance and bonding, and approve subcontractor deliverables and invoices to avoid conflicts with higher-tier obligations.

Subcontractor — Business Owner

An authorized owner, partner, or corporate officer signs for the subcontractor. The signer should have the authority to bind the business, confirm insurance coverage, and accept payment terms; lacking authority can raise enforceability issues later.

Core clauses every Sub-Contract Services Agreement should include

A complete agreement clearly identifies parties, scope, schedule, payment, liability allocation, and dispute resolution. Including these clauses reduces ambiguity and provides enforcement pathways if issues arise during performance.

Parties

Full legal names, business entity type, and contact information for prime contractor and subcontractor to ensure correct attribution and tax reporting.

Scope of Work

Detailed description of tasks, deliverables, performance standards, milestones, and any drawings or exhibits that define acceptance criteria.

Payment Terms

Total price or rate, invoicing frequency, retainage (if any), payment period, and conditions for withholding or set-off.

Insurance & Indemnity

Required insurance types and limits, proof of coverage, indemnity scope, and duties to defend to allocate risk between parties.

Term & Termination

Start and end dates, termination for convenience or cause, notice periods, and post-termination duties such as project closeout or return of materials.

Dispute Resolution

Choice of law, venue, and whether disputes go to mediation, arbitration, or courts, plus clauses on attorneys’ fees and recovery of costs.

Step-by-step: Completing and executing the agreement

Follow these steps to prepare, review, and sign a Sub-Contract Services Agreement reliably, whether on paper or electronically.

  • 01
    Prepare Document: Populate fields and attach exhibits.
  • 02
    Review Terms: Legal and insurance review before approval.
  • 03
    Obtain Signatures: Collect authorized signatures and dates.
  • 04
    Distribute Copies: Send final executed copies to all parties.

Suggested digital workflow settings for e-signature

Configure signer order, authentication, and retention settings to match your risk profile and any industry compliance needs.

Field Configuration
Signer Order Sequential or parallel signer order, depending on approvals.
Authentication Use email link or SMS code; KBA for higher assurance.
Conditional Fields Show fields only when specific options are selected to reduce signer errors.
Retention & Audit Enable audit trail, timestamping, and secure storage.

How digital signing and routing works for subcontract agreements

A typical online signing flow minimizes friction while preserving evidence of signer intent and identity. Configure steps to match internal approvals.

  • Upload and Tag: Upload PDF/DOCX and place signature fields.
  • Add Signers: Enter emails and assign field roles.
  • Authenticate: Signers verify identity by email/SMS or KBA.
  • Complete and Archive: Signed copies and audit trail are saved.

Technical considerations for e-submission and integrations

Confirm the platform provides secure storage, audit trails, export options, and any industry-specific compliance such as HIPAA or 21 CFR Part 11 if required.

  • CRM Integrations: Salesforce, NetSuite supported
  • Cloud Storage: Google Drive, Box, Egnyte
  • Document Formats: PDF, DOCX, Excel supported

eSignature vendor comparison for executing Sub-Contract Services Agreements

Platform features and pricing vary. This comparison highlights starting price, basic capabilities, and HIPAA availability; signNow appears first per vendor alignment.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial, no card Varies by vendor Varies by vendor Free limited plan Free limited plan
Bulk Send Yes (Business Premium) Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Essential contract data and risk controls to include

Legal Names: Exact entity names
Tax ID: EIN or SSN/TIN
Scope: Clear deliverable list
Payment Terms: Currency, timing
Insurance: Coverage types and limits
Signatures: Authorized signers and dates

Key legal and financial risks of incomplete or incorrect agreements

Invalid Signature: May render contract unenforceable
Late Payment: Leads to interest and lien claims
Unclear Scope: Increases dispute and change order risk
No Insurance: Exposes party to uncovered losses
Misclassification: Triggers payroll and tax penalties
Tax Reporting: 1099 penalties (IRC §6721) possible

Common mistakes to avoid when preparing a subcontract

  • Using vague scope language such as 'reasonable efforts' without measurable criteria, which creates disputes over completion and payment.
  • Failing to confirm signatory authority so a signer cannot legally bind the entity, increasing litigation risk and delaying enforcement.
  • Omitting insurance or indemnity specifications, which can leave parties exposed to third-party claims or uncovered project losses.
  • Neglecting tax and classification issues for workers, which can lead to IRS or state agency penalties and retroactive liabilities.

Practical practices to reduce risk and speed execution

Apply consistent internal controls and standardized terms to reduce negotiation time and minimize errors that slow approvals and payments.

Standardize templates
Keep a vetted standard subcontract template and attach project-specific exhibits. This reduces drafting time and ensures consistent risk allocation across projects.
Confirm authority in advance
Require signers to certify their authority in the signature block and verify business registration details before execution to prevent later disputes.
Use conditional fields
Configure the form to show insurer details, retainage, or bonding only when applicable to limit signer confusion and reduce incomplete submissions.
Preserve audit trails
Capture timestamps, IP addresses, and authentication events for each signer so signed agreements are reproducible and admissible if contested.

Real-world examples of subcontract agreements in use

These brief examples illustrate common scenarios where subcontract agreements helped organizations standardize execution and maintain compliance.

Martin Properties — Construction

A small construction firm needed remote execution across multiple sites with mobile signing.

  • They implemented online signing for rapid approvals.
  • "I can process and execute all of these documents online with 100% compliance and built-in security. Whether on mobile or working offline, I can get forms back to their necessary parties efficiently."

Xerox — Systems Integration

A large enterprise subcontracted NetSuite integrators across regions requiring consistent contract templates.

  • Centralized templates reduced negotiation cycles.
  • "airSlate SignNow provides us with the flexibility needed to get the right signatures on the right documents, in the right formats, based on our integration with NetSuite."

Key dates and filing or reporting deadlines to track

Track effective dates, cure periods, payment milestones, insurance renewals, and tax reporting deadlines to avoid penalties and project delays.

Effective Date:

Date when obligations begin; use MM/DD/YYYY format.

Notice to Cure:

Specify days to cure before termination or liquidated damages apply.

Payment Milestones:

Dates for interim payments, retainage release, and final invoice due.

Insurance Renewal:

Require certificates renewed before expiration to maintain coverage continuity.

Tax Reporting:

1099-NEC to recipients and IRS is due Jan 31 each year for nonemployee compensation.

Key milestones from drafting to closeout

Follow this sequential milestone view to manage the contract lifecycle and responsibilities at each stage.

01

Drafting

Prepare template and project-specific exhibits for review.

02

Approval

Internal stakeholders confirm scope, cost, and insurance.

03

Execution

Collect signatures and distribute executed copies.

04

Performance & Closeout

Track milestones, accept deliverables, and issue final payments.

Common questions and answers about Sub-Contract Services Agreements

Answers to frequent issues about enforceability, e-signatures, notarization, tax reporting, and document changes to help parties close agreements correctly.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.