Establishing secure connection…Loading editor…Preparing document…

Website Development Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

WEBSITE DEVELOPMENT CONTRACT

This Website Development Contract (the Contract) is entered into by and between Client Name: and Developer Name: on . The parties agree as follows.

RECITALS

WHEREAS, Client engages in the business of providing products and services and desires the development, design, and deployment of a website to market and support those offerings; and

WHEREAS, Developer is engaged in the business of website design and development and represents that Developer has the expertise, personnel, and resources required to deliver the website described in this Contract; and

WHEREAS, the parties wish to set forth the terms and conditions under which Developer will design, develop, test, and deliver the website and related services to Client.

PARTY CONTACT INFORMATION

SCOPE OF WORK

Developer will design, develop, and deliver a website in accordance with the specifications, deliverables, and milestones set forth below. Developer will provide the services using commercially reasonable skill and care and in a professional manner consistent with industry standards.

DELIVERABLES AND MILESTONES

The parties agree the work will be delivered according to the milestones below. Acceptance of a milestone deliverable will occur in accordance with the Acceptance and Testing clause.

PAYMENT TERMS

Client will pay Developer the fees set forth in this section in consideration for the services. All fees are payable in United States dollars unless otherwise agreed in writing.

Late payments shall accrue interest at the lesser of 1.5% per month or the maximum rate permitted by law and Client will reimburse Developer for reasonable collection costs, including attorneys' fees.

TERM AND TERMINATION

The Contract commences on the Start Date and continues until the Final Delivery Date or termination in accordance with this section.

Either party may terminate this Contract for material breach if the breach remains uncured for the notice period above. Termination for convenience by Client requires payment for work performed up to the effective termination date and payment for any non-cancellable commitments made by Developer in reliance on this Contract.

CONFIDENTIALITY

Each party will maintain in confidence all Confidential Information disclosed by the other party and will not use or disclose such information except as necessary to perform its obligations under this Contract. Confidential Information includes trade secrets, business plans, technical data, source code, and other non-public information identified as confidential or that a reasonable person would understand to be confidential.

INTELLECTUAL PROPERTY

Unless otherwise agreed in writing, Developer assigns to Client all right, title, and interest in and to the deliverables (excluding Developer pre-existing tools, libraries, or third-party components). To the extent any deliverables do not qualify as a work made for hire, Developer hereby irrevocably assigns all rights to Client upon full payment. Developer retains the right to use general skills, knowledge, and experience acquired during performance of the Contract.

ACCEPTANCE AND TESTING

Upon delivery of a milestone or final deliverable, Client will have an acceptance period to test functionality against the agreed specifications. If Client provides written notice of rejection during the acceptance period, Developer will remedy the deficiencies and resubmit for acceptance.

REVISIONS AND CHANGE ORDERS

Any changes to the scope, schedule, or price shall be made by a written change order signed by both parties. Developer will provide an estimate for requested changes and will not begin additional work until Client authorizes the change order in writing.

WARRANTIES, DISCLAIMERS, AND LIMITATION OF LIABILITY

Developer warrants that delivered services will conform materially to the agreed specifications for a period of 30 days following acceptance. EXCEPT FOR THE EXPRESS WARRANTY SET FORTH ABOVE, DEVELOPER DISCLAIMS ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. IN NO EVENT WILL EITHER PARTY BE LIABLE FOR INDIRECT, INCIDENTAL, EXEMPLARY, OR CONSEQUENTIAL DAMAGES. DEVELOPER'S AGGREGATE LIABILITY FOR ANY CLAIM ARISING OUT OF OR RELATING TO THIS CONTRACT WILL NOT EXCEED THE AMOUNTS PAID BY CLIENT TO DEVELOPER UNDER THIS CONTRACT DURING THE SIX MONTHS PRECEDING THE CLAIM.

MAINTENANCE AND SUPPORT

Ongoing maintenance and support is not included unless expressly stated. If parties agree to a support package, fees, response times, and scope will be set forth in a written amendment.

GOVERNING LAW

This Contract will be governed by and construed in accordance with the laws of the State of without regard to choice-of-law principles. The parties submit to the exclusive jurisdiction of the courts located in that State for disputes arising under this Contract.

ENTIRE AGREEMENT

This Contract, including all exhibits and signed change orders, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous agreements and understandings, whether written or oral. No amendment is effective unless it is in writing and signed by both parties.

NOTICES

All notices required or permitted under this Contract shall be in writing and delivered to the addresses set forth in the Party Contact Information section or to such other address as either party may designate by notice.

Client

Printed Name:

By:

Date:

Developer

Printed Name:

By:

Date:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What a Website Development Contract Covers

A Website Development Contract is a written agreement that sets out scope, deliverables, timelines, payment terms, intellectual property ownership, acceptance criteria, support and maintenance, and liability limits between a developer and a client. It formalizes responsibilities for design, coding, hosting, third-party integrations, and data handling. For commercial enforceability in the United States the parties typically specify governing law and dispute resolution, and they may elect electronic execution consistent with federal and state e-signature statutes such as the ESIGN Act and state UETA provisions.

Why a Clear Contract Matters for Development Projects

A precise, signed contract reduces scope creep, clarifies payment milestones, assigns ownership of code and assets, and sets expectations for testing and maintenance, lowering the risk of disputes and unplanned costs.

Why a Clear Contract Matters for Development Projects

Who Typically Prepares and Signs This Agreement

Parties should confirm signatory authority and execution method before starting work to ensure enforceability and smooth project onboarding.

  • Independent Developer — Freelancers use a compact contract to define deliverables, revisions, and payment schedule for single-project engagements.
  • Agency / Development Firm — Agencies include change-order processes, acceptance testing, and service-level terms for ongoing maintenance.
  • Client / Business Owner — Clients require IP assignment, confidentiality clauses, and clear acceptance criteria before final payment.

Step-by-step: Completing a Website Development Contract

Follow a logical sequence to reduce errors: identify parties, define scope, set milestones, allocate IP rights, add payment and termination terms, and obtain signatures.

  • 01
    Identify Parties: Enter full legal names and entity types for developer and client.
  • 02
    Describe Scope: List deliverables, features, acceptance tests, and excluded items.
  • 03
    Set Milestones: Define dates, deliverables tied to payments, and approval windows.
  • 04
    Sign and Date: All authorized signers sign and date; include witness or notarization if required.

Core clauses to include in a professional development agreement

Ensure the contract contains language that protects both parties and makes deliverables and payment enforceable under U.S. law.

Scope

A concise, itemized scope defines deliverables, milestones, acceptance tests, and excluded work so that change orders and extra work are handled with a clear process.

Payment

Specify deposit, milestone or subscription payments, invoicing terms, late fees, accepted payment methods, and any retainers to avoid payment disputes.

Intellectual Property

Define ownership of source code, design assets, and third-party libraries; include assignment language or license grants and clarify obligations for open-source components.

Warranties & Liabilities

Limit warranties to project-specific performance, include bug-fix windows, and cap liability to agreed amounts excluding willful misconduct.

Confidentiality

Specify the handling of confidential information, duration of nondisclosure obligations, and permitted disclosures for legal compliance.

Termination

Set termination rights, cure periods, treatment of work-in-progress, prorated payments, and survival of critical clauses post-termination.

Security and compliance items to record in the contract

Data Encryption: TLS 1.2/1.3 in transit; AES-256 at rest.
PHI Handling: HIPAA BAA required when handling protected health information.
Audit Trail: Maintain timestamped signing history and IP logs.
Access Controls: Define account roles, MFA, and administrator responsibilities.
Certifications: SOC 2 Type II, ISO 27001, PCI DSS where applicable.
Record Retention: Specify retention periods and secure archival procedures.

Where to send or store executed contracts

Decide distribution and storage before execution to ensure copies reach stakeholders and records comply with retention rules.

  • Client Records: Store a signed copy in the client's contract repository or CRM.
  • Developer Records: Developer keeps the executed contract for warranty and billing support.
  • Accounting: Send copies to accounts payable/receivable for invoicing and tax records.
  • Secure Archive: Retain an encrypted archival copy for compliance and dispute resolution.

Configuring an online signing workflow

Set up the document in your e-signature platform with fields, signer order, authentication, and retention before sending.

Field Configuration
Signature Blocks Place signature and date fields for each signer.
Signer Order Sequential or parallel routing as required.
Authentication Choose email, SMS, or stronger verification.
Retention Enable audit trail and secure storage settings.

Technical considerations for e-signing and sharing

Choose a compliant provider that supports required export formats, audit trails, and any industry-specific controls such as a HIPAA BAA.

  • File Formats: PDF, DOCX, and HTML supported.
  • Integrations: Salesforce, NetSuite, Google Workspace, Microsoft 365.
  • Authentication: SMS code, email link, or KBA options.

Typical timelines and deadline considerations

Contracts often pair delivery milestones with payment dates; include review windows and acceptance periods to reduce disputes.

Project Kickoff:

Begin within 5–14 business days after contract execution.

Milestone Reviews:

Allow 7–14 days for client review and written acceptance.

Payment Due:

Tie payments to milestone acceptance and issue invoices promptly.

Warranty Window:

Commonly 30–90 days for bug fixes after acceptance.

Change Orders:

Specify response and approval times for modifications.

Common drafting and execution mistakes to avoid

  • Vague scope descriptions that omit exact features, integrations, or performance criteria create frequent disputes and require costly change orders.
  • Missing or unclear acceptance criteria lead to disagreements about what constitutes completed work and delay final payments.
  • Failing to assign intellectual property rights or to specify third-party license responsibilities risks future ownership conflicts.
  • Not specifying payment triggers or dispute resolution increases the chance of nonpayment and expensive collections or litigation.

Consequences of an incomplete or incorrect contract

Payment Delay: Lost cashflow and potential collection costs.
IP Dispute: Risk of losing exclusive rights to code.
Regulatory Exposure: HIPAA or PCI violations may trigger fines.
Termination Costs: Early termination fees or unpaid work disputes.
Reputational Harm: Client disputes can damage future opportunities.
Legal Fees: Attorney costs for contract enforcement.

Representative eSignature pricing and capabilities for contract execution

Compare starting prices and core features across common e-signature vendors with signNow listed first for reference.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies Varies Varies Varies
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Real-world examples of contract use across organizations

These short examples show how different teams apply development contracts and e-signature workflows.

Agency Implementation

An agency standardized contracts to include milestone payments and IP assignment

  • Bulk sending contracts for new clients reduced turnaround time
  • The standardized approach lowered disputes and improved billing predictability for recurring projects.

Healthcare Integration

A clinic contracted a developer for patient portal work with a HIPAA addendum

  • They required BAA and encrypted hosting
  • The contract clarified responsibilities for PHI and incident response, reducing compliance risk.

Practical tips to speed execution and reduce disputes

Adopt these practices to create clearer contracts and faster sign-off cycles.

Use Clear Acceptance Criteria
Define tests, sample data, and approval steps so deliverables are objectively verifiable.
Tie Payments to Milestones
Link payments to completed, accepted work to incentivize timely delivery and approvals.
Limit Vague Language
Avoid terms like 'reasonable efforts' without definition to reduce later disputes.
Record Change Orders
Route any scope changes through formal, signed change orders with cost and schedule impacts.

Frequently asked questions about using and signing a Website Development Contract

Answers to common procedural and legal questions help avoid execution errors and compliance issues.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.