Fill and Sign the Replacing Re Setting Altering Converting or Moving Heat Producing Systems Electric or Form

REFRIGERATION CONTRACT THIS REFRIGERATION CONTRACT (“Contract”), effective as of the date of the last party to sign below, is between  , having an address at ("Contractor") and  , having an address at  ("Owner"). For valuable consideration the parties hereby agree as follows:1. SCOPE OF WORK: Refrigeration work involves the use of hand tools, instruments and gauges, measuring tools, fastening devices and refrigeration supplies to construct, fabricate, erect, install, maintain, service and repair the following: refrigeration equipment, producing systems, rooms and insulated spaces; temperature insulation; air- conditioning units, systems or coolers; ducts; blowers; registers; and humidity and thermostatic controls of air, liquid and/or gas temperatures. Refrigeration services may also include the following: complying with blueprints and specifications to install motors, compressors, evaporators and other components; connecting ducts, refrigerant lines and piping; making power hookups; and constructing, installing, re-installing, repairing, replacing, re-setting, altering, converting, or moving heat producing systems (electric or gas), combustion plants, and ventilation systems in any building, structure or appurtenance thereto. Contractor shall provide all labor and materials, and perform all refrigeration work described above and/or as described in the plans and specifications signed by both Owner and Contractor (“Project”). Such plans and specifications are hereby made a part of this Contract and may contain pictures, diagrams or measurements of the work area together with a description of the work to be done, materials to be used, and the equipment to be used or installed. 2. WORK SITE: The Project shall be constructed on the property of Owner located at  and more particularly described as  (hereafter "the Work Site"). Owner hereby authorizes Contractor to commence and complete the usual and customary excavation and grading on the Work Site as may be required in the judgment of the Contractor to complete the Project. Unless called for in the plans or specifications, no landscaping, finish grading, filling or excavation is to be performed at the Work Site by the Contractor.3.TIME OF COMPLETION: Contractor shall commence the work to be performed under this Contract on or before  and shall substantially complete the work on or before . Contractor shall not be liable for any delay due to circumstances beyond its control including strikes, casualty, acts of God, illness, injury, or general unavailability of materials. 4.PERMITS: Contractor shall apply for and obtain such permits and regulatory approvals as may be required by the local municipal/county government, the cost thereof shall be included as part of the Project price.5.INSURANCE: Contractor shall maintain general liability and workers compensation insurance.6.CHANGES TO SCOPE OF WORK: Owner may make changes to the scope of the work, including changes to the plans and specifications, from time to time during the construction of the Project. However, any such change or modification shall only be made by written "Change Order" signed by both parties. Such Change Orders shall become part of this Contract. Owner agrees to pay any increase in the cost of the Project as a result of a Change Order. In the event the cost of a Change Order is not known at the time a Change Order is executed, the Contractor shall estimate the cost thereof and Owner shall pay the actual cost whether or not it is in excess of the estimated cost.7.CONTRACT PRICE:{COST PLUS}Owner agrees to pay Contractor the actual cost to Contractor of materials plus the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows:  .OR{FIXED FEE}Owner agrees to pay Contractor the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows:  .Contractor shall furnish Owner appropriate releases or waivers of lien for all work performed or materials provided at the time the next periodic payment shall be due.8.LATE PAYMENT/DEFAULT: A failure to make payment for a period in excess of ten (10) days from the due date shall be deemed a material breach of this Contract. If payment is not made when due, Contractor may suspend work on the job until such time as all payments due have been made without breach of the Contract pending payment or resolution of any dispute. Owner agrees to pay a late charge of 1% of all payments that are more than ten (10) days late plus interest at the rate of 1% per month.9.DESTRUCTION AND DAMAGE: If the Project is destroyed or damaged for any reason, except where such destruction or damage was caused by the sole negligence of the Contractor or its subcontractors, Owner shall pay Contractor for any additional work done by Contractor in rebuilding or restoring the Project to its condition prior to such destruction or damage. If the estimated cost of replacing work already accomplished by Contractor exceeds 20 percent of the Contract price, either the Contractor or Owner may terminate this Contract. Upon termination by either party, Contractor shall be excused from further performance under this Contract and Owner shall pay Contractor a percentage of the Contract price in proportion to the amount of work accomplished prior to the destruction or damage.10. ASSIGNMENT: Neither party may assign this Contract, or payments due under the Contract, without the other party’s written consent. Any such assignment shall be void and of no effect.11. INTERPRETATION:(a)Interpretation of Documents. The Contract, plans, and specifications are intended to supplement one another. In the event of a conflict, the specifications shall control the plans, and the Contract shall control both. If work is displayed on the plans but not called for in the specifications, or if the work is called for in the specifications but not displayed on the plans, Contractor shall be required to perform the work as though it were called for and displayed in both documents.(b)Entire Agreement. This Contract constitutes the entire agreement of the parties. No other agreements, oral or written, pertaining to the work to be performed under this Contract exists between the parties. This Contract may only be modified by a written agreement signed by both parties.(c) Governing Law. This Contract shall be interpreted and governed in accordance with the laws of the State of Nevada.12. ATTORNEYS’ FEES AND COSTS: If any party to this Contract brings a cause of action against the other party arising from or relating to this Contract, the prevailing party in such proceeding shall be entitled to recover reasonable attorney fees and court costs.13. PERFORMANCE:(a)Contractor may, at its discretion, engage licensed subcontractors to perform work pursuant to this Contract provided Contractor shall remain fully responsible for the proper completion of the Project. (b) All work shall be completed in a workman-like manner and in compliance with all building codes and applicable laws. To the extent required by law, all work shall be performed by individuals duly licensed and authorized by law to perform said work.(c)Contractor agrees to remove all debris and leave the premises in broom clean condition.14. WARRANTY: Contractor's warranty shall be limited to defects in workmanship within the scope of work performed by Contractor and which arise and become known within one (1) year from the date hereof. All said defects arising after one (1) year and defects in material are not warranted by Contractor. Contractor hereby assigns to Owner all warranties on materials as provided by the manufacturer of such materials. 15. REQUIRED NOTICES: Disclosures to Owner as required by Nevada are attached hereto.AGREED:CONTRACTOR:Signature______________________________Print Name & Title__________________Date_______________________License Number________________________________Name and Address of License HolderOWNER:Signature______________________________Print Name__________________Date NOTICES TO OWNER Pursuant to NRS 108.221 to 108.246, inclusive, a contractor, subcontractor, laborer, supplier of materials or other person or entity who:(1) Performs work or furnishes materials of the value of $500.00 or more to improve the value of your property; and(2) Is not paid for the work or materials, has a right to place a lien on your property on which the work was performed and to sue you in court to obtain payment. This means that after a court hearing, your property could be sold by an officer of the court, and the proceeds of the sale used to satisfy the amount you owe. If you did not ask for and receive releases of liens from the contractors’ subcontractors, laborers or suppliers of materials, a lien may be placed on your property or you may be sued even if you have paid your contractor in full. To preserve their right to file a claim or lien against your property, certain claimants, such as subcontractors, laborers and suppliers of materials, are each required to provide you with a document called a “preliminary or pre-lien notice.” A preliminary or pre-lien notice is not a lien against your property. Its purpose is to notify you regarding persons or entities that may have a right to file a lien or claim against your property if they are not paid. To perfect their lien rights, contractors, subcontractors, laborers and suppliers of materials must file mechanics’ liens with the county recorder, which then become recorded liens against your property. Generally, the maximum time allowed for filing a mechanics’ lien against your property is 90 days after substantial completion of your project.TO ENSURE EXTRA PROTECTION FOR YOURSELF AND YOUR PROPERTY, YOU MAY WISH TO TAKE ONE OR MORE OF THE FOLLOWING STEPS: (1) Request that your contractor supply you with a payment and performance bond, which guarantees completion of your project and payment of the subcontractors, laborers and suppliers of materials who work on the project. This payment and performance bond is different from the surety bond that a contractor must file for licensure pursuant to NRS 624.270. A payment and performance bond provides that if the contractor does not complete the project, the bonding company will pay damages up to the amount of the bond. This payment and performance bond, as well as a copy of the construction contract, should be filed with the county recorder for your further protection. There is a fee for a payment and performance bond. This fee is usually equal to between 1 and 6 percent of the amount of the contract, depending on the ability of the contractor to be bonded. (2) Require that payments be made directly to subcontractors, laborers and suppliers of materials through a mechanism that controls payment for construction. In the area in which you live, services to control the funding of your project may be available, for a fee, to control payment of your contractor by the use of vouchers or other means. These services may also provide you with waivers of liens and other forms of protection. (3) Issue joint checks for payment, made payable to both, your contractor and the subcontractors, laborers and suppliers of materials who were involved in the project or portion of the project for which payment is due and who sent a preliminary or pre-lien notice to you. Those persons or entities have indicated that they may have the right to place a lien on your property, and therefore you need to protect yourself. Making checks jointly payable will help to ensure that all persons due payment are actually paid.(4) Require your contractor to provide you with unconditional “waiver and release” (lien release) forms so that when you make a payment on any completed phase of your project, each subcontractor, laborer and supplier of materials involved in that portion of the work for which the payment was made can sign the waiver and release forms. This protects you from liability to them for work for which they have already been paid. · Some stationery stores sell waiver and release forms if your contractor does not have them. The subcontractors, laborers and suppliers of materials from whom you obtain releases should be those persons or entities who have filed preliminary or pre-lien notices with you. If you are not certain which subcontractors, laborers and suppliers of materials are working on your project, you may obtain a list from your contractor. In regard to projects involving improvements to a single-family residence or a duplex owned by an individual, the persons signing these releases lose their right to file a mechanics’ lien against your property. In regard to other types of projects, obtaining such releases may still be important, but may not provide complete protection. · To protect yourself by use of a waiver and release form, you must be certain that all subcontractors, laborers and suppliers of materials who work on your project sign a waiver and release form. If a mechanics’ lien has already been filed against your property, in most cases the lien can only be released voluntarily by a recorded “release of mechanics’ lien,” which is signed by the person or entity that filed the mechanics’ lien against your property. However, if the person or entity that filed the lien fails to bring an action to enforce the lien in a timely manner, the lien may be removed without voluntary action on the part of that person or entity. You should not make final payment on your project until all mechanics’ liens that are filed against your property have been removed.TO PROTECT YOURSELF FULLY, YOU SHOULD CONSULT AN ATTORNEY: (1) BEFORE YOU SIGN A CONSTRUCTION CONTRACT; OR (2) IF A LIEN IS FILED AGAINST YOUR PROPERTY. Contractors are required by law to be licensed and regulated by the Nevada State Contractors Board. The Nevada State Contractors Board has jurisdiction to investigate complaints that are filed against contractors. Any questions concerning a contractor may be referred to the Board at: Southern Nevada Address:2310 Corporate Circle, Ste 200 Henderson, NV 89074Phone:(702) 486-1100Fax:(702) 486-1190Northern Nevada:Addres s:9670 Gateway Drive, Ste 100 Reno, NV 89521Phone:(775) 688-1141Fax:(775) 688-1271 Hours of OperationMonday - Friday 8:00am - 5:00pm The law of this state requires a person or entity that enters into a contract to perform construction work be properly licensed by the Nevada State Contractors Board for the category of work that the person or entity intends to perform. Laws regulating licensed contractors are designed to protect the public. If you contract with a person or entity who is not licensed to perform construction work, your remedies against that person or entity may be limited to a suit in civil court. You may be liable for damages arising out of any injuries to an unlicensed contractor or that contractor’s employees, as well as withholding taxes, and contributions pursuant to the Federal Insurance Contributions Act and contributions for industrial insurance and unemployment compensation. In addition, you must comply with other applicable state and federal laws regarding employment. Finally, you should be aware that construction performed on your property must comply with all applicable laws, ordinances, building codes and regulations. A contractor is required to include his license number on all of his advertising, vehicles, bids and contracts. You may contact the Nevada State Contractors Board to find out if a contractor has a valid license and, if so, the status of that license. The Board has complete information on the status of all licensed contractors in the State of Nevada. This information is available through the “voice response system” of the Nevada State Contractors Board. As referenced above, any contractor who works on a residential property is required to provide Residential Recovery Fund disclosures. RESIDENTIAL CONSTRUCTION RECOVERY FUND Payment may be available from the Recovery Fund if you are damaged financially by a project performed on your residence pursuant to a contract, including construction, remodeling, repair or other improvements, and the damage resulted from certain specified violations of Nevada law by a contractor licensed in this State. To obtain information relating to the Recovery Fund and filing a claim for recovery from the Recovery Fund, you may contact the Nevada State Contractors Board at the following locations: Southern Nevada Address:2310 Corporate Circle, Ste 200 Henderson, NV 89074Phone:(702) 486-1100Fax:(702) 486-1190Northern Nevada:Addres s:9670 Gateway Drive, Ste 100 Reno, NV 89521Phone:(775) 688-1141Fax:(775) 688-1271 Hours of OperationMonday - Friday 8:00am - 5:00pm 2. The Board may impose upon a contractor an administrative fine: (a) Of not more than $100 for the first violation of subsection 1; and (b) Of not more than $250 for a second or subsequent violation of subsection 1. 3. The Board shall deposit any money received pursuant to this section in the account established pursuant to NRS 624.470.