Establishing secure connection…Loading editor…Preparing document…

Agreement with Architect to Design Building for Fixed Fee

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

Agreement with Architect to Design Building for Fixed Fee

Agreement made this day of , 20, between

, of

referred to herein as the Owner, and , of

The undersigned Owner and Architect hereby agree that this Agreement constitutes the terms and conditions under which Architect shall provide Architectural services for a to be erected by Owner at .

I. Services of Architect.

A. Architect agrees to provide all Architectural, engineering, and consulting services except such field engineering services as may be employed and paid for by the contractor.

B. The services of Architect shall include attendance at the necessary conferences, the preparation of preliminary studies, work drawings, specifications, large scale and full-sized detailed drawings, as may be required, the issuance of certificates for payment, the keeping of accounts, supervision of the work, and inspections during the guarantee period. In addition, the services of Architect shall include the preparation of drawings, specifications, and written opinions in connection with construction changes.

II. Compensation. Owner agrees to pay Architect a total fee of $ , with percent of the fee to be paid on the completion by Architect and the acceptance by Owner of the working drawings and specifications. The balance of the fee shall be paid monthly as the work progresses, at a rate equal to the percentage of completion. Any balance remaining shall be paid on completion.

III. Expenses of Architect.

A. Architect shall pay all expenses in connection with site planning, site engineering, as well as structural, mechanical, and special engineering pertinent to the preparation of the drawings and specifications or their interpretation, and the determination or compliance, as may be required in the completion of the project.

B. Architect agrees to provide for the cost of transportation and living incurred by him and his assistants or associates while traveling in the discharge of duties connected with the work under this Agreement.

IV. Certification of Drawings. Owner has furnished Architect with a current, dated certified topographic survey of the project site and adjacent land and facilities, and Architect certifies the drawings will be based on such survey.

V. Expenses of Owner. Owner will authorize and pay for test borings or pits and consultation with a soils engineer and for chemical, mechanical, or laboratory tests, when and as required, but not including tests specifically required under the construction contract.

VI. Ownership of Damages. Drawings and specifications as instruments of service shall be the property of Architect, regardless of whether the work for which they are made is executed, and their use for any other project is not authorized.

VII. Architect’s Duties to Advise, Supervise and Inspect.

A. Architect will advise Owner in writing of any omissions, substitutions, defects, and deficiencies noted in the work of contractors, but does not guarantee the performance of their contract.

B. The supervision of Architect is to be distinguished from the continuous personal supervision to be obtained by a resident inspector. Architect or is agent shall visit the project once a week, or more often when the nature and progress of the work and the interests of Owner require an increase in the frequency of such visits.

C. There shall be a guarantee period of months, during which Architect shall inspect the project for evidence of faulty materials and quality of work. The landscape work and the heating and cooling systems shall be inspected by Architect in appropriate season. The project in general shall be inspected at or about the month after completion and, in addition, Architect shall make such other inspections and perform services as may be necessary and incidental to the requirements of the drawings and specifications.

D. When authorized by Owner, a resident inspector, satisfactory to both Owner and Architect, shall be employed by Architect at a salary satisfactory to Owner, who shall reimburse Architect for such salary, in addition to the Architect's fee previously agreed upon.

VIII. Certificates of Architect. Architect's certificates evidencing recent inspection and acceptability of the work, and certifying as to the validity of requested payments shall be executed simultaneously with requests for advances for payment covering construction cost or monthly reports of progress and compliance when advances during construction are not requested. The above-stated certificates shall be based on personal inspection of the work by Architect or agent. The name of the agent shall be indicated when an inspection is made by the agent for Architect.

IX. Termination of Agreement.

A. Either Architect or Owner may, on days' prior written notice to the other party, terminate this Agreement for reason of noncompliance with any of the provisions of this Agreement by the other party.

B. In the event of termination, Architect shall be entitled to only the prescribed portion of fee determined by the percentage of the construction completed.

X. Mandatory Arbitration. Any dispute under this Agreement shall be required to be resolved by binding arbitration of the parties hereto. If the parties cannot agree on an arbitrator, each party shall select one arbitrator and both arbitrators shall then select a third. The third arbitrator so selected shall arbitrate said dispute. The arbitration shall be governed by the rules of the American Arbitration Association then in force and effect.

XI. Construction Changes – Costs and Duties.

A. Owner agrees to pay, in addition to the contract price, the cost of any supplementary drawings required by reason of construction changes agreed to by both parties.

B. It is understood that Architect, under the terms of this Agreement, will review and act in an advisory capacity in connection with each construction change submitted by Owner and will prepare a letter indicating his opinion as to the acceptability and effect of each change without additional cost to Owner.

XII. Architect’s Certification of Interest. Architect certifies that he is an independent practitioner having no identity of interest with the builder, and that Architect does not have any financial interest in the project or the real estate on which it is to be constructed other than the fee he has received or is to receive under this Agreement.

XIII. Severability. The invalidity of any portion of this Agreement will not and shall not be deemed to affect the validity of any other provision. If any provision of this Agreement is held to be invalid, the parties agree that the remaining provisions shall be deemed to be in full force and effect as if they had been executed by both parties subsequent to the expungement of the invalid provision.

XIV. No Waiver. The failure of either party to this Agreement to insist upon the performance of any of the terms and conditions of this Agreement, or the waiver of any breach of any of the terms and conditions of this Agreement, shall not be construed as subsequently waiving any such terms and conditions, but the same shall continue and remain in full force and effect as if no such forbearance or waiver had occurred.

XV. Governing Law. This Agreement shall be governed by, construed, and enforced in accordance with the laws of the State of .

XVI. Notices. Unless provided herein to the contrary, any notice provided for or concerning this Agreement shall be in writing and shall be deemed sufficiently given when sent by certified or registered mail if sent to the respective address of each party as set forth at the beginning of this Agreement.

XVII. Attorney’s Fees. In the event that any lawsuit is filed in relation to this Agreement, the unsuccessful party in the action shall pay to the successful party, in addition to all the sums that either party may be called on to pay, a reasonable sum for the successful party's attorney fees.

XVIII. Entire Agreement. This Agreement shall constitute the entire agreement between the parties and any prior understanding or representation of any kind preceding the date of this Agreement shall not be binding upon either party except to the extent incorporated in this Agreement.

XIX. Modification of Agreement. Any modification of this Agreement or additional obligation assumed by either party in connection with this Agreement shall be binding only if placed in writing and signed by each party or an authorized representative of each party.

XX. Assignment of Rights. The rights of each party under this Agreement are personal to that party and may not be assigned or transferred to any other person, firm, corporation, or other entity without the prior, express, and written consent of the other party.

XXI. Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be deemed to be an original, but all of which together shall constitute but one and the same instrument.

XXII. Compliance with Laws. In performing under this Agreement, all applicable governmental laws, regulations, orders, and other rules of duly-constituted authority will be followed and complied with in all respects by both parties.

Witness our signatures as of the day and date first above stated.

By:

By:

Enter text✕
Prepare your document for signing right on this page
  • 01 Edit the text and complete the fields
  • 02 Click Sign Now and on the next screen add recipients and signature fields in SignNow
  • 03 Start your free trial to sign and send your doc
Sign Now

What the Agreement with Architect to Design Building for Fixed Fee Is

The Agreement with Architect to Design Building for Fixed Fee is a written contract that sets out the architect’s scope of services, deliverables, schedule, and a single fixed payment amount for all specified design work. It identifies the owner and architect, references plans and exhibits, defines milestones and approval criteria, allocates responsibility for permits and code compliance, and typically includes provisions for change orders, additional services, insurance, indemnity, and dispute resolution. The fixed-fee model caps design cost for the stated scope and creates clear expectations for timing, revisions, and acceptance of completed deliverables.

Why Use a Fixed Fee Architect Agreement

A fixed-fee agreement provides budget certainty and a clear allocation of risk for defined design services. It minimizes billing disputes, clarifies deliverables and milestones, and streamlines project planning by tying cost to scope rather than hourly billing.

Why Use a Fixed Fee Architect Agreement

Who Typically Uses This Agreement

The Agreement with Architect to Design Building for Fixed Fee is used by parties who prefer predictable design costs and defined deliverables.

  • Private developers and property owners seeking budget certainty for building design and permitting.
  • Public agencies and municipal owners contracting design services under fixed appropriations and procurement rules.
  • General contractors or design-build teams that need a defined design scope to coordinate bids and construction.

It is suitable for single-project owners, developers, and public agencies that require a clear, enforceable scope tied to a lump-sum fee.

How to Complete the Agreement Step by Step

Follow a consistent sequence to ensure the fixed fee, scope, and approvals are clear and enforceable.

  • 01
    Identify Parties: Enter full legal names and contact information for owner and architect.
  • 02
    Define Scope: List services, phases, and excluded tasks with attachments or exhibit references.
  • 03
    Set Fee: State the fixed dollar amount and any included reimbursable expenses.
  • 04
    Signatures: Include authorized signer names, titles, signature blocks, and effective date.

Core Components to Include in a Professional Fixed-Fee Architect Agreement

A robust fixed-fee agreement balances clarity of scope with protections on changes, schedule, and liability to reduce later disputes.

Scope Definition

Detailed list of tasks, phases, and excluded services plus referenced exhibits so both parties share the same expectations and avoid scope creep during design and permitting.

Deliverables

Specify the form and number of drawings, specifications, digital files, and stamped sets required at each phase to ensure acceptance criteria are explicit.

Payment Terms

Fixed fee amount, payment milestones, late payment interest, reimbursement rules for third-party fees, and provisions for additional services.

Schedule and Milestones

Timelines for each phase, review periods, and deadline consequences, including extensions for owner delays or permit hold-ups.

Changes and Revisions

Process for change orders, valuation of additional services, and how change requests affect the fixed fee or schedule.

Liability and Insurance

Limits of liability, indemnities, required professional liability insurance, and risk allocation for errors, omissions, and code compliance.

Security and Compliance Considerations for Signed Agreements

Encryption: TLS 1.2/1.3 in transit; AES-256 at rest
Audit Trail: Timestamps, IP addresses, signer actions recorded
HIPAA: BAA available where PHI present
21 CFR Part 11: Support for FDA-regulated workflows
Certifications: SOC 2 Type II; ISO 27001
Access Controls: Role-based permissions and SSO options

Penalties and Risks if the Agreement Is Incorrect or Incomplete

Ambiguous Scope: May trigger cost disputes
Missing Signatures: Can render the agreement unenforceable
Incorrect Effective Date: Alters statute and milestone timings
No Change Order Process: Leads to unpaid extra work
Improper Licensing Info: Regulatory penalties possible
Tax Withholding Errors: Backup withholding or fines

Common Mistakes to Avoid When Preparing the Agreement

  • Failing to attach referenced exhibits or drawings, which creates uncertainty about the agreed scope and deliverables.
  • Using vague fee language such as 'reasonable time' or 'as required' without objective milestones and acceptance criteria.
  • Overlooking permit responsibility and associated costs, shifting unexpected liabilities to the wrong party mid-project.
  • Not defining approval windows for owner reviews, which can delay progress and create disputes over missed milestone deadlines.

How to Configure a Digital Signing Workflow for This Agreement

A clear online workflow assigns signer order, fields, and authentication to capture binding approvals and preserve the audit trail.

Field Configuration
Signature Blocks Place name, title, date fields for each authorized signer
Attachments Include exhibits and referenced drawings as locked attachments
Authentication Use email or SMS code; use stronger ID verification for high-risk projects
Notifications Enable reminders and certificate delivery to all parties

Digital Signing and Platform Requirements

Use a platform that supports audit trails, common file formats, and integrations with your project systems.

  • File Formats: PDF, DOCX accepted and preserved
  • Integrations: Salesforce, NetSuite, Procore compatible
  • Authentication: Email link, SMS, KBA, or SSO

Typical Dates and Deadlines to Include

Specify explicit dates or milestone-triggered timeframes to avoid ambiguity and align payments with deliverables.

Effective Date:

MM/DD/YYYY — the agreement begins and notice periods start

Schematic Completion:

Date or weeks after effective date for initial design package

Design Development:

Deadline for DD deliverables and owner review periods

Permit Submission:

Target date for filing with authority having jurisdiction

Final Deliverables:

Date for final construction documents and sealed drawings

eSignature Pricing Comparison for Signing Architect Agreements

Comparison of typical entry-level plans and key capabilities for electronic signing platforms; signNow is listed first as the baseline option.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day free trial Varies by plan Varies by plan Varies by plan Varies by plan
Bulk Send Yes Yes Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Real-World Examples of Fixed-Fee Architect Agreements

These examples show how fixed-fee terms are applied across common project scenarios to control cost and define deliverables.

Small Commercial Retrofit

An owner hired an architect for a single fixed fee to deliver schematic through permit-ready drawings.

  • The fee covered two revision rounds.
  • Clear exhibit attachments and a change-order process prevented disputes and ensured project proceeded within the agreed budget and schedule.

Municipal Facility Design

A municipality required a lump-sum design contract to match budget appropriations.

  • Deliverables included ADA and code compliance reviews.
  • The fixed fee aligned with municipal procurement cycles and sped approvals because expectations and deliverable formats were identified up front.

Key Milestones and Processing Stages

Track major milestones in sequence so payments and approvals align with deliverable acceptance.

01

Contract Execution

Agreement signed and effective date recorded; initial payment due per payment schedule.

02

Schematic Phase

Schematic design delivered and reviewed; owner issues consolidated comments within specified review period.

03

Permit Submission

Construction documents submitted to authority having jurisdiction; architect responds to permit questions.

04

Final Acceptance

Final deliverables and sealed drawings issued; final payment processed and closeout documentation exchanged.

Frequently Asked Questions about the Agreement and Electronic Signing

Answers to common questions on enforceability, signatures, revisions, and recordkeeping when using a fixed-fee architect agreement.


Need help? Contact support

Explore Templates

Florida Last Will and Testament Instructions Articles of Dissolution Sellers Property Disclosure Statement Sample Agreement to Purchase Real Estate
be ready to get more
Join over 28 million airSlate SignNow users
Sign Now
Company
Forms
Pricing
Resources
Knowledge base
Other Products
© 2026 airSlate Inc. All rights reserved.