Establishing secure connection…Loading editor…Preparing document…

Subcontractor MSA Agreement

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

MASTER SUBCONTRACTOR SERVICES AGREEMENT

This Master Subcontractor Services Agreement (the "Agreement") is made and entered into as of by and between Contractor Name: , a legal entity organized as , with principal place of business at (hereinafter "Contractor"), and Subcontractor Name: , a legal entity organized as , with principal place of business at (hereinafter "Subcontractor"). Contractor and Subcontractor are each a "Party" and together the "Parties."

RECITALS

WHEREAS, Contractor has entered, or intends to enter, into one or more prime contracts, purchase orders or agreements with third parties pursuant to which Contractor requires certain services, materials, or deliverables; and

WHEREAS, Subcontractor represents that it has the skill, experience and resources to perform such services and deliverables in accordance with the requirements of Contractor and applicable prime contracts; and

WHEREAS, the Parties desire to set forth the general terms and conditions under which Subcontractor will perform Services for Contractor from time to time.

NOW, THEREFORE, in consideration of the mutual covenants herein contained, the Parties agree as follows:

1. DEFINITIONS

1.1 "Agreement" means this Master Subcontractor Services Agreement and all attachments and Statements of Work incorporated herein.

1.2 "Services" means the services to be performed by Subcontractor as described in a Statement of Work or Purchase Order issued under this Agreement. Each Statement of Work shall specify scope, deliverables, schedule, acceptance criteria and compensation.

1.3 "Work Product" means all deliverables, designs, documentation, software, inventions and other results created, produced, conceived or reduced to practice by Subcontractor in connection with the Services.

2. SCOPE OF WORK; STATEMENTS OF WORK

2.1 Subcontractor shall perform Services as set forth in one or more written Statements of Work executed by authorized representatives of the Parties. Each Statement of Work shall reference this Agreement and, except as expressly provided in a Statement of Work, all terms of this Agreement shall govern.

3. TERM; TERMINATION

3.1 Term. This Agreement commences on the effective date set forth above and will remain in effect until terminated in accordance with this Section.

3.2 Termination for Convenience. Either Party may terminate this Agreement or any Statement of Work for convenience upon days written notice to the other Party. In the event of termination for convenience, Contractor shall pay Subcontractor for Services performed and approved Deliverables rendered through the effective date of termination, subject to setoffs for Contractor's damages.

3.3 Termination for Cause. Either Party may terminate for material breach that remains uncured after thirty (30) days written notice specifying the nature of the breach. Termination shall be without prejudice to remedies available at law or equity.

4. COMPENSATION; PAYMENT

4.1 Fees. Contractor shall pay Subcontractor fees in accordance with the rates, milestones or price schedule set forth in each Statement of Work. Subcontractor shall not invoice for any amounts beyond those specified without the prior written consent of Contractor.

4.2 Set-Offs; Withholding. Contractor may withhold or set off amounts reasonably necessary to protect Contractor from loss resulting from Subcontractor's breach, defective performance, or failure to satisfy third-party claims.

5. TAXES

Subcontractor is solely responsible for all federal, state and local taxes, contributions and any other liabilities arising from compensation paid to Subcontractor or its personnel. Subcontractor shall indemnify Contractor for any taxes or penalties assessed against Contractor attributable to Subcontractor's failure to pay required amounts.

6. INSURANCE

6.1 Subcontractor shall maintain insurance coverage customary and adequate for the Services, including commercial general liability, workers' compensation, employer's liability and professional liability where applicable. Minimum limits: Commercial General Liability ; Professional Liability .

6.2 Certificates of Insurance evidencing required coverage shall be provided to Contractor upon request and shall provide for thirty (30) days' written notice to Contractor prior to cancellation or material change.

7. INDEPENDENT CONTRACTOR

Subcontractor is an independent contractor. Nothing in this Agreement creates an employment, joint venture, partnership or agency relationship. Subcontractor shall have sole control over the means and methods of performing the Services and shall be responsible for its own personnel, subcontractors and equipment.

8. CONFIDENTIALITY

8.1 Definition. "Confidential Information" means non-public information disclosed by one Party to the other, whether oral, written, electronic or otherwise, that is designated as confidential or that reasonably should be understood to be confidential.

8.2 Obligations. Receiving Party shall (a) use Confidential Information only to perform its obligations under this Agreement, (b) restrict access to those employees and contractors who have a need to know, and (c) protect Confidential Information with at least the same degree of care used to protect its own confidential information, but no less than reasonable care. Confidential Information shall not include information that is publicly available through no fault of the Receiving Party, independently developed by the Receiving Party, or rightfully received from a third party without restriction.

9. WORK PRODUCT AND INTELLECTUAL PROPERTY

9.1 Ownership. Unless otherwise agreed in a Statement of Work, all Work Product resulting from Services shall be considered "work made for hire" and ownership shall vest in Contractor upon creation. To the extent ownership does not vest automatically, Subcontractor hereby assigns and transfers all right, title and interest in and to the Work Product to Contractor, including all intellectual property rights.

9.2 License to Pre-Existing Materials. Subcontractor hereby grants Contractor a perpetual, worldwide, royalty-free, transferable license to any pre-existing Subcontractor materials incorporated into the Work Product to the extent necessary for Contractor to use, sell or modify the Work Product.

10. WARRANTIES

Subcontractor warrants that: (a) the Services will be performed in a professional, workmanlike manner in accordance with industry standards; (b) Work Product will conform to the specifications set forth in the applicable Statement of Work; and (c) Subcontractor has full power and authority to grant the rights granted herein. The warranty period is from acceptance unless otherwise specified.

11. INDEMNIFICATION

11.1 Subcontractor Indemnity. Subcontractor shall defend, indemnify and hold harmless Contractor and its officers, directors, employees and agents from and against any and all claims, liabilities, damages, losses and expenses (including reasonable attorneys' fees) arising out of or resulting from Subcontractor's negligent acts, omissions, willful misconduct, breach of this Agreement or infringement of third-party intellectual property rights by the Work Product.

11.2 Contractor Indemnity. Contractor shall defend and indemnify Subcontractor for claims arising out of Contractor's breach of the prime contract where such indemnity is required by applicable law or the prime contract and to the extent Contractor is responsible under applicable law.

12. LIMITATION OF LIABILITY

EXCEPT FOR LIABILITY ARISING FROM A PARTY'S GROSS NEGLIGENCE, WILLFUL MISCONDUCT, OR INDEMNIFICATION OBLIGATIONS, NEITHER PARTY SHALL BE LIABLE TO THE OTHER FOR SPECIAL, INDIRECT, INCIDENTAL, PUNITIVE OR CONSEQUENTIAL DAMAGES. CONTRACTOR'S AGGREGATE LIABILITY UNDER THIS AGREEMENT SHALL NOT EXCEED THE TOTAL AMOUNTS PAID OR PAYABLE TO SUBCONTRACTOR UNDER THE APPLICABLE STATEMENT OF WORK DURING THE TWELVE (12) MONTHS PRECEDING THE EVENT GIVING RISE TO LIABILITY.

13. COMPLIANCE WITH LAWS; EXPORTS

Each Party shall comply with all applicable laws, regulations and orders in performance of its obligations hereunder, including export control, anti-corruption and privacy laws. Subcontractor shall obtain and maintain all licenses, permits and approvals necessary to perform the Services.

14. SUBCONTRACTING; ASSIGNMENT

Subcontractor shall not subcontract or assign any material portion of the Services or this Agreement without Contractor's prior written consent, which consent shall not be unreasonably withheld. Subcontractor remains responsible for the acts and omissions of its permitted subcontractors.

15. NOTICES

All notices required or permitted under this Agreement shall be in writing and delivered to the addresses set forth below or such other address as either Party may designate by written notice to the other in accordance with this Section. Notices shall be deemed given when delivered personally, sent by certified mail (return receipt requested), or sent by nationally recognized overnight courier.

16. AMENDMENTS; WAIVER

No amendment, modification or waiver of any provision of this Agreement will be effective unless in writing and signed by authorized representatives of both Parties. No failure or delay in exercising any right shall operate as a waiver.

17. SEVERABILITY

If any provision of this Agreement is held invalid or unenforceable, the remaining provisions shall remain in full force and effect and the Parties shall negotiate in good faith to replace the invalid provision with a valid provision that accomplishes the original intent to the greatest extent possible.

18. GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be governed by and construed in accordance with the laws of the state of , without regard to conflicts of law principles. The Parties shall first attempt in good faith to resolve disputes through negotiation. If unresolved within sixty (60) days, the Parties may pursue injunctive or other equitable relief and any remaining dispute shall be resolved by final and binding arbitration conducted in the county designated by Contractor under the rules of a recognized arbitration institution. The arbitrator shall have authority to award any remedies permitted by law.

19. ENTIRE AGREEMENT

This Agreement, together with all executed Statements of Work and exhibits, constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes all prior and contemporaneous negotiations, proposals, representations, warranties and agreements, whether written or oral.

20. COUNTERPARTS; EXECUTION

This Agreement may be executed in counterparts and by electronic signature, each of which shall be deemed an original and all of which together shall constitute one and the same instrument.

MISCELLANEOUS

20.1 No Third-Party Beneficiaries. Except as expressly provided in a prime contract requiring flow-down provisions, this Agreement is for the sole benefit of the Parties and their permitted successors and assigns and does not confer any rights on third parties.

20.2 Force Majeure. Neither Party shall be liable for delays or failures in performance due to causes beyond its reasonable control, provided the affected Party gives prompt written notice and uses commercially reasonable efforts to resume performance.

SIGNATURES

Contractor

Printed Name:

By:

Title:

Date:

Subcontractor

Printed Name:

By:

Title:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Subcontractor MSA Agreement Is and when it applies

A Subcontractor MSA Agreement is a master services agreement that sets the ongoing commercial and legal relationship between a primary contractor and one or more subcontractors. It defines the scope of work, payment terms, insurance and indemnity obligations, intellectual property ownership, confidentiality, performance standards, schedules, and procedures for change orders and dispute resolution. The MSA creates a repeatable framework so individual statements of work or purchase orders can reference consistent terms. This agreement type reduces negotiation time on recurring engagements and centralizes risk allocation across project engagements.

Why use a Subcontractor MSA Agreement for repeat projects

A Subcontractor MSA Agreement standardizes commercial terms, clarifies responsibilities, and reduces negotiation overhead for recurring or multi-site work. It protects both parties by predefining liability limits, insurance minimums, intellectual property handling, and termination mechanics, creating legal predictability across multiple projects.

Why use a Subcontractor MSA Agreement for repeat projects

Who typically prepares and signs these agreements

The Subcontractor MSA Agreement is used by contracting parties that expect multiple projects or repeated engagements and want consistent contract terms.

  • General contractors coordinating multiple trade subcontractors across projects and locations, needing uniform indemnity, insurance, and lien waiver provisions.
  • Specialty subcontractors (electrical, plumbing, IT services) who want clear payment schedules, scope boundaries, and IP assignments for recurring engagements.
  • Procurement, legal, or operations teams at owner organizations that require standard third-party service terms and centralized contract records.

Use the MSA as the governing umbrella agreement, then attach project-specific scopes, schedules, or purchase orders that reference the MSA to create binding, streamlined engagements.

Primary signers and their roles

Contractor Executive

Chief procurement or operations officer authorized to bind the general contractor, responsible for accepting indemnity allocations, insurance levels, and payment mechanics on behalf of the prime contractor.

Subcontractor Owner

Company owner or authorized representative who confirms scope acceptance, agrees to warranty and IP clauses, and commits the subcontractor to insurance and safety obligations.

Core clauses to include in a professional Subcontractor MSA Agreement

A robust MSA has targeted provisions that manage risk, payment, performance, and intellectual property across multiple engagements.

Scope

Clearly define services, deliverables, accepted standards, and how change orders are submitted and approved to avoid scope creep and disputes.

Payment

Set invoicing frequency, net payment terms, retainage rules, late fees, and conditions for withholding payment for defects or noncompliance.

Insurance

Specify minimum insurance types and limits, certificate requirements, additional insureds, and notice obligations for policy changes or cancellations.

Indemnity

Allocate responsibility for third-party claims, define indemnifiable losses, and consider mutual indemnity for IP and bodily injury claims.

IP & Data

Address ownership of work product, licenses granted, data handling, and confidentiality protections for proprietary or sensitive information.

Termination

Establish termination for convenience and for cause, cure periods, transition assistance, and final payment procedures following termination.

Essential factual fields the agreement must list

Party Names: Full legal entity names
Scope Description: Summary of services
Payment Terms: Net days and retainage
Insurance Minimums: Type and limits
Effective Date: Start date of MSA
Governing Law: State law choice

Step-by-step: complete and execute a Subcontractor MSA Agreement

Follow these sequential steps to prepare, review, and sign an MSA so it becomes an effective governing contract for future work.

  • 01
    Prepare draft: Populate party details and base clauses.
  • 02
    Attach SOWs: Add project-specific statements of work.
  • 03
    Legal review: Have counsel review risk and indemnity allocations.
  • 04
    Execute: Sign by authorized representatives and distribute fully executed copies.

Online workflow settings to use when sending MSA for signature

Configure your e-signature workflow to capture intent, consent, and a clear audit trail for enforceability.

Field Configuration
Signature Field Require full name and date
Initials Field Place where parties must initial page changes
Attachment Field Include SOW or insurance certificates
Authentication Use email plus optional SMS code

Digital signing, authentication, and file formats

Choose a platform that supports secure eSignatures, retains audit trails, and exports standard signed PDFs.

  • File formats: PDF and DOCX supported
  • Authentication: Email, SMS, or KBA
  • Integrations: CRM and storage integrations

Ensure the solution complies with ESIGN/UETA, supports audit trails and retention, and can produce printable, tamper-evident signed records for future enforcement or audits.

Where to send and how executed copies should be routed

Determine distribution and storage rules to ensure each party receives a complete executed copy and records are retained according to policy.

  • Send to signer: Email or secure link to authorized signatory
  • Collect signatures: Capture signature, date, and audit metadata
  • Distribute copies: Send final PDF to all parties
  • Archive record: Store in contract repository with audit log

Typical timing and notice periods to include

Common timeframes affect payment, cure periods, notice requirements, and warranty durations—set them clearly in the MSA.

Payment due:

Net 30 is common unless otherwise negotiated

Invoice submission:

Monthly or upon milestone completion

Cure period:

Often 10–30 days for breach remediation

Warranty period:

Typically 1 year from acceptance unless modified

Insurance notice:

30 days' notice for cancellation or material change

Common pitfalls when preparing a Subcontractor MSA Agreement

  • Using vague scope language that creates change order disputes and extra costs.
  • Failing to require certificates of insurance and additional insured status for the contractor.
  • Overly broad indemnity clauses that are unenforceable in some jurisdictions.
  • Not specifying invoicing and retainage mechanics, leading to payment delays and disagreements.

Key risks and contractual consequences to address

Payment Withholding: Delayed or disputed payments
Lien Exposure: Mechanic's liens on project property
Insurance Lapse: Potential uninsured losses
Indemnity Claims: Significant third-party liability costs
Termination Costs: Early termination and transition expenses
Tax Liability: Misclassification or withholding penalties

Sample eSignature vendor comparison for executing Subcontractor MSAs

Compare typical vendor starting prices and feature availability for executing and storing signed MSAs; signNow is listed first as the initial vendor column.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial Yes, 7-day trial No No No No
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Practical drafting and execution tips for reliable MSAs

Follow these proven practices to limit disputes, speed approvals, and preserve enforceability of subcontractor MSAs.

Use a single template
Maintain a controlled MSA template with standard clauses and version history; route high-risk edits for legal review to keep consistency across projects and reduce negotiation cycles.
Attach detailed SOWs
Reference one-page or multi-page statements of work for each project that define deliverables, milestones, acceptance procedures, and test criteria so liability and payment trigger events are clear.
Align insurance and indemnity
Match required insurance limits to potential project exposure, require certificates of insurance, and draft indemnity language that is enforceable under the selected governing law.
Capture electronic consent
Use an e-signature workflow that documents signer intent, provides a consumer disclosure when required, and preserves a tamper-evident audit trail for later validation.

Real-world scenarios where an MSA simplifies subcontracting

These example scenarios illustrate how an MSA can streamline repeated engagements and reduce contract administration.

Construction firm

A general contractor standardizes subcontract terms across 20 projects to reduce review time by using a single MSA referenced by each SOW.

  • This removes repetitive negotiation.
  • As a result, project teams execute SOWs faster, reduce invoicing disputes, and maintain consistent insurance and indemnity protections across the portfolio.

IT services provider

A technology prime uses an MSA to define IP ownership and data security obligations for multiple development engagements.

  • IP assignment and data clauses are preapproved.
  • This ensures every project has the same IP outcome, accelerates onboarding of subcontractors, and reduces legal review to exceptional changes only.

Frequently asked questions about Subcontractor MSA Agreements

Answers to common questions about enforceability, electronic signing, revisions, and signature authority for subcontractor MSAs.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.