Can this contract be signed electronically?

Yes. Electronic signatures are enforceable under the ESIGN Act (15 U.S.C. §7001) and UETA in most states; confirm any narrow statutory exceptions that may apply to the specific transaction.

When is notarization required?

Notarization is generally not required for routine sales contracts, but specific jurisdictions or lenders may require notarized acknowledgements or notarized assignments for recording or financing purposes.

How do I preserve tax incentives?

Retain complete equipment specs, invoices, and proof of installation; follow IRS guidance for credits and retain records for at least 3 years from filing (IRC §6501(a)).

What if a signer lacks authority?

Confirm signatory authority before execution; if an agent signs, attach evidence of authority (board resolution, power of attorney) to avoid enforceability challenges.

How can I amend the contract after signing?

Amendments require mutual written agreement signed by authorized parties; document references to the original contract and keep executed amendment copies with the contract archive.

How should completed contracts be stored?

Keep signed originals or verified electronic copies with audit trails in secure storage for the recommended retention period; ensure the records are reproducible and tamper‑evident.

Electronic Signature
Templates
Sales
Sales Solar Contract

Sales Solar Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

SALES SOLAR CONTRACT

Parties and Contact Information

This Sales Solar Contract (the "Contract") is entered into by and between Seller: , Seller Address: , Contact: ; and Buyer: , Buyer Address: , Contact: .

Buyer Entity Type

Individual Business/Entity Tax ID (if applicable):

Recitals

WHEREAS Seller sells and installs photovoltaic systems and related equipment; and WHEREAS Buyer desires to purchase and have Seller install a solar photovoltaic system on the property identified as: (the "Property").

Scope of Work

Seller shall supply and install a solar photovoltaic system described below in accordance with the terms of this Contract. System size (DC): . Estimated annual production: .

Work Description

Equipment, Materials and Services

Item	Description	Quantity	Unit Price	Total

Subtotal Taxes Shipping / Logistics Total Amount Due

Payment Terms

Buyer agrees to pay Seller the Total Amount Due in accordance with the following schedule: Deposit: (due upon execution). Balance due upon completion and final acceptance: payable within days of invoice.

Accepted payment methods: check, bank transfer, certified funds, or other mutually agreed method. Late payments shall accrue interest at and Buyer shall be responsible for collection costs and reasonable attorney's fees.

Delivery and Installation

Estimated delivery of equipment: . Installation shall be completed by: subject to permitting, weather, and supply-chain delays.

Shipping method: . Risk of loss for equipment passes to Buyer upon delivery to the Property, except for damage occurring during Seller's installation activities, which Seller shall remedy as set forth herein.

Permits and Approvals

Seller will obtain building and electrical permits required for installation unless otherwise specified. Buyer is responsible for homeowner association approvals and for providing access to the Property. Buyer acknowledges that delays caused by permitting or third-party approvals may adjust the installation schedule.

Acceptance and Commissioning

Upon substantial completion, Seller will notify Buyer and perform final testing and commissioning. Buyer shall perform a final inspection within days and sign an acceptance certificate or provide written notice of deficiency. Final payment is conditioned on acceptance.

Warranties

Seller warrants that equipment supplied will conform to manufacturer specifications and will be free from defects in materials and workmanship for a period of years from the date of commissioning. Manufacturer warranties apply in addition to Seller's warranty but Seller's warranty obligations are limited to repair or replacement at Seller's discretion.

Exclusions: warranties do not cover damage due to Buyer negligence, alteration, improper maintenance, theft, vandalism, acts of God, or third-party equipment. Transferability of warranty is subject to manufacturer and Seller terms and may require registration.

Return, Repair and Refund Policy

Buyer may not return custom or installed equipment. Prior to installation, returns of unused, unopened equipment may be accepted at Seller's discretion subject to a restocking fee of . Refunds are limited to amounts actually received by Seller less reasonable costs incurred.

Limitation of Liability and Remedies

Except for willful misconduct or gross negligence, each party's aggregate liability under this Contract shall not exceed the total contract price. IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL OR PUNITIVE DAMAGES, INCLUDING LOSS OF REVENUE OR PROFITS.

Buyer's sole and exclusive remedy for breach of warranty shall be repair or replacement of nonconforming equipment or, at Seller's election, refund of a portion of the purchase price proportionate to the nonconforming equipment.

Indemnification

Each party shall indemnify and hold harmless the other party from third-party claims arising out of its negligent acts or omissions in performing under this Contract, including reasonable attorney's fees and costs, except to the extent caused by the indemnitee's negligence or willful misconduct.

Termination

Either party may terminate this Contract if the other materially breaches and fails to cure within days after written notice. Upon termination by Buyer without cause after Seller has begun performance, Buyer shall pay for work performed and materials ordered plus reasonable termination costs.

Governing Law and Dispute Resolution

This Contract shall be governed by the laws of the State of . Any dispute arising under this Contract shall be resolved by binding arbitration in the county where the Property is located, unless the parties agree otherwise in writing.

Miscellaneous

Entire Agreement: This Contract, including any exhibits and purchase orders executed by the parties, constitutes the entire agreement and supersedes all prior proposals and agreements. Amendments must be in writing signed by both parties.

Additional Terms or Notes

Acknowledgments

Buyer certifies that Buyer is the owner or has the authority of the owner to order the installation at the Property and that the information provided to Seller is true and complete. Buyer grants Seller the right to perform the work described herein and to make reasonable alterations required for installation.

Seller Printed Name:

By:

Date:

Buyer Printed Name:

By:

Date:

What the Sales Solar Contract Is and why it matters

A Sales Solar Contract is a written agreement that sets the terms for sale, delivery, installation, and commissioning of a photovoltaic (PV) system at a specified site. It identifies the seller (installer or developer) and buyer (homeowner or commercial owner), describes equipment and labor, sets payment and finance terms, allocates responsibility for permits and inspections, defines warranties and maintenance obligations, and specifies remedies for default, delays, or defects. In the United States these agreements are frequently adapted for permitting, interconnection, and tax-credit documentation and may be executed electronically under ESIGN and state e‑signature laws.

Why a clear Sales Solar Contract reduces risk

A well-drafted Sales Solar Contract clarifies scope, protects payment rights, preserves eligibility for incentives, and reduces disputes by explicitly assigning responsibilities for permits, interconnection, equipment specs, testing, and warranty service. Proper execution supports enforceability under the ESIGN Act (15 U.S.C. §7001) and applicable state UETA provisions.

Who typically prepares and signs this agreement

The Sales Solar Contract is used by installers, developers, property owners, and financing parties to formalize solar system sales and services.

Residential installers and contractors — Provides installation scope, permit responsibilities, and homeowner warranties in a single document.
Commercial developers and owners — Used to coordinate larger system specifics, performance guarantees, and third‑party financing terms.
Lenders and tax equity investors — Establishes collateral, assignment rights, and evidence required for incentives and financing approvals.

Each signer should confirm authority, review payment and warranty language, and ensure the contract aligns with local permit and interconnection requirements.

Step-by-step: completing the Sales Solar Contract

Follow these sequential steps to prepare, verify, and execute the contract in a compliant manner.

01

Gather documents: Collect IDs, proof of ownership, equipment quotes, and permit requirements.
02

Draft terms: Define scope, specs, payment schedule, and warranty language.
03

Review legal points: Confirm governing law, dispute resolution, and assignment clauses.
04

Execute and retain: Have authorized signers sign and store original and electronic copies.

Configure an online signing workflow for the contract

Set up fields and routing rules before sending: this reduces signer friction and preserves an audit trail.

Field	Configuration
Signature	Required; name and date fields attached to signer
Initials	Optional; use for page acknowledgement if needed
Attachment	Permit upload field for permitting documents
Conditional Clause	Show financing contingency only if payment is financed

Typical electronic execution flow for a Sales Solar Contract

A consistent signing flow streamlines approvals and creates a clear audit trail for lenders and inspectors.

Upload document: Sender uploads final contract PDF or DOCX.
Prepare fields: Place signature, date, and attachment fields as required.
Send to signers: Add signer emails and set signing order or simultaneous signing.
Complete signing: Signers authenticate, sign, and receive signed copies with audit trail.

Platform and integration considerations for e‑signing

Choose a platform that supports PDF/DOCX, integrations, audit trails, and required compliance features.

File formats: PDF and DOCX are widely supported.
Integrations: Salesforce, NetSuite, Google Workspace supported by many providers.
Authentication: Email, SMS, or advanced signer authentication available.

Confirm the vendor provides required compliance controls (audit trail, tamper evidence, data encryption) and supports your document routing needs before finalizing the workflow.

Essential security and compliance controls to preserve validity

Encryption: TLS 1.2/1.3 in transit; AES‑256 at rest

Audit Trail: Timestamp, IP, and action history retained

HIPAA BAA: Business Associate Agreement available when required

Authentication: Email, SMS, or stronger MFA options

Certifications: SOC 2 Type II and ISO 27001 compliance

Retention: Secure storage with tamper-evident file handling

Common mistakes to avoid when preparing the contract

Vague equipment descriptions: failing to specify make, model, series, and performance tolerance invites later disputes and warranty denial.
Unclear payment schedule: missing milestone definitions or acceptance criteria can lead to delayed payments or disagreements with financiers.
Permit and interconnection assumptions: assuming seller will obtain permits without explicit allocation of responsibility risks project stoppage and additional costs.
Improper signer authority: allowing unsigned or unauthorized representatives to sign can render the agreement unenforceable and delay financing.

Key legal and financial risks from a flawed contract

Breach Liability: Damages and remedy exposure

Permit Delays: Project stoppage and added costs

Incentive Loss: Tax credit or rebate ineligibility

Financing Default: Collateral or loan acceleration

Warranty Void: Manufacturer/service denial

Recordkeeping: Failure increases audit risk

Core contract clauses every Sales Solar Contract should include

Include clear, enforceable clauses covering technical, financial, and administrative obligations to reduce downstream disputes.

Scope of Work

Define system size, components, mounting method, site work, and acceptance testing procedures to create objective performance and delivery standards that avoid ambiguity.

Equipment and Specifications

List manufacturers, model numbers, warranties, performance tolerances, and replacement obligations so buyers and sellers share a common standard for evaluation and claims.

Payment and Financing

Specify total price, deposit, draw schedule, financing contingencies, and remedies for late payment; tie payments to clear milestones to protect both parties.

Permits and Inspections

Allocate responsibility for permits, fees, and inspector access; state who pays permit costs and who secures interconnection agreements with the utility.

Warranties and Maintenance

Document manufacturer and installer warranties, maintenance obligations, response times, and transferability of warranties upon sale of the property.

Termination and Dispute

Set termination rights, notice and cure periods, applicable law, and dispute resolution processes (mediation or arbitration) to limit litigation exposure.

Illustrative scenarios for contract use and adaptation

These two examples show how clauses are applied in common project situations.

Case Study 1

A homeowner contract required clear roof condition representations and a payment schedule tied to inspection milestones.

The installer provided a 5kW system quote with manufacturer warranties.
When a roof surprise occurred, preallocated change‑order clauses and contingency payment terms let parties resolve cost allocation without litigation, keeping the project on schedule and preserving incentive eligibility.

Case Study 2

A commercial developer used assignment language to secure third‑party financing and tax equity.

Lender required documentation of permits and interconnection.
The contract included explicit assignment rights and evidence exhibits so financing closed on time while protecting the developer from unexpected transfer obligations.

Frequently asked questions about Sales Solar Contracts

Answers to common legal, signing, and post‑execution questions to help avoid delays and compliance issues.

Need help? Contact support

Can this contract be signed electronically?
Yes. Electronic signatures are enforceable under the ESIGN Act (15 U.S.C. §7001) and UETA in most states; confirm any narrow statutory exceptions that may apply to the specific transaction.
When is notarization required?
Notarization is generally not required for routine sales contracts, but specific jurisdictions or lenders may require notarized acknowledgements or notarized assignments for recording or financing purposes.
How do I preserve tax incentives?
Retain complete equipment specs, invoices, and proof of installation; follow IRS guidance for credits and retain records for at least 3 years from filing (IRC §6501(a)).
What if a signer lacks authority?
Confirm signatory authority before execution; if an agent signs, attach evidence of authority (board resolution, power of attorney) to avoid enforceability challenges.
How can I amend the contract after signing?
Amendments require mutual written agreement signed by authorized parties; document references to the original contract and keep executed amendment copies with the contract archive.
How should completed contracts be stored?
Keep signed originals or verified electronic copies with audit trails in secure storage for the recommended retention period; ensure the records are reproducible and tamper‑evident.

be ready to get more

Join over 28 million airSlate SignNow users

Sign Now