Trade Services Multi Trade Contract

Trade Services Multi Trade Contract

Parties

Recitals

WHEREAS, Client desires to engage Contractor to perform multi-trade services at the Project Location described below in accordance with the terms and conditions of this Contract;

WHEREAS, Contractor represents that it has the experience, skill, licenses, insurance, and personnel necessary to perform the scope of work for trades including, but not limited to, electrical, plumbing, HVAC, carpentry, and associated finish work; and

WHEREAS, the parties intend that this Contract set forth the complete agreement between them regarding the services described herein.

Project Location & Trades

Trades to be performed (check applicable):

Scope of Work

Contractor shall furnish all labor, materials, equipment, supervision, and services necessary to complete the work described below in a professional and workmanlike manner consistent with industry standards.

Payment Terms

Total Contract Price: $

All invoices are due within days of invoice unless otherwise agreed in writing. Amounts unpaid after such period shall incur a late fee of per month or the maximum permitted by law, whichever is less.

Change Orders

Any changes to the Scope of Work that affect price, quality, or schedule must be authorized in writing by both parties in a written change order describing the change, adjustments to contract price, and schedule modifications.

Term and Termination

This Contract commences on the Start Date and continues through the Completion Date unless sooner terminated in accordance with this section. Start Date: . Completion Date:

Either party may terminate this Contract for convenience or for material breach. For termination without cause, the terminating party shall provide days written notice. Upon termination for convenience, Contractor shall be paid for work performed and documented costs incurred through the effective date of termination.

Insurance, Permits & Compliance

Contractor shall maintain insurance coverage appropriate for the trades performed, including general liability and workers' compensation as required by law, and shall provide certificates of insurance upon Client's request. Contractor shall obtain and pay for all permits, inspections, and fees required by authorities having jurisdiction unless otherwise agreed in writing.

Warranties

Contractor warrants that materials and workmanship furnished under this Contract shall be free from substantial defects for a period of from completion, except for defects caused by normal wear and tear or Client action. Specific warranty details are set forth below.

Confidentiality

Each party shall maintain the confidentiality of information designated as confidential by the other party or information that by its nature should reasonably be considered confidential. Confidential information shall not be disclosed to third parties except as required by law or with the disclosing party's prior written consent. Confidentiality obligations survive termination for a period of two years.

Indemnification

Contractor shall indemnify, defend, and hold harmless Client and its agents from and against any and all claims, liabilities, losses, damages, costs and expenses (including reasonable attorney fees) arising out of Contractor's negligence, willful misconduct, or breach of this Contract, except to the extent caused by Client's negligence or willful act.

Limitation of Liability

Except for liability arising from willful misconduct, gross negligence, or Contractor's indemnity obligations, neither party shall be liable to the other for consequential, incidental, special, or punitive damages. Contractor's aggregate liability for any cause of action arising out of this Contract shall not exceed the total amount paid by Client to Contractor under this Contract.

Dispute Resolution

The parties shall attempt in good faith to resolve disputes promptly through negotiation. If the dispute cannot be resolved within thirty (30) days of written notice, the parties agree to submit the dispute to binding arbitration in the jurisdiction named below. Judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction.

Entire Agreement & Miscellaneous

This Contract, including any referenced attachments and executed change orders, constitutes the entire agreement between the parties and supersedes all prior agreements, representations, and understandings. No modification shall be effective unless in writing and signed by both parties. If any provision of this Contract is held unenforceable, the remaining provisions shall remain in full force and effect. Contractor may not assign this Contract without Client's prior written consent.

Acceptance

By signing below, the parties acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Trade Services Multi Trade Contract.

Sign Now