Fill and Sign the Trim Products Are Installed Wherever Form

- 1 - TRIM CONSTRUCTION CONTRACT THIS TRIM CONSTRUCTION CONTRACT (“Contract”), effective as of the date of the last party to sign below, is between , having an address at ("Contractor") and , having an address at ("Owner"). For valuable consideration the parties hereby agree as follows: 1. SCOPE OF WORK: Trim work is interior or exterior construction made by cutting, surfacing, joining, gluing and fabricating various grade materials and moldings, such as paint-grade or stain-quality wood or other products to provide a functional surface, and placing, erecting and finishing such work in structures. Trim products are installed wherever different construction finishing materials intersect along joints, corners, door frames, windows and other building features. Trim work services include determining trim requirements, installing various types of trim (including door, bifold, casing, base or baseboard, base shoe, base cap, window stop, window stool, picture, corner guard, chair rail, wainscoting, and staircase, and ceiling molding, paneling, handrails, cased openings, stairway railings, custom woodworking, built-in shelving, cabinetry, countertops, entry door surrounds, mantels, closet shelves, hanger rods, window hardware and door stops), setting doors, door sills, windows and window sills, and finishing trim by sanding and ensuring even intersection with walls, ceilings and floors. Contractor shall provide all necessary t rim labor and materials, and perform all necessary trim work services described above and/or as se t forth in the plans and specifications signed by both Owner and Contractor (“Project”). Such plans and specifications are hereby made a part of this Contract and may contain pictures, diagrams or measurements of the work area together with a description of the work to be done, materials to be used, and the equipment to be used or installed. 2. WORK SITE: The Project shall be constructed on the property of Owner located at and more particularly described as ________ (hereafter "the Work Site"). Owner hereby authorizes Contractor to commence and complet e the usual and customary excavation and grading on the Work Site as may be required in the judgment of the Contractor to complete the Project. Unless called for in the plans or specifi cations, no landscaping, finish grading, filling or excavation is to be performed at the Work Site by the Contractor. 3. TIME OF COMPLETION: Contractor shall commence the work to be performed under this Contract on or before and shall substantially complete the work on or before . Contractor shall not be liable for any delay due to circumstances beyond its control including strikes, casualty, acts of God, illness, injury, or general unavailability of materials. 4. PERMITS: Contractor shall apply for and obtain such permits and regulatory approvals as may be required by the local municipal/county government, the cost thereof shall be include d as part of the Project price. 5. INSURANCE: Contractor shall maintain general liability and workers compensation insurance. 6. CHANGES TO SCOPE OF WORK: Owner may make changes to the scope of the work, including changes to the plans and specifications, from time to time during the c onstruction of the - 2 - Project. However, any such change or modification shall only be made by written "Change Order" signed by both parties. Such Change Orders shall become part of this Contract. Owner agrees to pay any increase in the cost of the Project as a result of a Change Order. In the event the cost of a Change Order is not known at the time a Change Order is executed, the Contrac tor shall estimate the cost thereof and Owner shall pay the actual cost whether or not it is in excess of the estimated cost. 7. CONTRACT PRICE: {COST PLUS} Owner agrees to pay Contractor the actual cost to Contractor of materials plus the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows: . OR {FIXED FEE} Owner agrees to pay Contractor the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows: . Contractor shall furnish Owner appropriate releases or waivers of lien for all work performed or materials provided at the time the next periodic payment shall be due. 8. LATE PAYMENT/DEFAULT: A failure to make payment for a period in excess of ten (10) days from the due date shall be deemed a material breach of this Contract. If paym ent is not made when due, Contractor may suspend work on the job until such time as all payments due have bee n made without breach of the Contract pending payment or resolution of any dispute. Owner agree s to pay a late charge of 1% of all payments that are more than ten (10) days late plus interest at the rate of 1% per month. 9. DESTRUCTION AND DAMAGE : If the Project is destroyed or damaged for any reason, except where such destruction or damage was caused by the sole negligence of the Contra ctor or its subcontractors, Owner shall pay Contractor for any additional work done by Contractor in rebuilding or restoring the Project to its condition prior to such destruction or damage. If t he estimated cost of replacing work already accomplished by Contractor exceeds 20 percent of the Contract price, either the Contractor or Owner may terminate this Contract. Upon termination by either party, Contractor shall be excused from further performance under this Contract and Owner shall pay Contractor a percentage of the Contract price in proportion to the amount of work accomplished prior to the destruction or damage. 10. ASSIGNMENT : Neither party may assign this Contract, or payments due under the Contract, without the other party’s written consent. Any such assignment shall be void and of no effect. - 3 - 11. INTERPRETATION:(a) Interpretation of Documents. The Contract, plans, and specifications are intended to supplement one another. In the event of a conflict, the specifications shall control the plans, and the Contract shall control both. If work is displayed on the plans but not called for in the specifications, or if the work is called for in the specifications but not displayed on the plans, Contractor shall be required to perform the work as though it were called for and displayed in both documents. (b) Entire Agreement. This Contract constitutes the entire agreement of the parties. No other agreements, oral or written, pertaining to the work to be performed under this Contract exi sts between the parties. This Contract may only be modified by a written agreement signe d by both parties. (c) Governing Law. This Contract shall be interpreted and governed in accordance with the laws of the State of New Jersey. 12. ATTORNEYS’ FEES AND COSTS: If any party to this Contract brings a cause of action against the other party arising from or relating to this Contract, the prevailing part y in such proceeding shall be entitled to recover reasonable attorney fees and court costs. 13. PERFORMANCE: (a) Contractor may, at its discretion, engage licensed subcontractors to perform work pursuant to this Contract provided Contractor shall remain fully responsible for the proper completion of the Project. (b) All work shall be completed in a workman-like manner and in compliance with all building codes and applicable laws. To the extent required by law, all work shall be pe rformed by individuals duly licensed and authorized by law to perform said work. (c) Contractor agrees to remove all debris and leave the premises in broom clean condition. 14. WARRANTY: Contractor's warranty shall be limited to defects in workmanship within the scope of work performed by Contractor and which arise and become known within one (1) year from the date hereof. All said defects arising after one (1) year and defects in material are not warranted by Contractor. Contractor hereby assigns to Owner all warranties on materials as provided by the manufacturer of such materials. A mortgage or security interest to be taken in connection with the financing or sale of the home improvement applies and is described as follows: ______________________________. A person other than the seller is to act as the general contractor or assume responsibility for performance of the contract and is identified as: Name: ______________________________ Address: ______________________________ - 4 - NOTICE TO OWNER Do not sign this contract in blank. You are entitled to a copy of the contract at the time you sign. Keep it to protect your legal rights. Do not sign any completion certificate or agreement stating that you are satisfied with the entire project before this project is complete. Home repair contractors are prohibited by law from requesting or accepting a certificate of completion signed by the owner prior to the actual completion of the work to be performed under the home repair contract. Workmen's compensation and public liability insurance are carried by the home repair contractor and applicable to the work to be performed under the contract. The home repair contractor is qualified as a self-insurer pursuant to Title 34; The home repair contractor is precluded from purchasing workmen's compensation under chapter 15 of Title 34 of the Revised Statutes,and does not carry workmen's compensation insurance. AGREED: CONTRACTOR: Signature Print Name & Title Date License Number Name and Address of License Holder Print Name of Salesperson (if applicable) Address of Salesperson (if applicable) Phone Number OWNER: Signature Print Name Date - 5 - * Required for use in home solicitation sales only: RECEIPT ______________________________ Contractor's Name ______________________________ Contractor’s Place of Business Description of the goods and services sold: ______________________________ Amount of money paid by the owner or the cash value of any goods delivered to the home repair contractor at the time the home repair contract was entered into: ______________________________ NOTICE TO OWNER: YOU MAY RESCIND THIS SALE PROVIDED THAT YOU NOTIFY THE HOME REPAIR CONTRACTOR OF YOUR INTENT TO DO SO BY CERTIFIED MAIL, RETURN RECEIPT REQUESTED, POSTMARKED NOT LATER THAN 5 P.M. OF THE THIRD BUSINESS DAY FOLLOWING THE SALE. FAILURE TO EXERCISE THIS OPTION, HOWEVER, WILL NOT INTERFERE WITH ANY OTHER REMEDIES AGAINST THE HOME REPAIR CONTRACTOR YOU MAY POSSESS. IF YOU WISH YOU MAY USE THIS PAGE AS NOTIFICATION BY WRITING "I HEREBY RESCIND' AND ADDING YOUR NAME AND ADDRESS. A DUPLICATE OF THIS RECEIPT IS PROVIDED BY THE HOME REPAIR CONTRACTOR FOR YOUR RECORDS.