Establishing secure connection…Loading editor…Preparing document…

Traffic Services Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

TRAFFIC SERVICES CONTRACT

This Traffic Services Contract (the "Agreement") is entered into as of by and between Client Name: , with principal address at (hereinafter "Client"), and Service Provider Name: , with principal address at (hereinafter "Provider").

RECITALS

WHEREAS, Client requires temporary traffic management and control services in connection with roadworks, special events, or construction activities at locations described in this Agreement; and

WHEREAS, Provider is duly qualified, experienced, and equipped to perform such traffic control, including traffic control planning, deployment of personnel, signage, barriers, flagging, and related equipment; and

WHEREAS, Client desires to engage Provider and Provider agrees to provide such services on the terms and conditions set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants contained herein, the parties agree as follows:

1. SCOPE OF SERVICES

1.1 Services. Provider shall furnish all labor, supervision, traffic control devices, signage, cones, barriers, vehicles, and other equipment necessary to perform the traffic management services described in the Project Description attached hereto or set forth below (collectively, the "Services"). Provider shall perform the Services in accordance with the standards of the traffic management industry and applicable law.

1.2 Service Term. Provider shall commence the Services on and shall continue until unless earlier terminated in accordance with this Agreement.

2. COMPENSATION AND PAYMENT

2.1 Fees. Client shall pay Provider for Services at the rates set forth below or as otherwise agreed in writing. Hourly rate per traffic control technician: $ . Estimated total for initial scope: $ .

2.2 Additional Costs. Client shall reimburse Provider for reasonable out-of-pocket expenses approved in advance in writing, including permit fees and special equipment rental. Reimbursable expenses shall be invoiced with supporting documentation.

3. TERM AND TERMINATION

3.1 Termination for Cause. Either party may terminate this Agreement for material breach by the other party if the breaching party fails to cure such breach within days after written notice specifying the breach.

3.2 Termination for Convenience. Client may terminate the Services for convenience upon providing at least days' prior written notice to Provider. In such event Provider shall be entitled to payment for Services performed and reasonable demobilization costs incurred prior to termination.

4. INSURANCE AND INDEMNITY

4.1 Insurance. Provider shall maintain, at its own cost, commercial general liability insurance, automobile liability insurance covering company vehicles, workers' compensation as required by law, and excess/umbrella coverage where appropriate. Provider shall maintain limits not less than those customarily required for traffic control services and shall deliver certificates of insurance to Client upon request.

4.2 Indemnity. Provider shall indemnify, defend, and hold harmless Client, its officers, employees and agents from and against all claims, liabilities, losses, damages and expenses (including reasonable attorneys' fees) arising out of Provider's negligence, willful misconduct, or failure to comply with applicable law in performing the Services. Client shall indemnify Provider for claims arising from Client's negligence or willful misconduct.

5. HEALTH, SAFETY, AND COMPLIANCE

5.1 Compliance. Provider shall perform the Services in compliance with all applicable federal, state and local laws, regulations, and ordinances governing traffic control, safety, and employment. Provider shall obtain any required permits and authorizations unless otherwise agreed in writing.

5.2 Safety Protocols. Provider shall implement and enforce a site-specific safety plan, ensure all personnel are trained for traffic control duties, and promptly report incidents involving personal injury or property damage to Client.

6. EQUIPMENT AND PERSONNEL

6.1 Personnel. Provider shall employ competent, licensed (where required) personnel to perform the Services. Provider is responsible for supervision, direction and control of its employees and subcontractors.

6.2 Equipment. Provider shall supply and maintain all equipment necessary to perform the Services. All equipment shall be maintained in safe operating condition and meet industry standards.

7. CONFIDENTIALITY

Each party shall hold in confidence and not disclose to third parties any nonpublic information disclosed by the other party in connection with this Agreement, except as required by law or as necessary to perform the Services. This obligation shall survive termination of this Agreement for a period of two (2) years.

8. LIMITATION OF LIABILITY

Except for liabilities arising from gross negligence or willful misconduct, each party's aggregate liability to the other for claims arising from or related to this Agreement shall not exceed the total amount paid or payable under this Agreement during the twelve (12) month period preceding the event giving rise to the claim.

9. WARRANTIES

Provider warrants that the Services will be performed in a competent and workmanlike manner consistent with industry standards. Except for the foregoing express warranty, Provider disclaims all other warranties, express or implied, including any warranty of merchantability or fitness for a particular purpose.

10. NOTICES

All notices and other communications required or permitted under this Agreement shall be in writing and shall be delivered to the addresses set forth below or such other address as either party designates by written notice to the other.

11. AMENDMENT; WAIVER

No amendment or modification of this Agreement shall be effective unless in writing and signed by both parties. No failure or delay by either party in exercising any right shall operate as a waiver of that right.

12. ASSIGNMENT

Neither party may assign its rights or delegate its obligations under this Agreement without the prior written consent of the other party, which consent shall not be unreasonably withheld, except that Provider may assign to an affiliate or in connection with a sale of substantially all of its assets.

13. GOVERNING LAW; VENUE

This Agreement shall be governed by and construed in accordance with the laws of the state specified below without regard to conflict of laws principles. The parties submit to the exclusive jurisdiction of the courts located in that state for any action arising out of this Agreement.

14. ENTIRE AGREEMENT; SEVERABILITY; COUNTERPARTS

This Agreement, together with any exhibits and attachments hereto, constitutes the entire agreement between the parties with respect to the Services and supersedes all prior agreements and understandings. If any provision of this Agreement is held invalid or unenforceable, the remaining provisions will remain in full force and effect. This Agreement may be executed in counterparts, each of which shall be deemed an original.

15. MISCELLANEOUS

15.1 Independent Contractor. Provider is an independent contractor and not an employee, partner, or agent of Client. Provider is responsible for withholding and paying all taxes and contributions required by law with respect to Provider's personnel.

15.2 Records. Provider shall maintain accurate time and expense records related to the Services and shall provide such records to Client upon reasonable request.

Client Printed Name:

By:

Date:

Provider Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Traffic Services Contract Is and when it applies

A Traffic Services Contract is a written agreement that defines the allocation of responsibilities, timelines, compensation, insurance, safety protocols, and permit requirements for services that manage traffic flows during construction, events, or maintenance. Typical services include flagging, lane closures, signage, temporary signals, and traffic control device installation. The contract clarifies who obtains permits, who coordinates with municipalities and utilities, and which party bears liability for incidents, damages, or regulatory noncompliance. It is commonly used between contractors, subcontractors, municipalities, and event operators to reduce operational risk and establish payment milestones.

Why a clear Traffic Services Contract matters

A well-drafted Traffic Services Contract reduces dispute risk, clarifies permit and insurance responsibilities, and sets measurable performance and safety standards. It improves coordination with agencies, protects parties from unexpected costs, and documents acceptance criteria for completed traffic control work.

Why a clear Traffic Services Contract matters

Typical parties who prepare or sign this contract

Parties typically exchange the contract before mobilization; insurance certificates, permits, and safety plans should be attached prior to work start.

  • Contractors and subcontractors responsible for on-site traffic management and compliance with local permits and OSHA requirements.
  • Municipalities and public works departments that require indemnities, insurance certificates, and coordination for lane closures.
  • Event organizers and property owners who need to document scope, timing, and financial responsibility for temporary traffic controls.

Core components to include in a professional Traffic Services Contract

A comprehensive contract lays out scope, schedule, payment, safety requirements, insurance, and dispute resolution to make obligations enforceable and reduce operational ambiguity.

Scope of Services

Describe precise traffic control tasks, hours of operation, equipment to be used, and any staging or staging limits. Specify deliverables such as signed daily traffic control logs and as-built diagrams to verify performance.

Schedule & Milestones

List mobilization date, critical lane closure windows, daily work hours, and completion milestones. Include provisions for weather delays, emergency access, and required notifications to traffic agencies for schedule changes.

Payment Terms

State contract value, unit pricing (per hour, per closure, per sign), invoicing cadence, retainage, and acceptable payment methods. Specify when progress payments trigger and documentation required for release.

Permits & Approvals

Allocate responsibility for obtaining permits, traffic control plans, and municipal approvals. Require copies of permits and any special conditions to be attached as exhibits to the contract.

Insurance & Indemnity

Define minimum insurance limits, additional insured endorsements, waiver of subrogation, and indemnity scope. Require insurers and policy numbers on certificate of insurance before work begins.

Health, Safety & QA

Include OSHA-compliant safety protocols, traffic control plan compliance, flagger certifications, and quality acceptance criteria. Specify incident reporting, corrective action timelines, and audit rights.

Essential information to collect on the contract

Party names: Full legal entity names
Effective date: MM/DD/YYYY
Scope summary: Concise service list
Payment details: Rates and billing terms
Insurance limits: Carrier and policy minimums
Permit references: Permit numbers or exhibits

Step-by-step: how to complete the Traffic Services Contract

Follow this sequence to prepare an enforceable contract and avoid common processing delays.

  • 01
    Assemble parties: Confirm legal names and authorized signers.
  • 02
    Define scope: Write detailed tasks, hours, and equipment.
  • 03
    Attach permits: Include traffic plans and municipal approvals.
  • 04
    Verify insurance: Collect certificates and endorsements before mobilization.

How to set up a digital workflow for this contract

Create a reproducible digital workflow to collect signatures, attach permits, and preserve an audit trail for compliance and dispute resolution.

Workflow Field Configuration
Document template Upload master contract and tag required fields
Signer order Define sequence: contractor, municipality, owner
Attachments Require permit and COIs as mandatory uploads
Notifications Set automated reminders and receipt emails

Where to send or file the executed contract

After execution, distribute the signed contract and required attachments to each party and retain a certified copy for compliance.

  • Contractor copy: Operations file and project manager archive
  • Municipality copy: Permit office or public works records
  • Owner copy: Property owner or event organizer
  • Central repository: Secure digital archive with audit trail

Distribution and eSubmission considerations

Use a solution that supports PDF and DOCX formats, stores audit trails, and integrates with your document repository to maintain records in a single, searchable location.

  • Email delivery: Common for signers; preserve originals
  • Secure portal: Preferred for permissions and attachments
  • eSign platform: Captures audit trail and signer attribution

Typical timelines and deadlines to include

Document explicit deadlines to avoid mobility conflicts, missed permits, and payment disputes.

Mobilization date:

Date crews arrive on site; sets insurance and liability start

Permit effective dates:

Match work windows to permit validity and conditions

Daily work hours:

Define start/stop times and noise-sensitive periods

Progress invoicing dates:

State invoice submission and payment terms

Completion acceptance:

Inspection and sign-off deadlines

Common mistakes to avoid when preparing this contract

  • Vague scope language that omits specific traffic control devices or personnel certifications, which can cause payment disputes and safety gaps.
  • Failing to attach permits and traffic control plans before work start, resulting in municipal stop-work orders or fines.
  • Not verifying insurance endorsements and additional insured language, leaving parties exposed to uncovered liability.
  • Using ambiguous payment milestones without required documentation like daily logs or evidence of completion, delaying payments.

Penalties and operational risks of an incorrect contract

Regulatory fines: Local fines and stop-work orders
Liability exposure: Third-party claims and uncovered losses
Payment disputes: Withheld or delayed invoices
Permit revocation: Loss of approved closures
Project delays: Extended completion timelines
Contract termination: Early contract cancellation

eSignature vendor pricing and capability snapshot for Traffic Services Contracts

Compare baseline pricing and common capabilities for eSignature vendors used to execute Traffic Services Contracts; signNow appears first for parity with vendor comparisons.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial, no credit card required Varies Varies Yes, limited Yes, limited
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No
Envelope Cap No cap 100 envelopes/user/year Varies by plan Varies by plan Varies by plan

Real-world examples of contract use

These short case arcs show how organizations apply Traffic Services Contracts to manage risk and speed execution.

Martin Properties

When Martin Properties needed remote approvals for roadway closures, they standardized a Traffic Services Contract to clarify responsibilities and permits.

  • The contract required contractor-provided permits and daily logs to be uploaded.
  • As a result, field crews received faster municipal sign-offs and management reported fewer stop-work orders and clearer invoicing for temporary traffic control.

BIS

BIS adopted a contractor template to reduce review time on repetitive traffic-control tasks.

  • The template centralized insurance endorsements and permit exhibits.
  • The template reduced negotiation time, ensured consistent indemnities, and simplified audit responses for municipal inspections.

Practical tips for accurate and efficient completion

Follow these practices to reduce back-and-forth, ensure compliance, and speed project mobilization.

Use a master template
Maintain a vetted master Traffic Services Contract that includes standard insurance, indemnity, and permit clauses. Update annually to reflect municipal changes and reduce legal review time.
Require attachments up front
Make permits, traffic control plans, and certificates of insurance mandatory attachments before the effective date to prevent unauthorized work and municipal penalties.
Standardize signatory authority
Document who can bind each party (job title or delegated signatory) to avoid invalid signatures and procurement disputes during fast-moving mobilizations.
Preserve audit trails
Use an eSignature platform that captures timestamps, IP addresses, and signer identity evidence to support compliance and dispute resolution.

Who typically signs and what authority they hold

Project Manager

A project manager authorized by the contractor signs to confirm operational commitments, resource allocation, and acceptance criteria. Their signature binds the contractor to performance schedules and invoicing terms.

Municipal Official

A municipal or public works representative signs to acknowledge permit conditions, public safety coordination, and approved closure windows. This signature often conditions contractor mobilization and permit compliance.

Frequently asked questions about the Traffic Services Contract

Answers to common questions about validity, signing methods, notarization, and post-execution steps for Traffic Services Contracts.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.