Establishing secure connection…Loading editor…Preparing document…

Construction Contract

This template is fully customizable. Edit the text, fill out the fields, and send it for signature. Give it a try!

CONSTRUCTION CONTRACT

THIS CONSTRUCTION CONTRACT (“Contract”), effective as of the date of the last party to sign below, is between having an address at
address at ("Contractor") and
having an ("Owner").

For valuable consideration the parties hereby agree as follows:

1. SCOPE OF WORK: Contractor shall provide all labor and materials, and perform all work necessary for the completion of the residence, structure, or improvements as described in the drawings and specifications signed by both Owner and Contractor (“Project”) and more particularly described as

Such drawings and specifications are hereby made a part of this Contract. Drawings and specifications shall contain a scale drawing showing the shape, size, and dimensions of the construction and equipment together with a description of the work to be done, materials to be used, and the equipment to be used or installed.

2. WORK SITE: The Project shall be constructed on the property of Owner located at and more particularly described as (hereafter "the Work Site"). Owner hereby authorizes Contractor to commence and complete the usual and customary excavation and grading on the Work Site as may be required in the judgment of the Contractor to complete the Project. Unless called for in the drawings or specifications, no landscaping, finish grading, filling or excavation is to be performed at the Work Site by the Contractor.

3. TIME OF COMPLETION: Contractor shall commence the work to be performed under this Contract on or before and shall substantially complete the work on or before Contractor shall not be liable for any delay due to circumstances beyond its control including strikes, casualty, acts of God, illness, injury, or general unavailability of materials.

4. PERMITS: Contractor shall apply for and obtain such permits and regulatory approvals as may be required by the local municipal/county government, the cost thereof shall be included as part of the Project price.

5. SOIL CONDITIONS: Contractor shall have no responsibility for the condition of the soils at the Work Site. Any excavation, filling or other work required by the Owner other than the usual and customary excavation and grading shall be agreed to in a Change Order for an amount in addition to the Contract Price. Contractor shall not be responsible for any damages suffered by Owner as a result of the soil conditions at the Work Site.

6. INSURANCE: Contractor shall maintain general liability, workers compensation and builder's risk insurance.

7. SURVEY AND TITLE: If the Project is near the Owner's property boundary, Owner will point out property lines to the Contractor. If the Owner or Contractor has any doubt about the location of the property lines, Owner shall provide Contractor with boundary stakes through a licensed surveyor. In addition, Owner shall provide Contractor documentation that Owner has title to the Work Site and shall provide Contractor copies of any covenants, conditions, or restrictions that affect the Work Site.

8. CHANGES TO SCOPE OF WORK: Owner may make changes to the scope of the work, including changes to the drawings and specifications, from time to time during the construction of the Project. However, any such change or modification shall only be made by written "Change Order" signed by both parties. Such Change Orders shall become part of this Contract. Owner agrees to pay any increase in the cost of the Project as a result of a Change Order. In the event the cost of a Change Order is not known at the time a Change Order is executed, the Contractor shall estimate the cost thereof and Owner shall pay the actual cost whether or not it is in excess of the estimated cost.

9. CONTRACT PRICE:

{COST PLUS}

Owner agrees to pay Contractor the actual cost to Contractor of materials plus the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows:

OR

{FIXED FEE}

Owner agrees to pay Contractor the sum of $ for performing the services set forth in the scope of the work. Contractor shall be paid as follows:

Contractor shall furnish Owner appropriate releases or waivers of lien for all work performed or materials provided at the time the next periodic payment shall be due.

10. LATE PAYMENT/DEFAULT: A failure to make payment for a period in excess of ten (10) days from the due date shall be deemed a material breach of this Contract. If payment is not made when due, Contractor may suspend work on the job until such time as all payments due have been made without breach of the Contract pending payment or resolution of any dispute. Owner agrees to pay a late charge of 1% of all payments that are more than ten (10) days late plus interest at the rate of 1% per month.

11. DESTRUCTION AND DAMAGE: If the Project is destroyed or damaged for any reason, except where such destruction or damage was caused by the sole negligence of the Contractor or its subcontractors, Owner shall pay Contractor for any additional work done by Contractor in rebuilding or restoring the Project to its condition prior to such destruction or damage. If the estimated cost of replacing work already accomplished by Contractor exceeds 20 percent of the Contract price, either the Contractor or Owner may terminate this Contract. Upon termination by either party, Contractor shall be excused from further performance under this Contract and Owner shall pay Contractor a percentage of the Contract price in proportion to the amount of work accomplished prior to the destruction or damage.

12. ASSIGNMENT: Neither party may assign this Contract, or payments due under the Contract, without the other party's written consent. Any such assignment shall be void and of no effect.

13. INTERPRETATION:

(a) Interpretation of Documents. The Contract, drawings, and specifications are intended to supplement one another. In the event of a conflict, the specifications shall control the drawings, and the Contract shall control both. If work is displayed on the drawings but not called for in the specifications, or if the work is called for in the specifications but not displayed on the drawings, Contractor shall be required to perform the work as though it were called for and displayed in both documents.

(b) Entire Agreement. This Contract constitutes the entire agreement of the parties. No other agreements, oral or written, pertaining to the work to be performed under this Contract exists between the parties. This Contract may only be modified only by a written agreement signed by both parties.

(c) Governing Law. This Contract shall be interpreted and governed in accordance with the laws of the State of Washington.

14. ATTORNEYS' FEES AND COSTS: If any party to this Contract brings a cause of action against the other party arising from or relating to this Contract, the prevailing party in such proceeding shall be entitled to recover reasonable attorney fees and court costs.

15. PERFORMANCE:

(a) Contractor may, at its discretion, engage licensed subcontractors to perform work pursuant this Contract provided Contractor shall remain fully responsible for the proper completion of the Project.

(b) All work shall be completed in a workman-like manner and in compliance with all building codes and applicable laws. To the extent required by law, all work shall be performed by individuals duly licensed and authorized by law to perform said work.

(c) Contractor agrees to remove all debris and leave the premises in broom clean condition.

16. WARRANTY: Contractor's warranty shall be limited to defects in workmanship within the scope of work performed by Contractor and which arise and become known within one (1) year from the date hereof. All said defects arising after one (1) year and defects in material are not warranted by Contractor. Contractor hereby assigns to Owner all warranties on materials as provided by the manufacturer of such materials.

AGREED:

CONTRACTOR:

 

OWNER:

STATUTORY NOTICE REQUIRED FOR A CONTRACT FOR SALE, CONSTRUCTION, OR SUBSTANTIAL REMODEL OF A RESIDENCE

CHAPTER 64.50 RCW CONTAINS IMPORTANT REQUIREMENTS YOU MUST FOLLOW BEFORE YOU MAY FILE A LAWSUIT FOR DEFECTIVE CONSTRUCTION AGAINST THE SELLER OR BUILDER OF YOUR HOME. FORTY-FIVE DAYS BEFORE YOU FILE YOUR LAWSUIT, YOU MUST DELIVER TO THE SELLER OR BUILDER A WRITTEN NOTICE OF ANY CONSTRUCTION CONDITIONS YOU ALLEGE ARE DEFECTIVE AND PROVIDE YOUR SELLER OR BUILDER THE OPPORTUNITY TO MAKE AN OFFER TO REPAIR OR PAY FOR THE DEFECTS. YOU ARE NOT OBLIGATED TO ACCEPT ANY OFFER MADE BY THE BUILDER OR SELLER. THERE ARE STRICT DEADLINES AND PROCEDURES UNDER STATE LAW, AND FAILURE TO FOLLOW THEM MAY AFFECT YOUR ABILITY TO FILE A LAWSUIT.

Notes:

The following “Disclosure Statement to Customer” is required for construction contracts of $1,000 or more.

NOTICE TO CUSTOMER

This contractor is registered with the state of Washington, registration no. and has posted with the state a bond or deposit of for the purpose of satisfying claims against the contractor for breach of contract including negligent or improper work in the conduct of the contractor's business. The expiration date of this contractor's registration is

THIS BOND OR DEPOSIT MIGHT NOT BE SUFFICIENT TO COVER A CLAIM THAT MIGHT ARISE FROM THE WORK DONE UNDER YOUR CONTRACT.

This bond or deposit is not for your exclusive use because it covers all work performed by this contractor. The bond or deposit is intended to pay valid claims up to that you and other customers, suppliers, subcontractors, or taxing authorities may have.

FOR GREATER PROTECTION YOU MAY WITHHOLD A PERCENTAGE OF YOUR CONTRACT.

You may withhold a contractually defined percentage of your construction contract as retainage for a stated period of time to provide protection to you and help insure that your project will be completed as required by your contract.

YOUR PROPERTY MAY BE LIENED.

If a supplier of materials used in your construction project or an employee or subcontractor of your contractor or subcontractors is not paid, your property may be liened to force payment and you could pay twice for the same work.

FOR ADDITIONAL PROTECTION YOU MAY REQUEST THE CONTRACTOR TO PROVIDE YOU WITH ORIGINAL “LIEN RELEASE” DOCUMENTS FROM EACH SUPPLIER OR SUBCONTRACTOR AT YOUR PROJECT.

The contractor is required to provide you with further information about lien release document if you request it. General information is also available from the state Department of Labor and Industries.

Acknowledgement of Receipt of Notice to Customer:

Dated this day of of the year

Customers Full Name and Signature

Enter text

What a Construction Contract Is and what it covers

A Construction Contract is a written agreement that defines the scope, price, schedule, responsibilities, and risk allocation between parties on a building project. It captures work descriptions, payment terms, milestones, change‑order procedures, warranties, insurance and indemnity provisions, and dispute resolution. Properly executed, it creates enforceable obligations and clarifies expectations for owners, general contractors, subcontractors and suppliers. Electronic signatures are commonly used to execute these agreements when parties meet ESIGN and applicable state electronic signature rules.

Why a clear Construction Contract matters

A detailed contract reduces misunderstandings, limits disputes, and preserves payment rights like mechanic’s liens. It sets measurable obligations for schedule, quality, and payments while allocating risk and remedies in case of delay, defect, or nonpayment.

Why a clear Construction Contract matters

Who typically prepares and signs a Construction Contract

Typical users include parties responsible for project delivery and those who protect project interests.

  • General contractors and construction firms who manage on‑site work, subcontractor coordination, and overall project schedule and budget.
  • Property owners, developers, and project sponsors who define project requirements, approve budgets, and hold payment obligations.
  • Subcontractors, suppliers, architects, and engineers who rely on contract terms for scope, payment timing, and warranty responsibilities.

Signatory roles and internal reviewers (project managers, procurement, legal) should be identified early to prevent execution delays.

Core sections to include in a professional Construction Contract

A robust contract organizes obligations clearly and links attachments (plans, specs, schedules) so parties can act on the same terms.

Scope of Work

Precise description of tasks, deliverables, and referenced plans or specifications; attach drawings and schedules as enforceable exhibits to avoid scope disputes.

Payment Terms

Contract price, progress payment schedule, retention amount and release terms, acceptable invoices, and remedies for late payment, including interest and stop‑work rights.

Project Schedule

Start date, milestone and substantial completion dates, liquidated damages or incentives, and requirements for baseline schedules and updates.

Change Orders

Written change‑order process, approval authority, pricing method for changes, and time‑impact evaluation to preserve entitlement and avoid disputes.

Warranties & Insurance

Express workmanship and materials warranties, insurance minimums, certificate requirements, and indemnity scope to allocate risk properly.

Dispute Resolution

Preferred mechanisms (negotiation, mediation, arbitration, or court), choice of law, venue, and requirements for notices and claim timing.

Step-by-step: complete and execute a Construction Contract

Use a repeatable sequence to prepare, approve, sign, and distribute the executed agreement.

  • 01
    Prepare Document: Assemble scope, attachments, and pricing with version control.
  • 02
    Internal Review: Legal, PM, and finance confirm obligations and insurance requirements.
  • 03
    Execute Signatures: Collect signatures from authorized representatives using an accepted method.
  • 04
    Distribute Copies: Send executed copies to all parties, permit files, and project management systems.

Where signed Construction Contracts are stored and shared

Signed contracts should be routed to project stakeholders and retained in project systems immediately after execution.

  • Owner Records: Owner receives original executed copy and stores it in corporate contract repository.
  • Contractor File: General contractor retains master contract and distributes subcontract exhibits internally.
  • Lender or Surety: Provide lender or surety with executed copies when required by financing agreements.
  • Permitting Office: Submit required executed documents with permit applications if local rules demand them.

Digital signing and system requirements for eExecution

Electronic execution can streamline signing if your platform meets authentication, audit and storage needs.

  • Authentication: Use email/SMS codes or stronger ID verification for high‑value contracts.
  • Integrations: Connect to Procore, NetSuite, or Google Workspace for routing and archival.
  • File formats: Support PDF and DOCX with immutable audit trails.

Maintain chain-of-custody records, preserve audit trails, and ensure exportable signed copies for permitting, lender, and contract audit purposes.

Typical timing elements to include and monitor

Define dates and deadlines clearly so milestones, payments, and claims operate predictably.

Effective Date:

Date when the contract and obligations begin.

Commencement Date:

When onsite work is scheduled to start.

Substantial Completion:

Target for when project is usable for intended purpose.

Final Completion:

Date for punchlist completion and final acceptance.

Payment Due Dates:

Schedule for progress, retention release, and final payment.

Common mistakes to avoid when preparing a Construction Contract

  • Vague scope descriptions that omit plans or specs, leading to differing interpretations and change claims.
  • Missing or inconsistent signature blocks and failure to verify signatory authority before execution.
  • Unclear payment milestones or retention language that create payment disputes and slow cash flow.
  • Failure to attach or date exhibits and schedules so the contract references the correct governing documents.

Risks and consequences of an incomplete or incorrect contract

Dispute Exposure: Increased litigation or arbitration risk when terms are ambiguous.
Lien Vulnerability: Failure to preserve lien rights or respond to lien notices.
Payment Delays: Ambiguous invoice requirements can justify payer withholding.
Permit Noncompliance: Incorrect documents can delay permits or inspections.
Insurance Gaps: Missing coverage clauses create uncovered losses.
Schedule Exposure: Undefined critical path and float disputes increase delay claims.

Real examples showing how online execution is used in practice

These cases illustrate common outcomes when parties adopt electronic execution and organized contract workflows.

Martin Properties — Onsite and remote signing

Tim Martin used online signed contracts to process documents remotely while maintaining compliance.

  • The team executed change orders and release forms in the field quickly.
  • The result was consistent documentation across mobile and desktop, fewer missing signatures, and improved ability to meet lender and permitting timelines.

Optica Ventures — Simpler client handling

Optica streamlined client signoffs for smaller commercial projects using standardized templates.

  • Templates reduced manual edits and turnaround time.
  • The standardized approach lowered administrative overhead, cut follow‑up cycles, and ensured each contract referenced current drawings and payment milestones.

Pricing snapshot for eSignature vendors commonly used with Construction Contracts

Pricing and capabilities vary by plan; signNow is listed first for vendor comparison and each column shows core pricing and plan features.

signNow DocuSign Adobe Sign PandaDoc HelloSign
Starting Price $8/user/mo $15/user/mo $14/user/mo $19/user/mo $15/user/mo
Free Trial 7-day trial Varies Varies Varies Varies
Bulk Send / Envelope Cap Yes, no cap Yes, 100 env/user/yr Yes Yes No
Audit Trail Yes Yes Yes Yes Yes
HIPAA Compliant Yes Yes Yes No No

Frequently asked questions about executing Construction Contracts

Answers to common legal, execution, and storage questions for Construction Contracts and related filings.


Need help? Contact support

be ready to get more
Join over 28 million airSlate SignNow users